Fairfield Connecticut Building Expert Directory

A Few Green Building Notes

April 03, 2019 — Christopher G. Hill - Construction Law Musings
This past week, the blogosphere (if that’s even the word these days) has been abuzz about green building and the value that green can add to a project. Three items in particular (among many) got my attention. The first of these was the fact that a new private sustainability rating system is ready for launch. The Institute for Sustainable Infrastructure (or ISI) is seeking public comment on its proposed envISIon. This new system (aptly dubbed Version 1.0) will go “live” in July for comment. Why mention this new system? First of all, ISI’s founding members are the American Society of Civil Engineers (ASCE), the American Public Works Association (APWA) and the American Council of Engineering Companies (ACEC). This trio gives the new program some fairly heavy weight backing. Second, while there are rating systems aside from the ever present LEED, none have taken hold in any real way to compete with LEED. I am curious to see if the envISIon system has any better luck. Finally, this shows that sustainable building is of interest to more than the USGBC and those of us that discuss LEED on a daily basis. I find this to be a great thing that could lead to more societal acceptance of sustainable practices as a standard practice rather than a goal. Hopefully such efforts will offset the other two notes that caught my eye recently. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

No Coverage Where Cracks in Basement Walls Do Not Amount to Sudden Collapse

January 10, 2018 — Tred Eyerly - Insurance Law Hawaii

In another of a series of collapse cases arising out of Connecticut, the federal district court found there was no coverage for the homeowner's cracked basement wall caused by defective concrete. Liston-Smith v. CSAA Fire & Cas. Ins. Co., 2017 U.S. Dist. LEXIS 206211 (D. Conn. Dec. 15, 2017).

Read the court decision
Read the full story...
Reprinted courtesy of Tred Eyerly, Insurance Law Hawaii
Tred Eyerly may be contacted at te@hawaiilawyer.com

Three Recent Cases Strike Down Liquidated Damages Clauses In Settlement Agreements…A Trend Or An Aberration?

November 01, 2021 — Adam M. Tuckman - ConsensusDocs
Beginning more than one century ago, owners and contractors generally have adopted the convention of including liquidated damages in their contracts to fix potential liability for delay (and other losses) at the inception of the project. The proliferation of liquidated damages clauses in modern contracts can be attributed to economic and legal factors. From the owner’s standpoint, it may be exceedingly difficult to prove the actual cost impact of a delayed completion of the project. A properly calculated liquidated damages rate would save the owner the significant expense of quantifying its delay damages. On the contractor’s side, a reasonable amount of liquidated damages may be preferable to uncapped or unknown liability, allowing the contractor to more accurately price its bid and efficiently allocate risk. Coinciding with, or perhaps a leading cause of, the industry’s embrace of liquidated damages provisions, was the shift in courts throughout the country from disfavoring such clauses to accepting them (within limits) as an appropriate exercise of contract rights. While some variation exists among the states, courts have generally recognized that liquidated damages clauses are a viable alternative to proof of actual loss so long as (i) actual losses were difficult to quantify, and (ii) the stipulated sum bears a reasonable relationship to the anticipated loss at the time of contracting. See, e.g., Restatement (Second) of Contracts § 356. Conversely, a clause that penalizes the breaching party rather than serving as an estimate of probable loss is likely to be found unenforceable. Read the court decision
Read the full story...
Reprinted courtesy of Adam M. Tuckman, Watt, Tieder, Hoffar, & Fitzgerald, LLP
Mr. Tuckman may be contacted at atuckman@watttieder.com

Best Lawyers Honors Hundreds of Lewis Brisbois Attorneys, Names Four Partners ‘Lawyers of the Year’

September 16, 2024 — Lewis Brisbois Newsroom
(August 15, 2024) - Best Lawyers has selected 171 Lewis Brisbois attorneys across 47 offices for its 31st edition of The Best Lawyers in America. It has also recognized four Lewis Brisbois partners on its "Lawyers of the Year" list: San Diego Partner Gary K. Brucker Jr. (Litigation - Real Estate); Weirton Managing Partner Michelle L. Gorman (Mass Tort Litigation/Class Actions - Defendants); Roanoke Partner Paul C. Kuhnel (Medical Malpractice Law - Defendants); and Los Angeles Co-Administrative Partner Steven R. Lewis (Product Liability Litigation - Defendants). Please join us in congratulating the following attorneys on their Best Lawyers recognition! You can see the full list of attorneys named to Best Lawyers' Ones to Watch in America here. Read the court decision
Read the full story...
Reprinted courtesy of Lewis Brisbois

Wendel Rosen’s Construction Practice Group Receives “Tier 1” Ranking by U.S. News and World Reports

November 10, 2016 — Garret Murai – California Construction Law Blog
Wendel Rosen’s Construction Practice Group has received a “Tier 1” ranking by U.S. News and World Reports in its 2017 Best Law Firms rankings and the firm as a whole has been named one of the “Best Law Firms.” This is the fourth consecutive year that Wendel Rosen’s Construction Practice Group has achieved a “Tier 1” ranking. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

NY Is Set To Sue US EPA Over ‘Completion’ of PCB Removal

June 25, 2019 — Mary B. Powers - Engineering News-Record
New York state intends to sue the U.S. Environmental Protection Agency for issuing a certificate to General Electric Co. affirming the company completed its $1.7-billion cleanup of about 40 miles of the upper Hudson River, contaminated with PCBs from two former factories. State Attorney General Letitia James said April 11 that a December state study showed elevated PCB levels in river sediment and concentrations in fish, which were not recovering at the rate EPA anticipated. Read the court decision
Read the full story...
Reprinted courtesy of Mary B. Powers, ENR
ENR may be contacted at ENR.com@bnpmedia.com

Court Grants Partial Summary Judgment on Conversion Claim Against Insurer

February 01, 2023 — Tred R. Eyerly - Insurance Law Hawaii
Although the court was incredulous that the parties were disputing the possession of a gate opener allegedly damaged in a lightning strike, it granted the insured's motion for partial summary judgment finding the insurer had converted the gate opener. Privratsky v. Liberty Mut. Fire Ins Co., 2022 U.S. Dist. LEXIS 196002 (D. Haw. Oct. 27, 2022). (Full disclosure, our office is co-counsel for the insured). Mr. Privratsky alleged his home on Maui was struck by lightning which caused an electrical surge. The home and personal property were damaged. The alleged cost of repair work at one point was as much as $325,000. A claim was submitted under a homeowner's policy issued by Liberty Mutual. Liberty paid for only some of the damage. Privratsky filed suit alleging three causes of action for: (1) declaratory judgment that the losses were covered by the policy issued by Liberty; (2) bad faith; and (3) conversion of personal property, namely, the damaged gate operator. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Proving Impacts to Critical Path to Defeat Liquidated Damages Assessment

December 16, 2019 — David Adelstein - Florida Construction Legal Updates
When a contractor is staring down the barrel of an owner’s assessment of liquidated damages, the burden will fall on the contractor to establish that the delay was attributable to the owner and the owner’s agents. The contractor will want to do this not only to defeat the assessment of liquidated damages, but because it will want to establish that the delay caused it to incur extended field overhead (general conditions) for which the owner is responsible. A contractor supports its burden by proving the impacts to its critical path. “In general, proving an allegation of government-caused delays without a means of showing the critical path is a steep prospect.” James Talcott Construction v. U.S., 2019 WL 1040383, *8 (Fed. Cl. 2019) (unreported opinion) (finding that because contractor did NOT present a critical path analysis it could not support its claim for delay caused by the government). Avoiding the assessment of liquidated damages means the contractor needs to support that it encountered excusable delay and it is/was entitled to an extension of time to complete the project. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES