FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Contractor’s Burden When It Comes to Delay

October 26, 2020 — David Adelstein - Florida Construction Legal Updates
When a contractor is challenging the assessment of liquidated damages, or arguing that it is entitled to extended general conditions, the contractor bears a burden of proof to establish there were excusable delays that impacted the critical path and, in certain scenarios, the delays were not concurrent with contractor-caused delay:

When delays are excusable, a contractor is entitled to a time extension, such that the government may not assess liquidated damages for those delays. The government bears the initial burden of proving that the contractor failed to meet the contract completion date, and that the period of time for which the government assessed liquidated damages was correct. If the government makes such a showing, the burden shifts to the contractor to show that its failure to timely complete the work was excusable. To show an excusable delay, a contractor must show that the delay resulted from “unforeseeable causes beyond the control and without the fault or negligence of the Contractor.” “In addition, the unforeseeable cause must delay the overall contract completion; i.e., it must affect the critical path of performance.” Further, the contractor must show that there was no concurrent delay.

Ken Laster Co., ASBCA No. 61292, 2020 WL 5270322 (ASBCA 2020) (internal citations omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

NY Gov. Sets Industry Advisory Council to Fix Public Contracts Process

February 01, 2022 — James Leggate - Engineering News-Record
A New York construction industry advisory group, created under a law Gov. Kathy Hochul signed in December, will study and recommend adjustments to state public contracting to address damages incurred by contractors, subcontractors and others because of payment delays on public projects. Reprinted courtesy of James Leggate, Engineering News-Record Mr. Leggate may be contacted at leggatej@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

---

New York Team’s Win Limits Scope of Property Owners’ Duties to Workers for Hazards Inherent in Their Work

May 20, 2024 — Lewis Brisbois Newsroom
New York, N.Y. (May 9, 2024) - New York Partners Jennifer Oxman and Andrew Harms recently secured dismissal of a personal injury plaintiff’s complaint on summary judgment in Queens County, with a state judge accepting their argument that a porter who allegedly tripped and fell on loose wood in a stairwell had no cause of action against the property owner because it was his job to clean the stairs in the first instance. The porter was not an employee of the property owner, but rather an employee of a property management company. Therefore, the workers compensation bar did not apply to the employee’s claims. In a four-page decision, Justice Chereé A. Buggs of Queens County Supreme Court found that plaintiff’s duties as a porter included cleaning the stairwell and that he saw and cleaned loose pieces of wood on occasions prior to his accident. Justice Buggs held that while the wood debris likely came from an “outside source”, i.e. a contractor performing work at a neighboring building, the source of the debris was not relevant. Rather, what mattered was the fact that the hazard upon which plaintiff tripped was “inherent in or related to” plaintiff’s work responsibilities. By contrast, Justice Buggs held that the contractor who allegedly was the source of the wood was not entitled to summary judgment under the same legal theory because it arguably caused and created the hazard upon which plaintiff tripped. Read the court decision
Read the full story...
Reprinted courtesy of Lewis Brisbois

---

Buyer's Demolishing of Insured's Home Not Barred by Faulty Construction Exclusion

June 21, 2017 — Tred R. Eyerly - Insurance Law Hawaii
Loss of the insured's home caused by a renter who demolished the home was covered under the homeowner's policy. Fisher v. Garrison Prop. & Cas. Ins. Co., 2017 Idaho LEXIS 143 (Idaho May 26, 2017). The insured, Shammie L. Fisher, entered a Purchase Agreement to sell her home to Ron Reynoso. The purchase of the property was contingent upon Reynoso obtaining financing. Before completing the purchase, he would lease the property. The Agreement stated, "Buyer intends to make certain improvements to the property upon possession, with the intent to sell the property for a profit." Within two months of renting the property to Reynoso, Fisher learned that he had demolished the entire house down to the foundation. He then ceased work and left. Fisher made a claim under her policy, but Garrison Property and Casualty Insurance Company denied coverage based upon the exclusion for faulty, inadequate or defective work. When Fisher sued, the trial court granted summary judgment to Garrison. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly - Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Instant Hotel Tower, But Is It Safe?

March 28, 2012 — CDJ STAFF

Broad Sustainable Building has leapfrogged in China’s construction boom by building a thirty-story hotel in just fifteen days in the city of Changsha. According to an article in the Los Angeles Times, most of the building was prefabricated, but most prefabricated buildings require a longer time for assembly. Broad claimed that it cut no corners on safety. However, Zhang Li, a Beijing architect, told the Times that “incredible speed also means incredible risk.”



At the completion date, the interior was still partially finished. Some rooms were furnished, while others weren’t quite so ready. The hotel will be used to house clients who are visiting Broad and some of its employees.



Broad called their process “the most profound innovation in human history” and predicted that soon a third of new buildings worldwide would be constructed this way. The company anticipates using the same process to build taller buildings, with hopes of eventually constructing a 150-story building.



China is currently undergoing a building boom which Zhang attributed to a desire to catch up to the developed world. As a result of this boom, he noted that building inspections are often skipped in China to speed up building.

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

---

Florida High-Rise for Sale, Construction Defects Possibly Included

October 30, 2013 — CDJ STAFF
The owners of One Bal Harbour in Bal Harbour, Florida have filed for bankruptcy and are seeking to sell off the luxury condominium and hotel building. There have been problems with the building, including flooding and allegations of structural defects. The original developer went bankrupt and sold before the construction defect lawsuits begain. The building’s opening price of $13 million won’t wipe out Elcom’s $20 million in debt. Read the court decision
Read the full story...
Reprinted courtesy of

---

California Appeals Court Says Loss of Use Is “Property Damage” Under Liability Policy, and Damages Can be Measured by Diminished Value

December 11, 2018 — Michael S. Levine & David M. Costello - Hunton Insurance Recovery Blog
In a win for policyholders, a California appellate court has held that the loss of use of property resulting from alleged negligence constitutes property damage under a liability insurance policy. In Thee Sombrero, Inc. v. Scottsdale Insurance Company, the property owner, Thee Sombrero, operated a venue as a nightclub. After a shooting inside the nightclub caused a patron’s death, the local government revoked Sombrero’s right to use the property as a nightclub and, instead, limited permissible use of the property to a banquet hall. Sombrero sued the security company it had hired to keep guns out of the club, alleging that it was the security company’s negligence that caused the city to revoke Sombrero’s nightclub use permit and that the loss of use of the facility as a nightclub resulted in damages of almost a million dollars based on an assessment of the property’s diminished market value. The security company did not contest the claim, and Sombrero obtained a default judgment. Reprinted courtesy of Michael S. Levine, Hunton Andrews Kurth and David M. Costello, Hunton Andrews Kurth Mr. Levine may be contacted at mlevine@HuntonAK.com Mr. Costello may be contacted at dcostello@HuntonAK.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Appeals Court Overruled Insured as Additional Insured on Subcontractor’s Commercial General Liability Policy

April 02, 2014 — Beverley BevenFlorez-CDJ STAFF
Scott R. Murphy and Clifford J. Shapiro of Barnes & Thornburg LLP in the publication National Law Review analyzed the findings of the Mississippi case Carl E. Woodward, LLC v. Acceptance Indemnity Insurance: “the U.S. Court of Appeals for the Fifth Circuit overruled the district court’s determination that a general contractor was insured as an additional insured on its subcontractor’s commercial general liability (CGL) policy for claims arising out of the allegedly defective work performed by the subcontractor.” “This case underscores the fact that many standard policy forms do not include completed operations coverage for additional insureds,” Murphy and Shapiro declared. “Owners and contractors that desire to have such coverage therefore need to check their contracts to be make sure the contract language requires completed operations coverage for additional insureds, and they also need to obtain and review the actual additional insured endorsement contained in their subcontractors’ insurance policies before work commences to make sure that the required completed operations insurance coverage is provided.” Read the court decision
Read the full story...
Reprinted courtesy of

---