There Are Consequences to Executed Documents Such as the Accord and Satisfaction Defense
October 01, 2024 —
David Adelstein - Florida Construction Legal UpdatesA federal government contractor in Jackson Construction Co., Inc. v. U.S., 62 Fed.Cl. 84 (Fed.Cl. 2024) sought delay damages against the government. It lost. The reason for the loss is a crucial reminder that documents parties sign ALWAYS matter. ALWAYS!!
In Jackson Construction Co., the contractor’s delay claim was premised on relocating a waterline. The contractor, however, received additional money for relocating the waterline, but no additional time, and this was memorialized in a modification to the contract (i.e., a change order). In executing the modification for the additional work, the contractor did NOT reserve rights for time or money. Indeed, the modification reflected that the monetary adjustment constitutes full compensation for the additional work including delay, namely:
The contract period of performance remains the same. It is further understood and agreed that this adjustment constitutes compensation in full on behalf of the contractor and his subcontractors and suppliers for all costs and markup directly or indirectly, including extended overhead, attributable to the change order, for all delays related thereto, and for performance of the change within the time frame stated.
Jackson Construction Co., supra, at 90.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Business Risk Exclusions Bar Coverage for Construction Defect Claims
June 28, 2013 —
Tred EyerlyThe federal district court assumed there was "property damage" caused by an "occurrence," but found the business risk exclusions barred coverage for construction defect claims. Hubbell v. Carney Bros. Constr., 2013 U.S. Dist. LEXIS 68331 (D. Colo. May 13, 2013).
The plaintiffs entered a construction contract with the insured general contractor to build a home. After the project was one-third completed, plaintiffs terminated the contract. Experts hired by plaintiffs found a failure to properly site the residence, as the house was constructed 48 feet from the intended location; violations of county height restrictions; failure to follow building plans, which were themselves deficient; and an improperly poured foundation. The experts estimated that the costs of repairing the property to be between $1.3 and $1.5 million, and that the cost of demolishing the structure and rebuilding it would be between $1.1 and $1.3 million.
After plaintiff filed suit, a stipulated judgment of $1.952 million was entered.
Read the court decisionRead the full story...Reprinted courtesy of
Tred EyerlyTred Eyerly can be contacted at
te@hawaiilawyer.com
Construction Activity on the Upswing
October 25, 2013 —
CDJ STAFFConstruction industry experts are now predicting that not only will 2013 be a growth year for construction, but that the industry will continue to grow through 2015. Predictions at the recent webinar, “The 2014 Outlook: Emerging Opportunities for Construction,” included that growth in the housing market will endure, commercial construction will improve, and that overall construction spending will increase.
This is in the face of what Bernard Markstein, the chief economist at Reed Construction Data, calls “barely acceptable” economic growth. Mr. Markstein also feels that the government shutdown will have an effect on growth of the gross domestic product.
One area of construction that is not expected to do well in the short term is retail. The economists noted that more shoppers are turning to online buying. Need for office space is also shrinking. Despite this, the group projected “high-single-digit growth” through 2014.
Read the court decisionRead the full story...Reprinted courtesy of
Supreme Court’s New York Harbor Case Isn’t a ‘Sopranos’ Episode
August 03, 2022 —
Stephen L. Carter - BloombergThe long-simmering harbor dispute between New York and New Jersey has observers reaching for illustrations from “The Sopranos” and “On the Waterfront.” But now that the US Supreme Court has agreed to adjudicate the spat, I wonder whether a more useful resource might be “The Paper Chase.”
The disagreement stems from New Jersey’s determination to exit the Waterfront Commission of New York Harbor, an entity established by the two states back in 1953 in response to news reports of widespread corruption and violence among those who loaded and unloaded ships. New Jersey argues that as a sovereign state, it can’t be forced to remain in the pact forever. New York replies that the deal has the force of law and neither state can quit without the permission of the other. (And Congress!)
The Supreme Court is now involved because that’s the venue the Constitution prescribes when one state sues another. Four days before New Jersey’s announced departure date of March 28, the justices issued an injunction preventing the move. This week they agreed to adjudicate the dispute and set an accelerated schedule for briefs and oral argument.
Read the court decisionRead the full story...Reprinted courtesy of
Stephen L. Carter, Bloomberg
Before Celebrating the Market Rebound, Builders Need to Read the Fine Print: New Changes in Construction Law Coming Out of the Recession
November 26, 2014 —
Alan H. Packer - Newmeyer & Dillion, LLPAs the homebuilding market continues to improve, many builders find themselves maneuvering familiar roads. That said, important new realities have taken hold since the market collapse. Navigating these changes requires extra thought for practical and legal reasons.
Using Old Designs “Off the Shelf”?
The adoption of the California Building Standards Code in 2010, with an updated schedule to go into effect January 1, may complicate the use of older designs. In addition, some builders are contemplating building on pads constructed five or more years ago, temporarily shelved until market conditions improved. Because of changes in both the applicable Code and due to possible changes in the underlying soils and drainage, these projects require additional scrutiny before starting construction.
Mechanic’s Lien Law Changes
Not too long ago, the California Legislature recently overhauled the entire mechanic’s lien law system in California. New forms, new statutory references, new rules and deadlines are all applicable to projects under construction now. Make sure your documents are up to date, as the use of older forms (particularly for liens, progress payments, and final payments) could create legal problems in the future.
Indemnity Law Changes
Since 2006, California lawmakers have passed four rounds of legislation aimed at limiting indemnity provisions in construction contracts. The laws are aimed at two aspects of indemnity law: “Type 1” indemnity provisions, and liability for the costs of defending a claim.
Type 1 Indemnity. California law previously permitted a builder to obtain “Type 1” indemnity from its subcontractors for all claims. Under a Type 1 provision, if a claim arose out of the trade’s work, the trade was fully responsible to defend and indemnify the builder – even if other trades or the Builder were partially at fault. Some cases even allowed, typically in a commercial context, the builder to obtain Type 1 indemnity even if the trade was not negligent, as long as the claim involved its work.
Defense Obligation. In 2008, California’s highest court issued an opinion in Crawford v. Weather Shield, evaluating an indemnity provision requiring trade (a window supplier/manufacturer) to defend the builder in claims involving allegations of damages arising out of the trade’s work. Because the trade had contractually agreed to defend the builder, the Court held it responsible for the builder’s defense costs -- even though, ultimately, the trade was found
not liable for the actual damages claimed.
Recent legislation after Crawford has dramatically shifted how indemnity provisions will be enforced. Builders may no longer obtain Type 1 indemnity for residential construction defect claims covered by SB800; instead, indemnity is limited to the extent a claim arises out of the trade’s work. Even more recent legislation applied these changes to claims arising out of commercial construction projects. The recent legislation allows the trades “options” on how to defend the builder, with an eye toward requiring that they pay only a “reasonably allocated” portion for the builder’s defense costs.
Smart builders are refining their contract documents to take into account these new limitations on indemnity provisions.
Insurance Market Changes
Due to uncertainties in subcontractor insurance and other factors, many builders have also converted their liability insurance from a “bring your own” model to “wrap-up” insurance, where the builder’s policy also covers their trades. Builders should carefully examine their subcontracts in light of this change as well.
Trade Partner Changes
On a practical level, many trade partners, particularly in the residential sector, have gone out of business or moved on to greener pastures. Builders need to find and negotiate contracts with new trade partners on the fly, and educate them on the builders’ procedures for payment and construction.
SB800 documentation
A decade ago, most builders updated their purchase documents and subcontracts for California’s “Right to Repair Law” (also known as SB800), which set forth functionality standards for construction defects in residential housing, and procedures for resolving claims prior to litigation. Builders ramping up to meet market demand should examine how they implemented SB800 changes in contract documents. Issues to consider:
- Whether to opt out of -- or back into -- statutory procedures.
- Whether to include arbitration or judicial reference provisions to control where claims are litigated after the SB800 process.
- Re-training personnel to preserve SB800 rights, including sign-offs on purchase documentation and recordation of key documents.
- Recent Court of Appeal decisions have complicated the SB800 landscape, potentially opening the door to “common law” tort claims in at least subrogation contexts. Strategic planning at the document stage may be a good way to mitigate this risk as the cases wind their way through the judicial process.
The continuing surge in building activity is a welcome sign for builders who have weathered the storm. Before taking too many steps, builders should consult with counsel, their designers, and their insurance advisors to take into account the new realities of this recovering housing market.
About the Author
Alan H. Packer is a partner in the expanding Walnut Creek, CA, office of the law firm of
Newmeyer & Dillion LLP whose specialties include real estate, insurance, and construction litigation. To reach Alan, call 925.988.3200 or email him at alan.packer@ndlf.com.
Read the court decisionRead the full story...Reprinted courtesy of
Big Policyholder Win in Michigan
January 05, 2017 —
Jeremiah M. Welch – Saxe Doernberger & Vita, P.C.Jeremiah Welch and
Michael Barrese recently had a big win in front of the Michigan Court of Appeals.
The case (Skanska-Schweitzer v. Farm Bureau General Insurance Company of Michigan) involved Skanska’s claim for defense and indemnity from Farm Bureau Ins. Co. of Michigan for an injury to an elementary school student arising out of the removal of playground equipment by a landscaping company, Horrocks. Farm Bureau denied coverage because it claimed that the work was not part of Horrocks’ contract with the project owner and therefore Skanska, the construction manager, did not qualify as an additional insured on the policy.
SDV argued that the AI endorsement did not specify that Horrocks’ work be performed as part of its contract with the owner; it only required that the work be performed “for Skanska.”
Read the court decisionRead the full story...Reprinted courtesy of
Jeremiah M. Welch, Saxe Doernberger & Vita, P.C.Mr. Welch may be contacted at
jmw@sdvlaw.com
My Top 5 Innovations for Greater Efficiency, Sustainability & Quality
October 25, 2020 —
Cristina Savian - AEC BusinessAs a construction professional and British citizen, I genuinely could not have been any prouder and humbled to have opened UK Construction Week Virtual last week.
2020 is the year of disruptions, and we are all looking for this “New Normal”, and while this newfound regularity may have opened new opportunities, as we are now broadcasting to a much wider audience than previous in-person events, and indeed we have to thank technology for that. For us construction professionals, this pandemic has put our industry further under pressure, however, it has also taught us something extremely important. The pandemic has shown the world how vital the construction industry is. The world cannot function without it. This new extraordinary experience has given us the prospect to turn our industry around and transform it into one of the most productive industries in our society.
How are we going to do it? I think you can guess what I am about to say, of course by leveraging technology! The panel discussion with leading construction experts across the UK with representatives from Skanska UK, Bryden Wood, and Innovate UK, focused on our top 5 innovations for greater efficiency, sustainability and quality in construction. Here are my top 5.
Read the court decisionRead the full story...Reprinted courtesy of
Cristina Savian, AEC Business
Coverage for Construction Defects Barred by Business Risk Exclusions
September 01, 2011 —
Tred R. Eyerly - Insurance Law HawaiiAlthough the court determined there was an occurrence, coverage was excluded by the business risk exclusions. See Cont’l W. Ins. Co. v. Shay Constr. Co., 2011 U.S. Dist. LEXIS 82839 (D. Colo. July 28, 2011).
White was the general contractor on the project. White had three subcontracts with Shay to provide framing, siding, and related work on the project. Shay was insured under a CGL policy issued by Continental Western.
Two of Shay’s subcontractors furnished materials, labor and equipment to Shay. These subcontractors filed suit in state court alleging they had not been compensated for the work and materials. White and Shay were named as defendants. White cross claimed against Shay, alleging Shay had breached its obligations under the subcontracts. Several allegations sounded in contract. Other allegations, however, contended Shay had performed defective work and had damaged the work of other trades in correcting deficiencies in its own performance.
Shay sought coverage under Continental Western’s policy. Continental Western filed suit for a declaratory judgment and moved for summary judgment.
Read the full story…
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii. Mr. Eyerly can be contacted at te@hawaiilawyer.com
Read the court decisionRead the full story...Reprinted courtesy of
