Seattle Washington Building Expert Directory

Default, Fraud, and VCPA (Oh My!)

September 12, 2023 — Christopher G. Hill - Construction Law Musings
I’ve discussed the Virginia Consumer Protection Act (VCPA) and the interaction between fraud and contract on numerous occasions here at Construction Law Musings. A recent case from the Eastern District of Virginia District Court discusses this interaction (along with that dreaded default) further. In Bhutta v. DRM Construction Corp., the homeowners, the Bhuttas, sued DRM for breach of contract, conversion, fraud, and a violation of the VCPA. These allegations were based upon DRM having taken a $40,000.00 deposit from the Bhuttas and then failing to even begin work. As you may have guessed from the title of this post, DRM did not respond to the Complaint and the Court granted default. The Court then took up the question of whether the Bhuttas had alleged enough on each count for default judgment on those counts. After going through a procedural recitation and finding that DRM was properly served and that the Court had jurisdiction, the Court got to the meat of the matter. The Court held that the Bhuttas properly plead a breach of contract for the obvious reason. The reason was that DRM never performed any work and the Bhuttas were damaged because they both paid the deposit and also had to hire another contractor to complete the work at a higher price. The Court granted default judgment for breach of contract. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Ohio Condo Development Case Filed in 2011 is Scheduled for Trial

April 09, 2014 — Beverley BevenFlorez-CDJ STAFF
In a recent hearing regarding the Cleveland, Ohio case Stonebridge Towers Homeowners v K&D Group, Judge John O’Donnell scheduled a trial for May 28th. Lead attorney for the homeowners stated that they would settle for “ten million and change,” according to The Plain Dealer. However, an attorney for K&D Group retorted that “the damaged condos could be fixed for much less money.” “The lawsuit claims negligent design, poor construction and multiple defects resulted from fraud and bribe-paying by the developers,” reported Plain Dealer. Read the court decision
Read the full story...
Reprinted courtesy of

Payment Bond Claim Notice Requires More than Mailing

August 04, 2015 — Christopher G. Hill – Construction Law Musings
It’s been a while since I posted something new relating to Virginia’s “Little Miller Act” and its various notice requirements for a subcontractor to make a payment bond claim. I have posted on the basics of a Virginia payment bond claim previously here at Musings. One of these basics is the 90 day notice requirement for suppliers or second tier subcontractors with no direct contractual relationship to the general contractor. A recent case from the Norfolk, Virginia Circuit Court examined when notice is “given” under the Little Miller Act. In R T Atkinson Building Corp v Archer Western Construction, LLC the Court looked at the question of whether mailing of the notice of claim is enough to constitute notice being “given” in a manner that would satisfy the statutory requirements. In that case, the supplier mailed the notice within the 90 day window, but the defendant argued on summary judgment that it did not receive the notice until 2 days after the 90 day window had closed. In support of this contention, the defendant provided tracking information showing delivery by the USPS on the non-compliant date. Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, Law Office of Christopher G. Hill, PC
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Differing Site Conditions: What to Expect from the Court When You Encounter the Unexpected

September 05, 2022 — Margarita Kutsin - Ahlers Cressman & Sleight
[1]Seattle Tunnel Partners (“STP”), a joint venture of Dragados USA and Tutor Perini, entered into a $1.4 billion contract with the Washington State Department of Transportation (“WSDOT”) to replace the Highway 99 viaduct. In December 2013, a tunnel boring machine (“TBM”) bearing the moniker “Bertha,” then the largest TBM ever built, measuring 425 feet long and 57 feet in diameter, struck an underground pipe. Shortly after the impact, Bertha overheated and eventually could no longer make forward progress. A massive repair effort ensued causing a 2.5-year delay in reaching substantial completion. WSDOT sued STP for the delay, seeking liquidated damages of $57 million. In response, STP argued its delay was excusable because it was caused by Bertha’s impact with the pipe, and the steel well casing was a Differing Site Condition (DSC) undisclosed in the contract documents. STP asserted counterclaims against WSDOT, alleging breach of contract and seeking $300 million in damages. Ultimately, a jury found that the steel well casing on the pipe was not a DSC, foreclosing STP’s excusable delay defense and counterclaims, and resulting in a $57 million verdict, plus interest, in favor of WSDOT. Read the court decision
Read the full story...
Reprinted courtesy of Margarita Kutsin, Ahlers Cressman & Sleight
Ms. Kutsin may be contacted at margarita.kutsin@acslawyers.com

Solicitor General’s Views to Supreme Court on Two Circuit Court Rulings that Groundwater Can be Considered “Waters of the United States”

March 04, 2019 — Anthony B. Cavender - Gravel2Gavel
On December 3, 2018, the U.S. Supreme Court invited the Solicitor’s views on the contested issues whether discharges to groundwater are subject to an he National Pollutant Discharge Elimination System (NPDES) permit, and whether there is an “ongoing violation” of the Clean Water Act for Citizen Suit jurisdiction when the source of the pipeline spill has been fixed, yet not all pollutants have been cleaned up. Read the court decision
Read the full story...
Reprinted courtesy of Anthony B. Cavender, Pillsbury
Mr. Cavender may be contacted at anthony.cavender@pillsburylaw.com

Soldiers Turn Brickies as U.K. Homebuilders Seek Workers

May 20, 2015 — Neil Callanan – Bloomberg
After 21 years in the British Army that included tours of duty in Afghanistan and Iraq, Ross Wilson was offered a buyout. Britain’s shortage of construction workers allowed him to trade desert sand for muddy building sites in the north of England. Wilson, 38, is working as an apprentice bricklayer for homebuilder Persimmon Plc, which will train more than 300 former soldiers this year because of the country’s shortage of skilled workers. The government formed after next month’s national election will have to urgently address the lack of new homes, according to the Royal Institution of Chartered Surveyors. Persimmon’s Combat to Construction program is the latest effort by the industry to increase output as the shortage sends asking prices to record highs. Read the court decision
Read the full story...
Reprinted courtesy of Neil Callanan, Bloomberg

Property Damage, Occurrences, Delays, Offsets and Fees. California Decision is a Smorgasbord of Construction Insurance Issues

November 15, 2017 — Garret Murai - California Construction Law Blog
I read once that 97 percent of cases never go to trial. However, there are still the ones that do. And, then, there are the ones that do both. The following case, Global Modular, Inc. v. Kadena Pacific, Inc., California Court of Appeals for the Fourth District, Case No. E063551 (September 8, 2017), highlights some of the issues that can arise when portions of cases settle and other portions go to trial, the recovery of delay damages on a construction project through insurance, and the recovery of attorneys’ fees. Global Modular, Inc. v. Kadena Pacific, Inc. The U.S. Department of Veterans Affairs contracted with general contractor Kadena Pacific, Inc. (Kadena) to oversee construction of its Center for Blind Rehabilitation in Menlo Park, California. Kadena, in turn, contracted with subcontractor Global Modular, Inc. (Global) to construct, deliver and install 53 modular units totaling more than 37,000 square feet for a contract price of approximately $3.5 million. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

Policy Language Matters: New Jersey Court Bars Cleanup Coverage Under Broad Policy Terms

May 15, 2023 — Stacy M. Manobianca - Saxe Doernberger & Vita, P.C.
The New Jersey Appellate Division in Handy & Harman v. Beazley USA Services, Inc., provided clarity regarding the interpretation of the Prior or Pending Litigation Exclusion in a site-specific environmental liability insurance policy. In Handy & Harman, the Appellate Division affirmed the trial court’s determination that the insurer was not required to defend or indemnify its policyholder, a metal etching company. The court held that the Prior or Pending Litigation Exclusion (which applied to prior litigation and prior claims) barred coverage for natural resource damages sought in the current litigation because (1) an Administrative Consent Order (“ACO”) is a claim; and (2) the underlying lawsuit was based on the same environmental contamination as addressed in the ACO.1 Read the court decision
Read the full story...
Reprinted courtesy of Stacy M. Manobianca, Saxe Doernberger & Vita, P.C.
Ms. Manobianca may be contacted at SManobianca@sdvlaw.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES