Seattle Washington Building Expert Directory

Defect Claims Called “Witch Hunt”

November 20, 2013 — CDJ STAFF
Saying that “it was blatantly obvious that LAWA’s airport maintenance has culpability in this matter,” Tutor-Saliba Corp is claiming that the recent lawsuit from Los Angeles World Airports, the operators of LAX, is “an apparent witch hunt.” The airport has claimed that Tutor-Saliba’s work in building the runway was defective. The firm notes in response that their warranty against defects expired in 2009 and claims that some of the areas with problems are areas they did work. Instead of defective workmanship, Tutor-Saliba has suggested that the problems with the runway are due to poor maintenance. Their suggestion is that LAX review its maintenance procedures. Read the court decision
Read the full story...
Reprinted courtesy of

Corps Releases Final Report on $29B Texas Gulf Coast Hurricane Defense Plan

October 11, 2021 — James Leggate - Engineering News-Record
A $28.87 billion plan to protect the Texas Gulf Coast’s residents and infrastructure against hurricanes and storm surge with a series of coastal storm risk management and ecosystem restoration projects took a step closer to reality Sept. 10 with the release of a final feasibility report and final environmental impact statement from the U.S. Army Corps of Engineers and Texas General Land Office (GLO). Reprinted courtesy of James Leggate, Engineering News-Record Mr. Leggate may be contacted at https://www.enr.com/leggatej@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

A Retrospective As-Built Schedule Analysis Can Be Used to Support Delay

May 23, 2022 — David Adelstein - Florida Construction Legal Updates
Delay claims are part of construction. There should be no surprise why. Time is money. A delay claim should be accompanied by expert opinions that bolster evidence that gets introduced. The party against whom the delay claim is made will also have an expert – a rebuttal expert. Not surprisingly, each of the experts will rely on a different critical path as to relates to the same project. The party claiming delay will rely on a critical path that shows the actions of the other party impacted their critical path and proximately caused the delay. This will be refuted by the opposing expert that will challenge the critical path and the actions claimed had no impact on the critical path (i.e., did not proximately cause the delay). Quintessential finger pointing! This was the situation in CTA I, LLC v. Department of Veteran Affairs, CBCA 5826, 2022 WL 884710 (CBCA 2022), where the government terminated the contractor for convenience and the contractor claimed equitable adjustments for, among other things, delay. The contractor’s expert relied on an as-built critical path analysis by “retrospectively creating updates to insert between the contemporaneous updates.” Id., supra, n.3. The government’s expert did not do a retrospective as-built analysis and relied on only contemporaneous schedule updates. Id. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Is the Sky Actually Falling (on Green Building)?

November 03, 2016 — Christopher G. Hill – Construction Law Musings
I have spoken on many occasions here at Construction Law Musings and elsewhere about the risks and rewards for contractors found in sustainable construction. The rewards were fairly apparent. New markets, government incentives and the desires of owners to be “green” clearly point toward a need for contractors to get into the sustainable building game. However, when I was first writing my Eeyore like thoughts most of the thoughts of all us construction attorneys were speculative. Whether because wholesale “green” construction was relatively new or because the court process was relatively slow, there were not many ways to test if our, shall we say “less optimistic,” predictions were going to come to pass. For better or worse, several of the more dire predictions have come true. One major green construction debacle is the Destiny USA litigation. I cannot possibly set out all of the various issues as well as my friend and colleague Chris Cheatham does in his e-book about the project and its aftermath. I highly recommend this e-book and the posts found at Chris’ Green Building Law Update blog for those of you interested in how the IRS, the USGBC and the Green Bonds Program interact to cause many a pitfall for construction and design professionals. Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, The Law Office of Christopher G. Hill, PC
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Recommencing Construction on a Project due to a Cessation or Abandonment

October 26, 2017 — David Adelstein - Florida Construction Legal Updates
There are instances where the owner of a construction project terminates its general contractor prior to the completion of the project. There are instances where the owner suspends the work prior to the completion of the project, meaning there is a cessation in the construction. And, there are instances where the project is simply abandoned. I have been involved in all instances, and the owner’s reasons vary…from an owner claiming a termination for default, termination for convenience, or a suspension or abandonment due to the market or financial factors. Regardless of the owner’s reasoning, at some point—hopefully—the owner will want to resume or, more properly stated, recommence construction and complete the project. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Florida Construction Legal Updates
Mr. Adelstein may be contacted at Dadelstein@gmail.com

Falling Tree Causing Three Injuries/Deaths Is One Occurrence

September 28, 2017 — Tred R. Eyerly - Insurance Law Hawaii
In a decision by Judge Sutton, the Sixth Circuit affirmed the district court's ruling that a falling tree causing one injury and two deaths was the result of a single occurrence. Evanston Ins. Co. v. Housing Auth. of Somerset, 2017 U.S. App. LEXIS 15199 (6th Cir. Aug. 15, 2017). A large tree fell on cousins Kaitlyn Griffin and Joshua Thacker. Kaitlyn died within minutes. She was pregnant at the time. Doctors delivered her baby, but the baby died shortly thereafter. Joshua survived but suffered serious injury. In December 2013, a state court jury found the Housing Authority liable for the accident and awarded $3.7 million in damages. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

In Review: SCOTUS Environmental and Administrative Decisions in the 2020 Term

August 10, 2021 — Anthony B. Cavender - Gravel2Gavel
Several decisions of interest were issued in the 2020 term, which stretched from October 2020 until early July 2021. This review will concentrate on environmental and administrative law cases. Texas v. New Mexico On December 14, 2020, the Court issued its ruling in an Original Action. Water is precious in the Pecos River Valley, and the distribution of water is governed by the Pecos River Compact. Here, Texas complained that New Mexico illegally was seeking delivery credits for evaporated water credits but the Court agreed that New Mexico was entitled to these credits under the provisions of the River Master’s Manual. Florida v. Georgia On April 1, 2021, in another waters right ruling on an Original Action filed in the Supreme Court, the Court rejected Florida’s claims that Georgia’s use of interstate waters harmed Florida’s businesses. Florida had to satisfy a heavy burden of proof, which it failed to do. Read the court decision
Read the full story...
Reprinted courtesy of Anthony B. Cavender, Pillsbury
Mr. Cavender may be contacted at anthony.cavender@pillsburylaw.com

Commonwealth Court Strikes Blow to Philly Window and Door Ordinance

January 05, 2017 — Wally Zimolong – Supplemental Conditions
On December 22, 2016, the Pennsylvania Commonwealth Court issued an important opinion that has flown under the radar somewhat. The case Rufo v. Board of Licenses and Inspection Review, invalidates a major portion of Philadelphia’s so called windows and doors ordinance, which requires owners of vacant properties to install glass windows and doors with frames on vacant properties. A copy of the opinion can be found here. (I only learned about the case because of a tweet by a litigator with the pro-freedom group the Institute for Justice.) The Windows and Doors Ordinance The case concerns Section 306.2 of the Property Maintenance Code which requires “the owner of a vacant building that is a blighting influence, as defined in this subcode, [to] secure all spaces designed as windows with windows that have frames and glazing and all entryways with doors.” Property owners found in violation of the ordinance can face stiff fines. Property owners are subject to a daily fine for each door and window in violation of the Ordinance. The fine is $300 per window or door. However, because most vacant properties have multiple windows and doors the fines can add up exponentially. Read the court decision
Read the full story...
Reprinted courtesy of Wally Zimolong, Zimolong LLC
Mr. Zimolong may be contacted at wally@zimolonglaw.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES