Fairfield Connecticut Building Expert Directory

When Do You Call Your Lawyer?

October 08, 2014 — Craig Martin – Construction Contractor Advisor
The National Association of Home Builders recently conducted a survey asking its members about the legal issues they faced in the last 12 months and whether they consulted their attorney to deal with the problem. Below are some highlights of the survey. Legal Issue % of Homebuilders % Contacted Counsel Warranty/call back claims 34% 51% Contract disputes 22% 84% Defective Install/Workmanship 20% 83% OSHA Issues 13% 33% CGL Coverage Questions 11% 73% Construction Liens 10% 57% Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

Tender the Defense of a Lawsuit to your Liability Carrier

January 19, 2017 — David Adelstein – Florida Construction Legal Updates
Sometimes you come across a head scratcher. This would be a decision that does not seem to make a whole lot of sense. For instance, if you are sued and you maintain liability insurance that would potentially provide you a defense and indemnification, not notifying your insurance carrier is a head scratcher. You pay substantial dollars towards the premium of that policy. So, not then notifying your carrier about a lawsuit is a head scratcher, and I mean a head scratcher!! If you are sued, not only should the carrier be notified, but the defense of that lawsuit should be tendered to your liability carrier. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Florida Construction Legal Updates
Mr. Adelstein may be contacted at dadelstein@gmail.com

There Are Consequences to Executed Documents Such as the Accord and Satisfaction Defense

October 01, 2024 — David Adelstein - Florida Construction Legal Updates
A federal government contractor in Jackson Construction Co., Inc. v. U.S., 62 Fed.Cl. 84 (Fed.Cl. 2024) sought delay damages against the government. It lost. The reason for the loss is a crucial reminder that documents parties sign ALWAYS matter. ALWAYS!! In Jackson Construction Co., the contractor’s delay claim was premised on relocating a waterline. The contractor, however, received additional money for relocating the waterline, but no additional time, and this was memorialized in a modification to the contract (i.e., a change order). In executing the modification for the additional work, the contractor did NOT reserve rights for time or money. Indeed, the modification reflected that the monetary adjustment constitutes full compensation for the additional work including delay, namely:

The contract period of performance remains the same. It is further understood and agreed that this adjustment constitutes compensation in full on behalf of the contractor and his subcontractors and suppliers for all costs and markup directly or indirectly, including extended overhead, attributable to the change order, for all delays related thereto, and for performance of the change within the time frame stated.

Jackson Construction Co., supra, at 90.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Good Indoor Air Quality Keeps Workers Healthy and Happy

June 10, 2024 — Ellie Gabel - Construction Executive
Most people primarily think of air conditioners as appliances to keep people cool. However, a 2024 study of office air conditioners shows that they promote indoor air quality by minimizing the harmful effects of bushfire smoke. The research indicated air conditioners used in office environments can trap particles and reduce people’s exposure to harmful elements such as sulfates and nitrates. The researchers collected particulate matter from commercial air conditioner filters during the peak bushfire season in Australia. Evaluations showed the daily particulate matter levels were usually two to three times the average amount. However, some hourly maximums were 10.5 times the usual. The team took samples for four months, finding the specimens exceeded national air quality standards 19% of the time. Analyses performed in a university showed commercially available air filters captured significant amounts of bushfire smoke, reducing the associated hazards for building occupants. Reprinted courtesy of Ellie Gabel, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

Preparing For the Worst with Smart Books & Records

November 07, 2012 — CDJ STAFF
Contractors are often too caught up in keeping the wheel of business churning to recognize deficiencies in how their records are managed. Working hard and working often tend to leave little time for consideration of your documents. But all too often I see the unthinkable, a contractor gets into trouble and has to call on its surety for help. At that point, you might finally get your first dose of reality about your records – and it can cost you. Read the court decision
Read the full story...
Reprinted courtesy of Douglas Reiser of Reiser Legal LLC.
Mr. Reiser can be contacted at info@reiserlegal.com

Eighth Circuit Rejects Retroactive Application of Construction Defect Legislation

September 17, 2014 — Tred R. Eyerly – Insurance Law Hawaii
The Eighth Circuit refused to retroactively apply an Arkansas statute establishing coverage for faulty workmanship. J-McDaniel Const. Co., Inc. v. Mid-Continent Cas. Co., 2014 U.S. App. LEXIS 14911 (8th Cir. Aug. 4, 2014). The homeowners sued J-McDaniel for faulty workmanship in constructing their home. The defective construction work was performed by subcontractors. Mid-Continent refused to defend or indemnify J-McDaniel. The insured sued Mid-Continent. The district court dismissed the claim pursuant to Essex Ins. Co. v. Holder, 261 S.W. 3d 456, 460 (Ark. 2008). In Essex, the Arkansas Supreme Court held that defective workmanship resulting in damages only to the work product itself was not an occurrence. Although The Arkansas legislature overruled Essex by statute, the district court found that the Arkansas case law barred retroactive application of the statute. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Construction Spending Drops in March

May 10, 2013 — CDJ STAFF
Reuters reports that construction spending dropped by 1.7 percent in March, bringing it to the lowest level since August, more than wiping out February’s increase of 1.5 percent. Economists had predicted a mild gain of 0.7 percent. Spending fell due to a 4.1 percent drop in public construction projects, bringing it to its lowest in six and a half years. Read the court decision
Read the full story...
Reprinted courtesy of

Policyholder Fails to Build Adequate Record to Support Bad Faith Claim

May 19, 2011 — Tred R. Eyerly

The importance of careful preparation and documentation was the take away lesson in a Texas bad faith case, C.K. Lee v. Catlin Specialty Ins. Co., 2011 U.S. Dist. LEXIS 19145 (S.D. Tex. Feb. 28, 2011).

C.K. Lee owned a commercial shopping center in Houston. Catlin issued a commercial property policy to Lee. On September 12, 2008, Hurricane Ike hit and caused substantial property damage throughout the Texas Gulf Coast area. On September 24, 2008, Lee submitted a claim for damage to the roof of his shopping center to Catlin.

Catlin hired Engle Martin to represent its interests in adjusting the claim. Engle Martin eventually adjusted over 200 Ike-related claims for Catlin.

In November 2008, Engle Martin and Emergency Services Inc., retained by Lee, inspected Lee’s property. Engle Martin observed evidence of roof repairs that had apparently been made both before and after Hurricane Ike. Engle Martin decided it was necessary to use an infrared scan of the roof to help identify which damages, if any, were attributable to wind and which, if any, were attributable to sub par, prior repairs or natural deterioration.

Engle Martin retained Project, Time & Cost (PT&C) to conduct the infrared inspection. PT&C’s inspection determined there was no wind-related damage to the roof and no breaches or openings created by wind. Instead, the roof had exceeded its life expectancy and was in need of replacement due to normal wear and weathering. Consequently, Catlin decided that the damage to Lee’s roof was not caused by winds from Hurricane Ike.

Meanwhile, Lee’s contractor, Emergency Services, prepared a report estimating that the total cost of repairing the roof would be $871,187. Engle Martin’s estimate for repair of the roof was $22,864.

Lee filed suit for breach of contract, breach of the duty of good faith and fair dealing, and violations of the Texas Insurance Code. Catlin moved for summary judgment on all claims but breach of contract, arguing that because there was a bona fide dispute concerning the cause of the damages and whether they were covered under the policy, there was no evidence of bad faith or violations of the Texas Insurance Code.

Read the full story…

Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii. Mr. Eyerly can be contacted at te@hawaiilawyer.com

Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES