Cambridge Massachusetts Building Expert Directory

Federal Court of Appeals Signals an End to Project Labor Agreement Requirements Linked to Development Tax Credits

October 20, 2016 — Gregory R. Begg & Aaron C. Schlesinger – Peckar & Abramson, P.C.
What Action Should Owners, Developers and Contractors Take in Anticipation of Successful Challenges to PLA Requirements? Recently, a federal court in New Jersey issued a decision which very well may invalidate all Project Labor Agreements (“PLA’s”) entered into as a condition to receipt of tax incentives for private development. Tax incentives utilized to promote private development are different, according to the court, than typical public works projects where PLA requirements have generally been held valid. Owners, developers, contractors and governmental entities must assess the consequences of this decision upon contracts already and to be awarded in the future where tax benefits may be linked to a PLA requirement. In 1993, in what has become known as the Boston Harbor Case, the United States Supreme Court held that state and local governmental entities may condition the award of public works contracts on the contractor’s agreement to enter into PLA’s. That decision has been followed nationwide since then to uphold the validity of various state and local law bidding conditions requiring successful bidders to negotiate and enter into project labor agreements as a condition to the award of public works contracts. The rationale is that when the government, like any other private party, is participating in an economic market, it may exercise its discretion in setting terms and conditions it believes best suit its interests in the efficient procurement of goods and services in that market. Therefore, a PLA requirement by a governmental entity engaged in market activity is no more or less valid than a PLA requirement on a purely private project. Reprinted courtesy of Gregory R. Begg, Peckar & Abramson, P.C. Aaron C. Schlesinger, Peckar & Abramson, P.C. Mr. Begg may be contacted at gbegg@pecklaw.com Mr. Schlesinger may be contacted at aschlesinger@pecklaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Application Of Two Construction Contract Provisions: No-Damages-For-Delay And Liquidated Damages

February 14, 2022 — David Adelstein - Florida Construction Legal Updates
A recent Florida opinion between a prime contractor and a Florida public body touches upon two important issues: (1) the application of a no-damage-for-delay provision; and (2) the application of a liquidated damages provision. Both provisions find there way into many construction contracts. Unfortunately, the opinion is sparse on facts. Nevertheless, the application of these provisions is worthy of consideration. In this opinion, Sarasota County v. Southern Underground Industries, Inc., 2022 WL 162977 (Fla. 2d DCA 2022), a county hired a contractor to install sanitary and water piping underneath a waterway. During construction, a nearby homeowner complained that vibration from the drilling caused damage to his home. As a result, the county stopped the contractor’s work to address a potential safety issue, as it was contractually entitled to do. The contractor hired a structural engineer to inspect the house and the engineer issued a report determining that any alleged damage was cosmetic and that there was sufficient monitoring of the vibrations to prevent future damage. The contractor also had an insurance policy to cover any homeowner claim for damage. However, upon receipt of the engineer’s report, the county did not lift its stop work order. Rather, the stop work order remained in place for an additional 71 days. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Real Estate & Construction News Roundup (9/4/24) – DOJ Sues RealPage, Housing Sales Increase and U.S. Can’t Build Homes Fast Enough

October 07, 2024 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
In our latest roundup, environmental regulations tighten for commercial properties, Wells Fargo sells most of its commercial mortgage services business, first-time home buyers struggle with housing affordability, and more!

The U.S. Department of Justice announced that it is suing the real estate company RealPage, saying it engaged in a price-fixing scheme to drive up rents. (Jennifer Ludden, NPR)
As environmental regulations for commercial buildings and properties tighten across the U.S., green leases and technologies offer owners and operators opportunities to reduce their portfolios’ carbon footprints, generate cost savings and further align with ESG goals. (Nish Amarnath, Construction Dive)
Wells Fargo & Co. agreed to sell most of its commercial mortgage servicing business to Trimont LLC, ceding the title of biggest US commercial and multifamily mortgage servicer to the Atlanta-based firm. (Hannah Levitt and Scott Carpenter, Yahoo)

Read the court decision
Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

UCP Buys Citizen Homes

March 31, 2014 — Beverley BevenFlorez-CDJ STAFF
UCP, a home builder and land developer based in San Jose, California, has purchased “Charlotte-based Southeast regional home building venture Citizens Homes, whose chairman is well-known home building industry veteran Tony Mon, and whose president and chief operating officer is third-generation home builder Scott Thorson,” according to Big Builder. According to a UCP press statement, as quoted by Big Builder, “[t]he purchase price, estimated to be approximately $15 million, is based on the total assets of Citizens at the closing of the acquisition, less cash and cash equivalents, and less certain assumed trade payables. In addition, Citizens is eligible to receive earnout payments from UCP of up to $6 million in the aggregate based on performance over the next five years.” The acquisition is expected to close during the second quarter of 2014. Read the court decision
Read the full story...
Reprinted courtesy of

California Posts Nation’s Largest Gain in Construction Jobs

March 28, 2012 — CDJ STAFF

California added about 8,900 construction jobs in January, 2012, as compared to December, 2011, leading the nation in the number of added construction jobs. Thirty-four other states also saw added construction jobs. A year prior, only twenty-eight states added construction jobs. The Associated General Contractors of America analyzed the monthly report from the Labor Department. Ken Simonson, the chief economist for the Associated General Contractors of America noted that “the gains this January partly reflect very mild weather this winter and exceptionally cold and snowy conditions a year before.”

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

Happy Thanksgiving from CDJ

November 27, 2013 — CDJ STAFF
As Thanksgiving kicks off this holiday season, all of us at CDJ would like to gratefully acknowledge all of our valued readers and contributors in the construction defect and claims community. This November marks CDJ’s third anniversary. With your continued support we are looking forward to expanded coverage and features in our 4th year. Best wishes to you and yours this holiday season! Read the court decision
Read the full story...
Reprinted courtesy of

Colorado Supreme Court to Hear Colorado Pool Systems, Inc. v. Scottsdale Insurance Company, et al.

October 10, 2013 — David M. McLain — Higgins, Hopkins, McLain & Roswell, LLC
The Colorado Pool case has been featured in two past blog entries, including: “An Arapahoe County District Court Refuses to Apply HB 10-1394 Retrospectively,” which discussed the case at the trial court level, and “Colorado Court of Appeals Finds Damages to Non-Defective Property Arising From Defective Construction Covered Under Commercial General Liability Policy,” which discussed the case at the Court of Appeals level. In both instances, the courts held that retroactively applying C.R.S. C.R.S. § 13-20-808 to policies in effect prior to the date of the statute’s enactment would be impermissibly retrospective because it would change the coverage under the policy for which the parties had originally bargained. Read the court decision
Read the full story...
Reprinted courtesy of David M. McLain
David M. McLain can be contacted at mclain@hhmrlaw.com

Wisconsin Court Applies the Economic Loss Doctrine to Bar Negligence Claims for Purely Economic Losses

August 17, 2020 — Rahul Gogineni - The Subrogation Strategist
In Mech. Inc. v. Venture Elec. Contrs., Inc., No. 2018AP2380, 2020 Wisc. App. LEXIS 170, the Court of Appeals of Wisconsin, District Two, considered whether a party may bring a negligence claim for purely economic damages. In upholding the lower court, the appellate court found that a party is barred by the Economic Loss Doctrine from bringing a negligence claim for purely economic damages. Both parties involved in this action were subcontractors on a building project at the Great Lakes Research Facility for the University of Wisconsin-Milwaukee. As a result of Venture Electrical Contractors, Inc. (Venture) not paying for requested work, Mechanical, Inc. (Mechanical) sued Venture for $11,961.31. Venture, in turn, countersued in negligence for $1.1 million for costs incurred due to delays and untimely performance. Mechanical sought dismissal of the negligence claim based upon the Economic Loss Doctrine. Finding that the Economic Loss Doctrine applies to purely economic losses, the trial court dismissed Venture’s negligence claim. Venture appealed to the Court of Appeals of Wisconsin. Read the court decision
Read the full story...
Reprinted courtesy of Rahul Gogineni, White and Williams LLP
Mr. Gogineni may be contacted at goginenir@whiteandwilliams.com

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES