A Retrospective As-Built Schedule Analysis Can Be Used to Support Delay
May 23, 2022 —
David Adelstein - Florida Construction Legal UpdatesDelay claims are part of construction. There should be no surprise why. Time is money. A delay claim should be accompanied by expert opinions that bolster evidence that gets introduced. The party against whom the delay claim is made will also have an expert – a rebuttal expert. Not surprisingly, each of the experts will rely on a different critical path as to relates to the same project. The party claiming delay will rely on a critical path that shows the actions of the other party impacted their critical path and proximately caused the delay. This will be refuted by the opposing expert that will challenge the critical path and the actions claimed had no impact on the critical path (i.e., did not proximately cause the delay). Quintessential finger pointing!
This was the situation in CTA I, LLC v. Department of Veteran Affairs, CBCA 5826, 2022 WL 884710 (CBCA 2022), where the government terminated the contractor for convenience and the contractor claimed equitable adjustments for, among other things, delay. The contractor’s expert relied on an as-built critical path analysis by “retrospectively creating updates to insert between the contemporaneous updates.” Id., supra, n.3. The government’s expert did not do a retrospective as-built analysis and relied on only contemporaneous schedule updates. Id.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Partner John Toohey is Nominated for West Coast Casualty’s Jerrold S. Oliver Award of Excellence!
March 11, 2024 —
Dolores Montoya - Bremer Whyte Brown & O'Meara LLPBremer Whyte Brown & O’Meara, LLP is honored to share that Newport Beach Partner John Toohey is nominated for West Coast Casualty’s 2024 Jerrold S. Oliver Award of Excellence!
Every year, West Coast Casualty recognizes an individual who is committed, trustworthy, and has contributed years to the betterment of the construction defect community. The award is named after the late Judge Jerrold S. Oliver who is considered a “founding father” in the alternate resolution process in construction claims and litigation. Each year, members of the construction community are asked to nominate individuals who invoke the same spirit as Judge Oliver.
Read the court decisionRead the full story...Reprinted courtesy of
Dolores Montoya, Bremer Whyte Brown & O'Meara LLP
Arizona Is the No. 1 Merit Shop Construction State, According to ABC’s 2020 Scorecard
February 15, 2021 —
ABC - Construction ExecutiveAssociated Builders and Contractors released its
2020 Merit Shop Scorecard, an annual ranking based on state policies and programs that encourage workforce development, strengthen career and technical education, grow careers in construction, and promote fair and open competition for taxpayer-funded construction projects.
Arizona topped the rankings for the first time this year based on the state’s promotion of free enterprise and investment in tomorrow’s construction workforce, a top priority for ABC. Georgia followed Arizona in second place this year, up from fifth in 2019. Florida, a year-to-year high performer, remained in the top five after two years in the top rank in 2018 and 2019.
“A foundational pillar of ABC is building the next generation of craft professionals, and the top states in this year’s rankings lead the country in workforce development policies,” said Ben Brubeck, ABC’s vice president of regulatory, labor and state affairs. “The merit shop contractor can flourish in free enterprise environments created in states like Arizona and Florida, which has positive ripple effects on a state’s overall economic growth.”
Reprinted courtesy of
ABC, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the court decisionRead the full story...Reprinted courtesy of
Back to Basics – Differing Site Conditions
December 19, 2018 —
Tracey W. Pruiett - Smith CurrieEncountering an unexpected site condition is one of the more common risks on a construction project. A “differing site condition”, or it is sometimes called a “changed condition”, is generally understood to be a physical condition that is discovered while performing work and that was not visible or otherwise expected at the time of bidding. Often, the condition could not have been discovered by a reasonable site investigation. Examples of common differing site conditions include: soil with inadequate bearing capacity to support the building being constructed, soil that cannot be reused as structural fill, unanticipated groundwater, quicksand, mud, rock formations, or other artificial subsurface obstructions. Differing site conditions may also occur within the walls or ceilings of a renovation project such as the renovation of a hospital or historic building.
Read the court decisionRead the full story...Reprinted courtesy of
Tracey W. Pruiett, Smith CurrieMs. Pruiett may be contacted at
twpruiett@smithcurrie.com
Public Adjuster Cannot Serve As Disinterested Appraiser
April 18, 2023 —
Tred R. Eyerly - Insurance Law HawaiiThe Florida Supreme Court found that the president of a public adjusting firm, which was to be compensated on a contingency basis for its adjusting services, could not subsequently serve as a "disinterested" appraiser pursuant to the policy language. Parrish v. State Farm Fla. Ins. Co., 2023 Fl. LEXIS 261 (Feb. 9, 2023).
Jon Parrish was insured under a policy issued by State Farm Florida Insurance Company. When his home was damaged by Hurricane Irma in September 2017, he filed a claim and hired Keys Claims Consultants, Inc. (KCC) to provide public adjusting services. Mr. Parrish agreed to pay KCC a contingency fee equal to ten percent of whatever amount he eventually recovered from State Farm.
There was disagreement between State Farm's estimate of the loss and that of KCC. Mr. Parrish demanded that the appraisal process set forth in the policy be implemented. Mr. Parrish informed State Farm that George Keys, the president of KCC, would serve as Mr. Parrish's appraiser.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
Remote Depositions in the Post-Covid-19 World
September 06, 2021 —
Islam M. Ahmad - Wilke Fleury, LLPDespite the easing of COVID-19 restrictions in California, many of the changes imposed on the legal industry by the pandemic will likely remain in effect for the foreseeable future. One major change for litigators has been conducting depositions remotely. This change takes an already intricate task and makes it further complex by adding a new dimension of factors to consider. It is imperative that litigators understand these factors to avoid giving their opposition an undue advantage and to maximize the utility of depositions. While we may disagree as to whether remote depositions are a welcome change, the fact of the matter is that lawyers must adapt to them and provide adequate legal representation. This article explores some of the challenges and opportunities presented by remote depositions.
- The Deponent
The deponent is the single most important element of any deposition and handing it properly becomes even more delicate in remote settings. I recently took a deposition where the plaintiff met their attorney for the first time at their deposition. The result was not spectacular. The plaintiff was ill-prepared, and the case eventually settled for far less than what it might have if it had been better prepared.
Read the court decisionRead the full story...Reprinted courtesy of
Islam M. Ahmad, Wilke Fleury, LLPMr. Ahmad may be contacted at
iahmad@wilkefleury.com
Connecticut Gets Medieval All Over Construction Defects
February 10, 2012 —
CDJ STAFFThe Hartford Courant reports that Connecticut is trying a very old tactic in a construction defect suit. The law library building at the University of Connecticut suffered from leaks which have now been repaired. The state waited twelve years after was complete to file lawsuit, despite that Connecticut has a six-year statute of limitations on construction defect claims. Connecticut claims that the statute of limitations does apply to the state.
The state is arguing that a legal principle from the thirteenth century allows it to go along with its suit. As befits a medieval part of common law, the principle is called “nullum tempus occurrit regi,” or “time does not run against the king.” In 1874, the American Law Register said that nullum tempus occurrit reipublicae “has been adopted in every one of the United States” and “is now firmly established law.”
In the case of Connecticut, Connecticut Solicitor General Gregory D’Auria said that “the statute of limitations does not apply to the state.” He also noted that “the state did not ‘wait’ to file the lawsuit. The lawsuit was filed only after all other options and remedies were exhausted.”
Connecticut also argued that “nullus tempus occurrit regi” applied in another construction defect case at the York Correctional Institution. The judge in that case ruled in December 2008 to let the case proceed. But in the library case, Judge William T. Cremins ruled in February 2009 that the statute of limitations should apply to the state as well. Both cases have been appealed, with the library case moving more quickly toward the Connecticut Supreme Court.
Read the full story…
Read the court decisionRead the full story...Reprinted courtesy of
Rising Construction Disputes Require Improved Legal Finance
November 15, 2022 —
Apoorva Patel - Construction ExecutiveConstruction disputes are famously high stakes, and the industry is currently experiencing an uptick in the value and number of disputes resulting from contractual obligations and third-party or force majeure incidents. While this is not entirely surprising given COVID-19’s disruption of global markets and supply chains, the numbers are noteworthy.
For example, in 2020 alone, the International Chamber of Commerce (ICC)—the leading institution for construction disputes, partly because its clauses feature in many FIDIC standard form contracts—registered 194 construction arbitrations, and construction disputes now comprise over 20% of the ICC caseload.
In addition to the damage to business outcomes that the underlying disputes may present, parties can quickly spend many millions on legal fees and expenses, as well as technical experts and consultants, if and when those disputes progress through the courts or arbitration. According to Norton Rose’s 2020 Global Construction Disputes Report, the average construction dispute value rose sharply from $30.7 million in 2019 to $54.26 million in 2020.
Reprinted courtesy of
Apoorva Patel, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the court decisionRead the full story...Reprinted courtesy of