SEATTLE WASHINGTON BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Graham & Who May Trigger The Need To Protest

December 23, 2023 — Hugo Fraga - Ahlers Cressman & Sleight PLLC
On May 30, 2023, the Washington Court of Appeals, Division I, issued a decision that appears to expand a contractor’s obligation with respect to WSDOT notice and claim procedures. In Graham Contracting, Ltd. v. City of Federal Way, No. 83494-1-I, 2023 WL 3721171 (Wash. Ct. App. May 30, 2023) (Unpublished), the Court held that under the 2016 WSDOT Standard Specifications for Road, Bridge, and Municipal Construction (“Standard Specifications”), a Contractor must protest the actions of not only the “Engineer” but also the actions of any person or organization acting on behalf of the Owner. This case arises out of a public construction contract in which Graham Contracting Ltd (“Graham”) built a multi-million dollar roadway improvement for the City of Federal Way along a stretch of Pacific Highway. The appeal was from the trial court’s granting of the City’s motion for summary judgment to dismiss claims by Graham for extra time and money due to delays and impacts to Graham’s construction of the Project. Read the court decision
Read the full story...
Reprinted courtesy of Hugo Fraga, Ahlers Cressman & Sleight PLLC
Mr. Fraga may be contacted at hugo.fraga@acslawyers.com

---

Locals Concerns over Taylor Swift’s Seawall Misdirected

January 13, 2014 — CDJ STAFF
Homeowners in Westerly, Rhode Island have been concerned about alterations made to a seawall below Taylor Swift’s seaside home in Rhode Island, particularly in that some large boulders have been moved to the shore. But officials with Rhode Island’s Coastal Resource Management Council have assured residents that the work is being done at their request, according to the Westerly Sun. In addition to moving boulders, the project repairs an existing seawall which was damaged by Hurricane Sandy. The cost is estimated to be $2 million. Read the court decision
Read the full story...
Reprinted courtesy of

---

Does a Broker Forfeit His or Her Commission for Technical Non-Compliance with Department of Real Estate Statutory Requirements?

September 14, 2020 — Kevin J. Parker - Snell & Wilmer Real Estate Litigation Blog
In a recent Arizona Court of Appeals case, CK Revocable Trust v. My Home Group Real Estate LLC, 2020 WL 4306183 (7/28/2020), the Court of Appeals addressed the distinction between “substantive” and “technical” statutory requirements for real estate broker commission agreements. The Court explained that failure to comply with a substantive requirement would preclude the broker from recovering a commission, but failure to comply with a technical requirement would not. As examples of such substantive requirements, the Court identified the statutory requirement that the broker be licensed at the time the claim for commission arose, and the statutory requirement that the listing agreement be signed by both the broker and the client. Read the court decision
Read the full story...
Reprinted courtesy of Kevin J. Parker, Snell & Wilmer
Mr. Parker may be contacted at kparker@swlaw.com

---

Complying With Data Breach Regulations in the Construction Industry

November 24, 2019 — Ryan Bilbrey - Construction Executive
Recent data breach incidents—like the massive Capital One cyberattack, where a former employee accessed more than 100 million customer accounts and credit card applications—have left many users questioning how safe their information really is in the hands of companies. There is reason to be concerned. More than 4.1 billion records were exposed in nearly 4,000 data breaches reported in the first half of 2019 alone, according to the 2019 MidYear QuickView Data Breach Report. Construction companies are not immune. As the industry becomes more reliant on technology—using augmented reality, Building Information Modeling and drones on construction sites, for example—construction companies are becoming greater targets for hackers looking to gain a financial or strategic advantage. Instead of assuming a company will never experience a breach (or rather, denying that it will ever happen), it’s important to be aware of possible threats and establish data breach response policies to minimize potentially catastrophic fallout. Reprinted courtesy of Ryan Bilbrey, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of
Mr. Bilbrey may be contacted at rbilbrey@biaprotect.com

---

Happenings in and around the 2015 West Coast Casualty Seminar

May 07, 2015 — Beverley BevenFlorez-CDJ STAFF
West Coast Casualty Construction Defect Seminar returns to the Disneyland Hotel next week (May 14th and 15th), and the Construction Defect Journal has compiled a list of concerts, sporting events, and museum exhibitions taking place in and around Anaheim. Whether you like to spend your personal time checking out a new band, or watching your favorite Angel slide into home, or perusing the local art museum, there is something to spark your interest. CONCERT VENUES THE HOUSE OF BLUES IN ANAHEIM Located in Downtown Disney, The House of Blues in Anaheim is a short walk from the convention hall.

Live Band Karaoke Wednesday, May 13th Starting at 10pm No Cover For More Information...

Rockin’ The Blues with Griff Hamlin Thursday, May 14th at 10pm For More Information...

Tyrone Wells Saturday, May 16th at 7pm For More Information and to Purchase Tickets...

THE GROVE OF ANAHEIM Near Angel Stadium, the Grove of Anaheim is just a few miles away from the seminar location.

Ministry Monday, May 11th Doors Open at 7pm / Show Begins at 8pm For More Information and to Purchase Tickets...

Kamelot plus Special Guest Dragonforce Friday, May 15th Doors Open at 7pm / Show Begins at 8pm For More Information and to Purchase Tickets...

CHAIN REACTION Attendees can escape to this all-ages club that’s just a ten minute drive from the Disneyland Hotel.

Ice Nine Kills Wednesday, May 13th at 7pm For More Information and to Purchase Tickets...

Warped Tour Battle of the Bands Thursday, May 14th at 7pm For More Information and to Purchase Tickets...

Manifest Presents Saturday, May 16th at 7pm For More Information and to Purchase Tickets...

SPORTING EVENTS ANGEL’S STADIUM – BASEBALL Take care of your popcorn-and-peanuts-and-cracker-jacks fix while cheering for the Angel’s—conveniently just a few miles from the Disneyland Hotel.

Angels v. Colorado Rockies Tuesday, May 12th at 7:05pm Wednesday, May 13th at 7:05pm For More Information and to Purchase Tickets...

MUSEUM EXHIBITIONS MUZEO This local museum and cultural center is a short drive from the convention hall.

Cougars and Grizzlies: Sharing their Path April 18, 2015-September 13th, 2015 Museum Days/Hours: Tuesday – Sunday (Closed Mondays) / 10 am to 5 pm For More Information and to Purchase Tickets...

BOWERS MUSEUM (Santa Ana) Voted “The Best Museum in Orange County” by OC Register Readers for 16 consecutive years, this arts and cultural center is worth the fifteen minute drive.

Qi Baishi: China’s Modern Master April 11th, 2015-July 11th, 2015 Museum Days/Hours: Tuesday – Sunday (Closed Mondays) / 10 am to 4 pm For More Information and to Purchase Tickets...

Where Ends Meet: A Retrospective of Works by Nancy Ravenhall Johnson March 13th, 2015-August 16th, 2015 Museum Days/Hours: Tuesday – Sunday (Closed Mondays) / 10 am to 4 pm For More Information and to Purchase Tickets...

Exhibition: Adams, Curtis, and Weston: Photographers of the American West May 16th, 2015-November 29th, 2015 Museum Days/Hours: Tuesday – Sunday (Closed Mondays) / 10 am to 4 pm For More Information and to Purchase Tickets...

Lecture: Adams, Curtis, and Weston: Photographers of the American West Saturday, May 16th from 1:30pm to 2:30pm For More Information and to Purchase Tickets...

Read the court decision
Read the full story...
Reprinted courtesy of

---

Ninth Circuit Resolves Federal-State Court Split Regarding Whether 'Latent' Defects Discovered After Duration of Warranty Period are Actionable under California's Lemon Law Statute

December 17, 2015 — Laura C. Williams & R. Bryan Martin – Haight Brown & Bonesteel LLP
In Daniel v. Ford Motor Company (filed 12/02/15), the Ninth Circuit resolved a federal and state court split on the issue of whether consumers can sustain a breach of implied warranty claim under California’s Song Beverly Consumer Warranty Act (aka the “lemon law” statute) for “latent” defects discovered after the warranty period has expired. Answering this question in the affirmative, the Ninth Circuit followed the holding in the California state appellate decision of Mexia v. Rinker Boat Co. 95 Cal.Rptr.3d 285 (2009), which definitively determined there is nothing in California’s lemon law that requires a consumer to discover a latent defect during the duration of the warranty. The underlying class action lawsuit was brought in federal district court by purchasers of Ford Focus vehicles. The plaintiffs alleged Ford was aware of, but failed to disclose, a rear suspension defect in the Focus that resulted in premature tire wear which can cause decreased vehicle control, catastrophic tire failure and drifting on wet or snowy roads. The plaintiffs alleged a number of claims including violations of California’s Song Beverly Consumer Warranty Act and Magnuson Moss Warranty Act. Ford successfully moved for summary judgment on all claims prompting an appeal. Reprinted courtesy of Laura C. Williams, Haight Brown & Bonesteel LLP and R. Bryan Martin, Haight Brown & Bonesteel LLP Ms. Williams may be contacted at lwilliams@hbblaw.com Mr. Martin may be contacted at bmartin@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Judgment Stemming from a Section 998 Offer Without a Written Acceptance Provision Is Void

March 22, 2021 — Arezoo Jamshidi, Stevie B. Newton & Lawrence S. Zucker II - Haight Brown & Bonesteel LLP
In Mostafavi Law Group, APC v. Larry Rabineau, APC (B302344, Mar. 3, 2021), the California Court of Appeal, Second Appellate District (Los Angeles), addressed an issue of first impression: whether the purported acceptance of a Code of Civil Procedure section 998 (“section 998”) offer lacking an acceptance provision gives rise to a valid judgment. The appellate court held that a section 998 offer to compromise (“998 Offer”) without an acceptance provision is invalid and any judgment stemming from it is void. In Mostafavi Law Group, plaintiffs sued defendants for defamation per se, among other claims, which was litigated at-length over several years. Defendants served plaintiffs with a written 998 Offer, offering to settle the action for the sum of $25,000.01. The 998 Offer did not specify the manner in which plaintiffs were to accept the offer. Within the statutory time period for acceptance, plaintiffs’ counsel hand-wrote the following onto the 998 Offer: “Plaintiff Mostafavi Law Group, APC accepts the offer.” That day, plaintiffs also filed a notice of acceptance of the 998 Offer, along with proof thereof, and sent a copy to defendants. The next day, having received the notice of acceptance, defendants advised plaintiffs that they would “draft and send . . . a settlement agreement for . . . signature” before paying the settlement funds. Reprinted courtesy of Arezoo Jamshidi, Haight Brown & Bonesteel LLP, Stevie B. Newton, Haight Brown & Bonesteel LLP and Lawrence S. Zucker II, Haight Brown & Bonesteel LLP Ms. Jamshidi may be contacted at ajamshidi@hbblaw.com Mr. Newton may be contacted at snewton@hbblaw.com Mr. Zucker may be contacted at lzucker@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Loss Ensuing from Alleged Faulty Workmanship is Covered

July 19, 2017 — Tred R. Eyerly - Insurance Law Hawaii
The federal district court found that under Montana law, water damage resulting from alleged faulty workmanship in repairing the insured's roof was covered. Leep v. Trinity Universal Ins Co., 2017 U.S. Dist. LEXIS 86759 (D. Mont. June 6, 2017). The insured's property was damaged in a hail storm. The insured contracted with Sprauge to repair the hail damage. Sprauge tore off and replaced roof lining and shingles. Sprague replaced a vent cap and tubes, but did not replace any vent piping or vents. The contract between the insured and Sprauge provided it was the owners' responsibility to check the exhaust vents for all furnaces and water heaters after the roofing project was completed. Subsequent to the repairs, water was found dripping from a bathroom fan. Moisture was also found on the second story emanating from the ceiling. Finally, in the attic, the furnace vent piping was disconnected and the furnace exhaust was venting into the attic. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly - Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---