A Few Things You Might Consider Doing Instead of Binging on Netflix
April 13, 2020 —
Garret Murai - California Construction Law BlogGovernments throughout the world have issued “shelter in place” orders requiring that residents stay at home except for “essential” purposes. As a result, in the United States, more than a third of Americans have been ordered to stay at home. This, in turn, has had a direct impact on construction projects which have slowed or have been temporarily shuttered altogether, and it will (not may) have an impact on the flow of project funds. So what can project owners and contractors do? We’ve got a few tips.
1. Read Your Contract, Paying Particular Attention to Force Majeure, No Damages for Delay and Notice Provisions
For the most part, with the exception of statutory rights and remedies which we will discuss below, your contract spells out your rights and remedies should the proverbial “S” hit the fan. It is, in other words, the rules you agreed to, and you should know what those rules provide. Three provisions you should look for, and if they’re in your contract, you should review carefully are: (1) Force majeure provisions; (2) No damages for delay provisions; and (3) notice provisions.
Read the court decisionRead the full story...Reprinted courtesy of
Garret Murai, Nomos LLPMr. Murai may be contacted at
gmurai@nomosllp.com
Medical Center Builder Sues Contracting Agent, Citing Costly Delays
March 19, 2014 —
Beverley BevenFlorez-CDJ STAFFThe Pennsylvania firm Bedwell Co. “has sued the Camden County Improvement Authority, saying it is owed $4.6 million for construction of [the Cooper Medical School of Rowan University]” in Camden, New Jersey, according to the Courier-Post. The Bedwell Co. alleges that its expenses exceeded fifty million, “but that it has been paid only $46 million.”
The lawsuit states, as quoted by the Courier-Post, “From its inception, the project was plagued by delays due to defects in the design document and other circumstances that were beyond Bedwell’s control.” Furthermore, there were “an abnormally large quantity of design changes, schedule disputes, schedule disruptions and work-activity interference.”
“Representatives of the CCIA and HDR could not be reached for comment Wednesday,” according to the Courier-Post. “Bedwell declined to comment on the allegations in the suit.”
Read the court decisionRead the full story...Reprinted courtesy of
No Occurrence Found for Damage to Home Caused by Settling
October 22, 2014 —
Tred R. Eyerly – Insurance Law HawaiiThe Nebraska Supreme Court found the insurer properly denied coverage to the general contractor for damage to a home caused by settlement. Cizek Homes, Inc. v. Columbia Nat. Ins. Co., 2014 Neb. LEXIS 152 (Neb. Sept. 9, 2014).
The general contractor built and then sold the residence. Subsequently, the homeowners complained that the soil beneath their residence was settling and causing damage to their home. The homeowners presented a draft complaint to the general contractor, alleging that negligence and faulty workmanship had caused damage to the home.
The general contractor notified its carrier, Columbia. Coverage was denied.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Insurance Law HawaiiMr. Eyerly may be contacted at
te@hawaiilawyer.com
Insurer Motion to Intervene in Underlying Case Denied
August 10, 2021 —
Tred R. Eyerly - Insurance Law HawaiiThe Colorado Supreme Court determined that the insurer defending under a reservation of rights could not intervene in the underlying case after the insured assigned its rights to any bad faith claim against the insurer. Auto-Owners Ins. Co. v. Bolt Factory Lofts Owners Ass'n, Inc., 2021 Colo. LEXIS 365 (Colo. May 24, 2021).
Bolt Factory initiated a construction defects lawsuit against various contractors. Several defendants filed third-party complaints against subcontractors, including Sierra Glass Company. Auto-Owners agreed to defend its insured, Sierra Glass, under a reservation of rights. Auto-Owners declined to settle with Bolt Factory for $1.9 million, within policy limits. Sierra Glass then retains independent counsel and entered into a settlement with Bolt Factory. The settlement allowed Sierra Glass to assign its bad faith claims to Bolt Factory in exchange for the right to pursue the insurer for payment of the excess judgment rather than Sierra Glass. Instead of entering into a stipulated judgment, Bolt Factory and Sierra Glass proceeded to an abbreviated trial.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
House of the Week: Spanish Dream Home on California's Riviera
July 30, 2014 —
Emily Heffter – BloombergFamous clients of renowned Los Angeles architect Richard Landry are not known for their restraint.
The Brentwood estate he designed for Tom Brady and Gisele Bundchen has a moat and just sold to Dr. Dre for $40 million. Michael Jackson died in a home Landry designed (a rental), and he has designed luxurious mansions for Wayne Gretzky, Michael Bolton, Mark Wahlberg and Kenny G.
Still, homeowner Lorna Auerbach did something unique when Landry started designing her dream home in Pacific Palisades: She flew him to Spain, with her, for 10 days.
Read the court decisionRead the full story...Reprinted courtesy of
Emily Heffter, Bloomberg
Wisconsin Federal Court Addresses Scope Of Appraisal Provision In Rental Dwelling Policy
September 05, 2022 —
James M. Eastham - Traub LiebermanIn Higgins v. State Farm Fire & Cas. Co., No. 22-C-198, 2022 U.S. Dist. LEXIS 117477 (E.D. Wis. July 5, 2022), the Court addressed the often disputed question of whether an appraisal provision in an insurance policy is limited to disputes over valuation or extends beyond valuation to causation and/or coverage. The underlying loss in the Higgins case involved a fire at a rental dwelling owned by the Plaintiff and insured by State Farm under a Rental Dwelling policy for, among other things, fire losses. Subsequent to being notified of the fire, State Farm investigated and provided the Plaintiff with its estimated cost of repair. Plaintiff disputed the estimate, including the repairs necessary, and also sought additional sums for debris removal and lost rent.
The insurance policy at issue in Higgins included an appraisal provision which provided: “If you and we fail to agree on the amount of loss, either one can demand that the amount of the loss be set by appraisal.” Pursuant to this provision, Plaintiff demanded that State Farm submit to an appraisal to resolve the parties' disagreements. State Farm responded by indicating that it would enter into appraisal over the areas where there were "pricing differences" but not areas where there were "scope differences." According to State Farm, there were a number of issues regarding the scope of repairs necessary to restore the dwelling to its pre-loss condition. Plaintiff disagreed with State Farm's position and did not seek to move forward with the appraisal process on only the items State Farm identified as appropriate for appraisal.
Read the court decisionRead the full story...Reprinted courtesy of
James M. Eastham, Traub LiebermanMr. Eastham may be contacted at
jeastham@tlsslaw.com
Hydrogen Powers Its Way from Proof of Concept to Reality in Real Estate
May 10, 2021 —
Victoria Judd, Sidney L. Fowler & Robert G. Howard - Gravel2Gavel Construction & Real Estate Law BlogHydrogen is the new buzzword in every industry, and real estate is no exception. Hydrogen does not emit carbon dioxide when burnt and could therefore help reduce the climate impact of buildings, which in aggregate represent one of the biggest emitters of greenhouse gases after industry and surface transport. To the extent that hydrogen is to become an important power source globally, it will need to enter the domestic power market. The first step appears to be the development of pilot villages.
In the UK, there are several hydrogen trials in uninhabited properties or in closed private networks. There are some uninhabited houses on a Royal Air Force base in Cumbria that are exclusively heated with hydrogen and also a private gas network at Keele University which uses 20 percent hydrogen blended with natural gas. In addition, there is a small village near Newcastle that is being used as a test case: for a period of 10 months starting in spring 2021, up to 20 percent hydrogen will be blended into the natural gas network so that more than 650 homes can be partially heated by hydrogen. It is expected that a small number of additional villages will be able to heat their homes with 100 percent hydrogen as soon as 2022, with a scale up to have a hydrogen town by 2030.
Reprinted courtesy of
Victoria Judd, Pillsbury,
Sidney L. Fowler, Pillsbury and
Robert G. Howard, Pillsbury
Ms. Judd may be contacted at victoria.judd@pillsburylaw.com
Mr. Fowler may be contacted at sidney.fowler@pillsburylaw.com
Mr. Howard may be contacted at robert.howard@pillsburylaw.com
Read the court decisionRead the full story...Reprinted courtesy of
Brown Paint Doesn’t Cover Up Construction Defects
April 25, 2012 —
CDJ STAFFIn a decision that describes the case as illustrating “the perils that real estate brokers and their agents assume when acting as a dual listing agent to both the buyers and sellers of the same house,” the California Court of Appeals has issued a decision in William L. Lyon & Associates v. The Superior Court of Placer County. Lyon & Associates sought summary judgment to dismiss the claims of the Henleys who bought a home in a transaction where a Lyon agent represented both sides.
The prior owners of the home, the Costas, had used a Lyon agent in purchasing their home. When they later sought to sell it, that agent “became aware of some of the house’s defects and problems.” In response, the Costas sought the help of another agent, Connie Gidal, also of Lyons & Associates. Photos taken in the presence of Ms. Gidal show defects of the paint and stucco. The Costas also took the step of painting the house dark brown. During the sale process, “rain caused many of the painted-over defects to reappear.” The Costas “purchased more dark brown paint and covered up the newly visible damage prior to inspection by the Henleys.”
With the damage concealed, the Henleys bought the home in May 2006. The agreement with Lyons & Associates noted that “a dual agent is obligated to disclose known facts materially affecting the value or desirability of the property to both parties.” Escrow closed on May 9, 2006. The contract with the broker included a two-year limit on the time to bring legal action.
The Henleys moved in during June 2006, and “began to discover construction defects that had been concealed by the Costas.” In addition to the painted-over stucco problems, the Henleys found that the Costas had “installed quartzite stone overlays on the backyard steps in a manner that caused water intrusion on the house’s stucco walls.”
In May 2009, the Henleys sued the Costas, Ron McKim Construction, Lyons & Associates, and Ms. Gidal. Their complaint alleged that Lyons & Associates had committed breach of contact, negligence, fraud, breach of fiduciary duty, and negligent nondisclosure in connection with the construction defects. The Costas named Lyons in a cross complaint. Lyons moved for summary judgments on the grounds that the two-year statute of limitations had expired before the complaint and cross-complaint were filed. Both the Henleys and the Costas opposed this claim. The court denied the motion and Lyons appealed.
The appeals court upheld the denial, noting that the both California Supreme Court decision and later action by the legislature compels real estate brokers and salespersons “to conduct a reasonably competent and diligent visual inspection of the property offered for sale.” The court noted that under California law, brokers have responsibilities to both sellers and buyers. The section of law cited by Lyons applies to seller’s agents. The court rejected the contention by Lyons that they were “cooperating brokers.” The Henleys were “not constrained by the two-year statute of limitations.”
Lyons contended that even if California’s statute did not apply, there was a contractual limit of two years. The court also rejected this, agreeing with the Henleys that “the two-year limitation period must be extended by the discovery rule.”
The court noted that “Lyon & Associates may not reap the benefit of a shortened contractual limitation period when its own alleged malfeasance contributed to the delay in the discovery of the buyer’s injury.” The court found that the Henleys could proceed with their breach of contract claim, because, “when a breach of contract is committed in secret, such as the intentional nondisclosure of a real estate broker regarding a previously visible construction defect, the contractual limitations period is properly held subject to the discovery rule.” The court felt that the interpretation favored by the California Association of Realtors would “halve the applicable statute of limitations period.”
In addition to rejecting Lyon request for summary judgment on the claims made by the Henleys, the court also rejected the request of summary judgment on the claims made by the Costas, concluding that neither claim is time-barred. Costs were awarded to both the Henleys and Costas.
Read the court’s decision…
Read the court decisionRead the full story...Reprinted courtesy of
