Fairfield Connecticut Building Expert Directory

COVID-19 Damages and Time Recovery: Contract Checklist and Analysis

April 27, 2020 — Patrick J. Greene, Jr. - Peckar & Abramson
This Alert explores the contract provisions and related rights that are likely to govern time and compensation adjustments for COVID-19 impacts. As parties begin analyzing such rights, this is intended to serve as a useful guide and checklist. Analysis of relevant contract provisions should start with careful consideration of the specific impacts that have been experienced and the causes of those impacts. The nature of the impact (delay, extra work, disruption, etc.) and the causes of such impacts (owner direction, government order, etc.) will generally govern the analysis and resulting course of action. Listing or creating a matrix of impacts and their causes may be an effective working tool. Essentially, there are five primary impacts that will likely require critical analysis under the relevant contract provisions, and notably, more than one impact may be present: a) complete or partial suspension of work, b) additional work or requirements, c) added cost, d) delay, and e) disruption. Read the court decision
Read the full story...
Reprinted courtesy of Patrick J. Greene, Jr., Peckar & Abramson
Mr. Greene may be contacted at pgreene@pecklaw.com

Pending Home Sales in U.S. Increase Less Than Forecast

October 29, 2014 — Michelle Jamrisko – Bloomberg
The number of contracts to buy existing homes rose less than forecast in September, signaling demand will probably plateau heading into the end of 2014. The pending home sales index increased 0.3 percent after dropping 1 percent in August, the National Association of Realtors said today in Washington. The median projection in a Bloomberg survey of economists called for a 1 percent gain. Home resales have yet to regain last year’s peak as still-tight credit and low inventories remain hurdles for the industry, which means residential real estate will make a limited contribution to the expansion. The recent drop in mortgage rates and pickup in hiring will probably help underpin demand, even as first-time buyers struggle to enter the market. Read the court decision
Read the full story...
Reprinted courtesy of Michelle Jamrisko, Bloomberg
Ms. Jamrisko may be contacted at mjamrisko@bloomberg.net

CISA Clarifies – Construction is Part of Critical Infrastructure Activities

April 20, 2020 — Brenda Radmacher & Ernest Isola - Gordon & Rees Construction Law Blog
After ongoing confusion by many over whether construction should be considered part of the “essential business,” during the COVID-19 pandemic, the Cybersecurity and Infrastructure Security Agency (CISA) issued an updated Coronavirus Guidance for America on March 28, 2020 to clarify construction’s critical role in supporting essential infrastructure. CISA’s initial advisory list referenced construction in regard to some areas such as energy and wastewater treatment, but it was unclear as to the whole of the construction industry. CISA’s update clarified that construction activities are included in its list of essential critical infrastructure workers. This new federal guidance should remove the ambiguity that led to varying responses by state and local officials halting some construction. The guidance clarifies that construction and related activities – including the manufacture and supply/delivery of supplies and equipment, permitting, safety, and inspections of projects – are covered as part of the critical infrastructure and economic activities. The ongoing challenge will be for construction activities to proceed in a way that protects workers and the general public from the spread of coronavirus. However, contractors are always resourceful and have been implementing safety measures effectively on projects with an unwavering commitment to safety and are ready to meet this challenge. In addition to following the guidance from the CDC, we recommend that contractors implement a comprehensive safety program for their employees as well as for all parties that come onto the jobsite. It is critical that contractors have clear a clear plan for communications with their teams to ensure compliance with the CDC recommendations. This should include what has recently become standard protocol or social distancing, not hosting large group meetings and conducting meetings online or via conference call, maintaining a six-foot distance between people, discouraging hand-shaking or other contact, not sharing tools, and sanitizing reusable PPE. Contractors also should also be sure to place safety posters about “How to Protect Yourself” where they can be readily seen and encourage staying home when sick, cough and sneeze etiquette, and hand hygiene at the entrance of a jobsite. We also recommend heightened site security including interviewing anyone coming to the jobsite. Reprinted courtesy of Brenda Radmacher, Gordon & Rees and Ernest Isola, Gordon & Rees Ms. Radmacher may be contacted at bradmacher@grsm.com Mr. Isola may be contacted at eisola@grsm.com Read the court decision
Read the full story...
Reprinted courtesy of

California Case Is a Reminder That Not All Insurance Policies Are Alike Regarding COVID-19 Losses

April 05, 2021 — Neal I. Sklar & Joshua A. Morehouse - Peckar & Abramson, P.C.
A recent case from the Central District of California reminds us that not all insurance policies are alike. Depending on the particular policy, losses from the COVID-19 outbreak could qualify as property damage and therefore could be recoverable under an all-risk insurance policy. COVID-19 has in many cases imposed significant costs on contractors, and in a host of ways. Contractors’ attempts to recover these costs from owners or insurers have at times been frustrated by contractual or policy language written after a lengthy time, during which the risk of a pandemic on the scale of COVID-19 was not as much of a concern as it is now. This has led contractors to explore new, often creative legal theories in their attempts to recover costs flowing from COVID-19. A recent Complaint filed in the Central District of California focuses on all-risk property insurance policies and the potential for contractors who have purchased such policies to classify contamination from COVID-19 as an insurable property loss. In AECOM v. Zurich Insurance Company, Case No. 2:21-cv-00237-JAK-MRW (C.D. Cal), a contractor purchased “all-risk” property insurance from Zurich. This policy covered “economic losses from all risks not expressly excluded.” According to the Complaint, the presence of COVID-19 on its properties “physically alter[ed] air, airspace, and surfaces preventing… (the contractor) from using its properties for their intended purpose and function.” Reprinted courtesy of Neal I. Sklar, Peckar & Abramson, P.C. and Joshua A. Morehouse, Peckar & Abramson, P.C. Mr. Sklar may be contacted at nsklar@pecklaw.com Mr. Morehouse may be contacted at jmorehouse@pecklaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Several Wilke Fleury Attorneys Featured in Sacramento Magazine’s 2023 Top Lawyers!

October 30, 2023 — Wilke Fleury LLP
Wilke Fleury is extremely proud of its incredibly talented attorneys! Congratulations to Steven Williamson, Islam Ahmad, Matthew Powell, Adriana Cervantes, Daniel Foster, Neal Lutterman, Aaron Claxton, George Guthrie, Trevor Stapleton, David Frenznick, Michael Polis, Daniel Egan, and Stephen Marmaduke, who are all featured in Sacramento Magazine’s 2023 List of Top Lawyers! Reprinted courtesy of Wilke Fleury LLP Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

BHA has a Nice Swing Benefits the Wounded Warrior Project

May 20, 2015 — Beverley BevenFlorez-CDJ STAFF
Bert L. Howe & Associates (BHA) would like to congratulate the winners of the BHA Has a Nice Swing golf game for charity at the 2015 West Coast Casualty Construction Defect Seminar. With the help of the participants, BHA was able to raise $1925 to benefit the Wounded Warrior Project. BHA would also like to congratulate the raffle winners. Prizes included a DJI Phantom 2 Vision+ Drone and Dodger baseball tickets. The Wounded Warrior Project’s purpose is to raise awareness and enlist the public’s aid for the needs of injured service members; to help injured service members aid and assist each other; and to provide unique, direct programs and services to meet the needs of injured service members. Learn more about the Wounded Warrior Project... Read the court decision
Read the full story...
Reprinted courtesy of

Insurance Companies Score Win at Supreme Court

December 26, 2022 — Mason Fletcher & Ryan Sternoff - Ahlers Cressman & Sleight PLLC
In 2011, the Washington State Department of Transportation (“WSDOT”) contracted with Seattle Tunnel Partners, a joint venture of Dragados USA and Tutor Perini (“STP”) to construct a tunnel (“SR 99 Tunnel”) to replace the dilapidated Alaska Way Viaduct. STP obtained a builder’s “all-risk” insurance policy (“Policy”) from Great Lakes Reinsurance (UK) PLC and several other insurers (collectively, the “Insurers”) which insured against damage to both the project and the tunnel boring machine popularly known as Big Bertha (“Bertha”). Bertha began excavating in July 2013 but broke down a few months later when the machine stopped working. Work did not resume on the project until December 2015. WSDOT and STP tendered insurance claims for the losses associated with the delays and breakdown of Bertha but the Insurers denied coverage. Thereafter, WSDOT and STP sued. The Insurers moved the trial court for partial summary judgment to resolve some, but not all, of the coverage disputes. In a unanimous decision, the Washington State Supreme Court affirmed the trial court and Court of Appeals, and held that insurance companies do not have to reimburse WSDOT and STP for costs accrued during a two-year Project delay, under certain provisions of the insurance policies. Reprinted courtesy of Mason Fletcher, Ahlers Cressman & Sleight PLLC and Ryan Sternoff, Ahlers Cressman & Sleight PLLC Mr. Sternoff may be contacted at ryan.sternoff@acslawyers.com Read the court decision
Read the full story...
Reprinted courtesy of

When Must a New York Insurer Turn Over a Copy of the Policy?

December 23, 2023 — Nicholas P. Hurzeler - Lewis Brisbois
New York, N.Y. (December 7, 2023) - It has long been the rule in New York that a defendant should disclose all insurance policies that might provide coverage to the plaintiff for an underlying claim. McKiernan v Vaccaro, 168 AD3d 827 [2d Dept 2019]; Keenan v Harbor View Health & Beauty Spa, 205 AD2d 589 [2d Dept 1994]. This rule applies to all tort cases, including motor vehicle; however, it does not apply to lawsuits seeking to recover No Fault expenses (see, CPLR 3101(f)(5)). Frequently, a plaintiff will demand a copy of the policy even when the claim is still pre-suit. This raises the question of when the insurer must comply with this specific type of discovery demand in New York. Read the court decision
Read the full story...
Reprinted courtesy of Nicholas P. Hurzeler, Lewis Brisbois
Mr. Hurzeler may be contacted at Nicholas.Hurzeler@lewisbrisbois.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES