Seattle Washington Building Expert Directory

Formal Request for Time Extension Not Always Required to Support Constructive Acceleration

April 25, 2022 — David Adelstein - Florida Construction Legal Updates
Does a constructive acceleration claim require the contractor to always request an extension of time which is then denied by the owner? While this is certainly the preference and the contractor should be requesting an extension of time as a matter of course for an excusable delay, the answer is NO! in certain circumstances. This is conveyed in the factually detailed case discussed below where a formal request for an extension of time was not required for the contractor to support its constructive acceleration claim. But first, what is constructive acceleration: Constructive acceleration “occurs when the government demands compliance with an original contract deadline, despite excusable delay by the contractor.” The Federal Circuit in Fraser defined the elements of constructive acceleration as follows: (1) that the contractor encountered a delay that is excusable under the contract; (2) that the contractor made a timely and sufficient request for an extension of the contract schedule; (3) that the government denied the contractor’s request for an extension or failed to act on it within a reasonable time; (4) that the government insisted on completion of the contract within a period shorter than the period to which the contractor would be entitled by taking into account the period of excusable delay, after which the contractor notified the government that it regarded the alleged order to accelerate as a constructive change in the contract; and (5) that the contractor was required to expend extra resources to compensate for the lost time and remain on schedule. Nova Group/Tutor-Saliba v. U.S., 2022 WL 815826, *42 (Fed.Cl. 2022) quoting Fraser Constr. Co. v. U.S., 384 F.3d 1354, 1361 (Fed. Cir. 2004) (internal citations omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Legislative Update: Bid Protest Law Changes to Benefit Contractors

November 24, 2019 — Brett M. Hill - Ahlers Cressman & Sleight PLLC
A new statute became effective July 28, 2019 that benefits contractors who have bid protests in Washington. A bid protest is the only way for disappointed bidders to challenge irregularities in the public bidding process on public works projects. Bid protests ensure the integrity of the public bidding system and are the contractor’s only remedy if its bid is improperly rejected or the winning bidder has errors in its bid that render it nonresponsive. Under the old law, a contractor was required to submit their bid protest within 2 days after the bid opening. The problem was that a contractor often does not know the basis to protest an award without seeing the other bids to determine whether the winning bid was responsive. Many owners provide copies of the bids if requested at the bid opening, but some contractors found that owners were refusing to provide copies of the other bids until after the 2-day protest period expired. The new law, which passed this last Legislative session[1], states that a contractor has two days after the bid opening to either submit a written protest or request copies of the competing bids. If the contractor requests copies of the competing bids from the owner, the contractor then has until 2 days after the competing bids are provided by the owner before the contractor is required to submit its bid protest. Read the court decision
Read the full story...
Reprinted courtesy of Brett M. Hill, Ahlers Cressman Sleight PLLC
Mr. Hill may be contacted at brett.hill@acslawyers.com

Fire Fears After Grenfell Disaster Set Back Wood Building in UK

May 29, 2023 — Olivia Rudgard - Bloomberg
This article is part of the Bloomberg Green series Timber Town, which looks at the global rise of timber as a low-carbon building material. To get fire department approval for their six-story London office project made of strong engineered wood known as mass timber, Theo Michell and Richard Walker had to build a full-scale section of it in the UK, ship it to Poland and attempt to set it on fire. The mockup was set alight “with enough material that replicates the fire load that you get from furniture and carpets and desks, and all the rest of it, and you see how that structure performs,” says Michell. “It was cool,” adds Walker. “It looked amazing.” Their building, called Paradise, passed the fire test and is under construction, though not without a significant drag on their budget and time. Read the court decision
Read the full story...
Reprinted courtesy of Olivia Rudgard, Bloomberg

Citigroup Reaches $1.13 Billion Pact Over Mortgage Bonds

April 09, 2014 — Dakin Campbell – Bloomberg
Citigroup Inc. (C) agreed to pay $1.13 billion to settle claims from mortgage-bond investors as it seeks to curb liabilities tied to the financial crisis. It took a $100 million first-quarter charge. The 68 securitization trusts covered by the settlement issued a combined $59.4 billion in mortgage-backed securities from 2005 to 2008, the New York-based bank said yesterday in a statement. The agreement covers 18 investors represented by Gibbs & Bruns LLP and trustees have until June 30 to accept the deal, the law firm said in a separate statement. The accord must be approved by the Federal Housing Finance Agency. Citigroup, the third-biggest U.S. bank, is resolving a portion of liabilities tied to mortgages it packaged and sold to investors in the run-up to the 2008 crisis. JPMorgan Chase & Co. (JPM) and Bank of America Corp. (BAC), the two largest U.S. lenders, previously agreed to multibillion-dollar settlements with Gibbs & Bruns clients. Read the court decision
Read the full story...
Reprinted courtesy of Dakin Campbell, Bloomberg
Mr. Campbell may be contacted at dcampbell27@bloomberg.net

Toll Brothers Snags Home Builder of the Year Honors at HLS

May 13, 2014 — Beverley BevenFlorez-CDJ STAFF
Builder magazine named Toll Brothers as their Builder of the Year during their Housing Leadership Summit in Laguna Niguel, California, according to Big Builder: “The Builder of the Year, BUILDER’s highest honor each year, is recognized for its excellence in successful business strategy, its achievements, and its corporate leadership.” “The company’s up-market price-point, lifestyle segmentation positions, and its best-of-breed execution set it apart from competitors in production home building and development as one of housing’s most powerful and promising brands,” BUILDER editorial director John McManus said while presenting the award, as quoted by Big Builder. “Toll Brothers one day will be a globally recognizable luxury housing and hospitality trademark along the lines of Four Seasons or Ritz-Carlton.” Read the court decision
Read the full story...
Reprinted courtesy of

Earthquake Hits Mid-Atlantic Region; No Immediate Damage Reports

November 30, 2017 — The Associated Press (Randall Chase) - Bloomberg
Dover, Del. (AP) -- An earthquake has jolted the Mid-Atlantic region of the East Coast, but there are no immediate reports of damage or injuries. The U.S. Geological Survey says the 4.1 magnitude quake struck just after 4:45 p.m. Thursday, and was centered about 6 miles (10 kilometers) east-northeast of Dover, Delaware. It was felt as far away as Baltimore. Read the court decision
Read the full story...
Reprinted courtesy of The Associated Press (Randall Chase), Bloomberg

The Privilege Is All Mine: California Appellate Court Finds Law Firm Holds Attorney Work Product Privilege Applicable to Documents Created by Formerly Employed Attorney

June 29, 2017 — David W. Evans & Stephen J. Squillario – Haight Brown & Bonesteel LLP
In Tucker Ellis LLP v. Superior Court (A148956 – Filed 6/21/2017), the First Appellate District held that (1) the holder of the attorney work product privilege is the employer law firm rather than the former employee attorney who created the privileged documents while a firm employee, and (2) as a result, the firm did not owe a duty to obtain the former attorney’s permission before disclosing the subject documents to third parties. In Tucker Ellis LLP, the attorney, while still employed by Tucker Ellis, exchanged a series of e-mails with a consultant retained by the firm to assist in asbestos litigation for a client. The firm also entered into an agreement with the consultant to summarize scientific studies on the causes of mesothelioma in a published review article. After the attorney departed the firm, Tucker Ellis was served with a subpoena in connection with a matter pending in Kentucky for the production of communications with the consultant regarding the article. In response, Tucker Ellis, in relevant part, produced the work product e-mails authored by the former attorney. The e-mails eventually ended up on the Internet and reached over 50 asbestos plaintiffs’ attorneys, resulting in the attorney’s termination from his new firm. After Tucker Ellis ignored the attorney’s “claw-back” letter, he filed suit against the firm for negligence, among other causes of action. The trial court granted the former attorney’s motion for summary adjudication on the issue of duty, reasoning that the firm owed the attorney a legal duty to prevent the disclosure of the work product. Tucker Ellis filed a petition for a writ of mandate with the Court of Appeal challenging the trial court’s decision on the duty issue. Reprinted courtesy of David W. Evans, Haight Brown & Bonesteel LLP and Stephen J. Squillario, Haight Brown & Bonesteel LLP Mr. Evans may be contacted at devans@hbblaw.com Mr. Squillario may be contacted at ssquillario@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

The Economic Loss Rule and the Disclosure of Latent Defects: In re the Estate of Carol S. Gattis

January 15, 2014 — Brady Iandiorio - Higgins, Hopkins, McLain & Roswell, LLC
In a recent case of first impression, the Colorado Court of Appeals determined that the economic loss rule does not bar a nondisclosure tort claim against a seller of a home, built on expansive soils which caused damage to the house after the sale. The case of In re the Estate of Carol S. Gattis represents a new decision regarding the economic loss rule. Because it is a case of first impression, we must wait to see whether the Colorado Supreme Court grants a petition for certiorari. Until then, we will analyze the decision handed down on November 7, 2013. The sellers of the home sold it to an entity they controlled for the purpose of repairing and reselling the home. Before that purchase, Sellers obtained engineering reports including discussion of structural problems resulting from expansive soils. A structural repair entity, also controlled by Sellers, oversaw the needed repair work. After the repair work was completed, Sellers obtained title to the residence and listed it for sale. Sellers had no direct contact with Gattis, who purchased the residence from Sellers. The purchase was executed through a standard-form real estate contract, approved by the Colorado Real Estate Commission: Contract to Buy and Sell Real Estate, to which no changes were made. Several years after taking title to the residence, Gattis commenced action, pleading several tort claims alleging only economic losses based on damage to the residence resulting from expansive soils. Read the court decision
Read the full story...
Reprinted courtesy of Brady Iandiorio, Higgins, Hopkins, McLain & Roswell, LLC
Mr. Iandiorio may be contacted at iandiorio@hhmrlaw.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES