FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Insurance for Large Construction Equipment Such as a Crane

July 30, 2018 — David Adelstein - Florida Construction Legal Updates
Many, many projects require the use of a crane. The skyline is oftentimes filled with the sight of cranes—one after the other. Most of the time, the cranes are leased from an equipment supplier. What happens if the crane (or any large, leased equipment) gets damaged? I wrote an article regarding a builder’s risk carrier NOT covering damage to a crane from a storm based on a common exclusion. Another case, Ajax Bldg. Corp. v. Hartford Fire Ins. Co., 358 F.3d 795 (11th Cir. 2004), had a similar result. In this case, a prime contractor leased a crane from an equipment supplier. The crane was used by the structural concrete subcontractor. The crane collapsed during the subcontractor’s work. The supplier sued both the contractor and subcontractor. The prime contractor was defended under a contractor’s equipment liability policy and the subcontractor was defended under a general liability policy it procured for its work on the project. Ultimately, a settlement was reached where the subcontractor’s liability insurer paid a bulk of the damage. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Construction Litigation Roundup: “Sudden Death”

October 17, 2023 — Daniel Lund III - Lexology
It’s not football, though. Rather, just when you thought it was safe in Louisiana to wait to file a garden-variety construction contract payment claim, an appellate court slams the door on it – applying a statute of “repose” to your claim. “Personal actions” – such as an action on contract – are generally subject in Louisiana to a 10-year “liberative prescription,” the applicable statute of limitations pursuant to Louisiana Civil Code article 3499. Like some other states, Louisiana has a statute of “repose” – imposing “peremption” rather than prescription for claims having to do with construction projects – limiting those claims (generally speaking) to five years post-completion. Like other statutes of “repose,” Louisiana Revised Statute 9:2772 provides that claims on construction projects may not be filed after five years, a duration which is not subject to interruption or extension. Read the court decision
Read the full story...
Reprinted courtesy of Daniel Lund III, Phelps
Mr. Lund may be contacted at daniel.lund@phelps.com

---

Check The Boxes Regarding Contractual Conditions Precedent to Payment

August 21, 2023 — David Adelstein - Florida Construction Legal Updates
Remember this: complying with contractual conditions precedent to payment is important. There is a reason why construction contracts include contractual conditions precedent to payment. The contract does not include this language for sh*ts and giggles. This language is included to establish what is required of the payee before payment becomes due. There may be conditions precedent to the payment of progress payments. There may be conditions precedent to the payment of final payment. Payment is not due until the conditions precedent have been satisfied. Do yourself a favor and consider this language in the construction contract, particularly if a dispute arises. If the condition precedent has not or cannot be satisfied, game plan as to the factual reason. The best thing to do is be prepared – check the boxes regarding conditions precedent to ensure you have considered this contractual language. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

A Third of U.S. Homebuyers Are Bidding Sight Unseen

February 28, 2018 — Noah Buhayar – Bloomberg
Thirty-five percent of homebuyers in the U.S. aren’t even visiting the property before they put in a bid, amid torrid competition in a tight market, according to the latest survey by Redfin Corp. Read the court decision
Read the full story...
Reprinted courtesy of Noah Buhayar, Bloomberg

---

Colorado Supreme Court Issues Decisions on Statute of Limitations for Statutory Bad Faith Claims and the Implied Waiver of Attorney-Client Privilege

July 11, 2018 — Jennifer Arnett-Roehrich - Gordon & Rees Insurance Coverage Law Blog
The Colorado Supreme Court has been busy the past two weeks, issuing a couple rulings that should be of interest to the insurance industry:

Statute of Limitations for Bad Faith Statute: In Rooftop Restoration, Inc. v. American Family Mutual Insurance Co., 2018 CO 44 (May 29, 2018), the Colorado Supreme Court held that the one-year statute of limitations that applies to penalties, does not apply to claims brought under C.R.S. 10-3-1116, Colorado’s statutory cause of action for unreasonable delay or denial of benefits. Section 10-3-1116 provides that a first-party claimant whose claim for payment of benefits has been unreasonably delayed or denied may seek to recover attorney fees, costs, and two times the covered benefit, in addition to the covered benefit. A separate Colorado statute, CRS 13-80-103(1)(d) provides a one-year statute of limitations for “any penalty or forfeiture of any penal statutes.” To arrive at the conclusion that the double damages available under section 10-3-1116 is not a penalty, the Court looked at yet another statutory provision, governing accrual of causes of action for penalties, which provides that a penalty cause of action accrues when “the determination of overpayment or delinquency . . . is no longer subject to appeal.” The Court stated that because a cause of action under 10-3-1116 “never leads to a determination of overpayment or delinquency . . . the claim would never accrue, and the statute of limitations would be rendered meaningless.” Para. 15. Presumably, the default two-year statute of limitations, provided by CRS 13-80-102(1)(i), will now be found to apply to causes of action seeking damages for undue delay or denial of insurance benefits.

Read the court decision
Read the full story...
Reprinted courtesy of Jennifer Arnett-Roehrich, Gordon & Rees Scully Mansukhani
Ms. Arnett-Roehrich may be contacted at jarnett-roehrich@grsm.com

---

There Are Consequences to Executed Documents Such as the Accord and Satisfaction Defense

October 01, 2024 — David Adelstein - Florida Construction Legal Updates
A federal government contractor in Jackson Construction Co., Inc. v. U.S., 62 Fed.Cl. 84 (Fed.Cl. 2024) sought delay damages against the government. It lost. The reason for the loss is a crucial reminder that documents parties sign ALWAYS matter. ALWAYS!! In Jackson Construction Co., the contractor’s delay claim was premised on relocating a waterline. The contractor, however, received additional money for relocating the waterline, but no additional time, and this was memorialized in a modification to the contract (i.e., a change order). In executing the modification for the additional work, the contractor did NOT reserve rights for time or money. Indeed, the modification reflected that the monetary adjustment constitutes full compensation for the additional work including delay, namely:

The contract period of performance remains the same. It is further understood and agreed that this adjustment constitutes compensation in full on behalf of the contractor and his subcontractors and suppliers for all costs and markup directly or indirectly, including extended overhead, attributable to the change order, for all delays related thereto, and for performance of the change within the time frame stated.

Jackson Construction Co., supra, at 90.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Hurricane Harvey Victims Face New Hurdles In Pursuing Coverage

September 07, 2017 — Tred R. Eyerly - Insurance Law Hawaii
Just as Hurricane Harvey departs the state, a new law in Texas, effective September 1, 2017, is going to make it more difficult for home and business owners to pursue claims against their insurance companies. Prior Texas law imposed liability on an insurer who violated the Insurance Code for the amount of the claim, interest on the amount of the claim at an annual interest rate of 18 percent, and reasonable attorney fees. H.B. 1774 was recently enacted to address legal actions for claims arising from damage to or loss of property due to hailstorms, lightening, wind, hurricane, rainstorm and other natural events. The bill creates additional procedural hurdles before a policy holder can file a lawsuit against the insurer. A written notice must be provided to the insurer at least 61 days before filing a lawsuit. The notice must include a statement of the acts giving rise to the claim, the specific amount alleged to be owed, and amount of reasonable and necessary attorney's fees already incurred by the policy holder. Once notice is received, the statute allows the insurers to send a written request to inspect, photograph, or evaluate the property. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly - Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Presidential Memorandum Promotes Reliable Supply and Delivery of Water in the West

November 14, 2018 — Anthony B. Cavender - Gravel2Gavel
In a Memorandum dated October 19, 2018 and entitled Promoting the Reliable Supply and Delivery of Water in the West, the President has directed the Secretaries of the Interior and Commerce to work together to minimize “unnecessary regulatory burdens and foster more efficient decision-making” so that major federal water projects are constructed and operated in a manner that delivers water and power in an “efficient, cost-effective way.” More specifically, they will take steps to streamline the western water infrastructure regulatory processes and remove unnecessary burdens in accordance with the timetables set forth in the Memorandum. Read the court decision
Read the full story...
Reprinted courtesy of Anthony B. Cavender, Pillsbury
Mr. Cavender may be contacted at anthony.cavender@pillsburylaw.com

---