Fairfield Connecticut Building Expert Directory

The Construction Project is Late—Allocation of Delay

November 17, 2016 — David Adelstein – Florida Construction Legal Updates
The construction project is late. Very late. The owner is upset and notifies the contractor that it is assessing liquidated damages. The contractor, in turn, claims that the project is late because of excusable, compensable delays and, perhaps, excusable, noncompensable delays. This is a common and unfortunate story between an owner and contractor on any late construction project. Now the fun begins regarding the allocation of the delay! Through previous articles, I discussed that in this scenario the burden really falls on the contractor to establish that the liquidated damages were improperly assessed against it and, thus, it is entitled to additional time and/or extended general conditions as a result of excusable delays. Naturally, this requires the contractor to develop a critical path analysis (time impact analysis) allocating the impacts / delays (and the reasons for the impacts/ delays) to the project completion date. The reason the burden really falls on the contractor is because the owner’s burden is relatively easy – the project was not complete on time pursuant to the contract and any approved changed orders. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Katz, Barron, Squitero, Faust, Friedberg, English & Allen, P.A.
Mr. Adelstein may be contacted at dma@katzbarron.com

Sureties and Bond Producers May Be Liable For a Contractor’s False Claims Action Violation

October 26, 2017 — Michael C. Zisa & Susan Elliot – Peckar & Abramson, P.C.
Two recent decisions from the United States District Court for the District of Columbia and the United States Court of Federal Claims highlight that sureties and bond producers are not immune to the potentially severe consequences of the False Claims Act (“FCA”) and related federal fraud statutes. In each case, the Court determined that sureties and bond producers can face potential liability under these fraud statutes for direct and indirect submission of false claims to the federal government Reprinted courtesy of Michael C. Zisa, Peckar & Abramson, P.C. and Susan Elliott, Peckar & Abramson, P.C. Mr. Zisa may be contacted at mzisa@pecklaw.com Ms. Elliott may be contacted at selliott@pecklaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Ten ACS Lawyers Recognized as Super Lawyers or Rising Stars

August 30, 2021 — Cameron Sheldon - Ahlers Cressman & Sleight PLLC
ACS is very honored and pleased to announce ten members of our firm were awarded the distinction of top attorneys in Washington. Our blog articles usually cover Construction Legal News, but we feel this is a newsworthy accolade to be shared with friends and clients. To become candidates to receiving the Super Lawyer nomination, lawyers are nominated by a peer or identified by research. After completing this first step in the process, Super Lawyer’s research department analyzes 12 indicators, such as experience, honors/awards, verdicts/settlements, and others. As for the third step, there is a peer evaluation by practice area. Finally, for step four, candidates are grouped into four firm-size categories. In other words, solo and small firm lawyers are compared only with other solo and small firm lawyers, and large firm lawyers are compared with other large firm lawyers. The process is very selective and only 5 percent of the total lawyers in Washington are nominated as Super Lawyers. John P. Ahlers, one of the firm’s founding partners, was recognized as the third Top Lawyer out of all Washington lawyers in the State. Named partner Scott R. Sleight and partner Brett M. Hill were both recognized as one of the 100-Best Lawyers in the State. Read the court decision
Read the full story...
Reprinted courtesy of Cameron Sheldon, Ahlers Cressman & Sleight PLLC
Ms. Sheldon may be contacted at cameron.sheldon@acslawyers.com

Toolbox Talk Series Recap – Considerations for Optimizing Dispute Resolution Clauses

June 05, 2023 — Michael Filbin - The Dispute Resolver
In the April 27, 2023 edition of Division 1's Toolbox Talk Series moderated by Manuel del Valle, Sergio Andre Laclau (Partner at Mello Torres) and Liza Akins (Senior Assistant GC and Division Counsel at ARCO Design/Build) offered the following strategies for drafting effective ADR clauses in construction contracts:

Define the ADR process for various types of disputes.

Not all disputes on a construction project are the same, and the parties can tailor the ADR process to different situations. For example, the parties could choose to arbitrate complex disputes and resolve minor claims through mediation. Differentiating the ADR process between complex and minor disputes can save parties time and money. While Liza prefers arbitration for complex claims because you can get a quick and final decision from an arbitrator experienced with construction disputes, she noted that arbitration costs can add up quickly. Therefore, if the dollar amount in dispute is relatively small, arbitration may not make sense financially. Mediation tends to be a comparatively cheaper and faster option. Read the court decision
Read the full story...
Reprinted courtesy of Michael Filbin, Cozen O'Connor
Mr. Filbin may be contacted at mfilbin@cozen.com

Cal/OSHA-Approved Changes to ETS Will Take Effect May 6, 2022

May 16, 2022 — Matthew C. Lewis & Nicole R. Kardassakis - Payne & Fears
A new, third revised version of the Cal/OSHA COVID-19 Prevention Emergency Temporary Standards (“ETS”) has been approved by Cal/OSHA, and is expected to go into effect on May 6, 2022. This updated ETS will likely be in effect through Dec. 31, 2022. The language still needs to be reviewed, finalized, and filed with the Secretary of State by the Office of Administrative Law, but a redline of the proposed changes that Cal/OSHA has approved is available here. Much of the previous ETS (which took effect in January 2022, and we discussed here) will remain in effect. But the new version includes some key changes, including the following:

Employers will now have similar obligations toward employees who are fully vaccinated and employees who are not fully vaccinated with respect to testing and face coverings. Employers must make COVID-19 testing available at no cost to all symptomatic employees during the employee’s paid time, regardless of the employee’s vaccination status. Employers also must make respirators available to all employees upon request, again regardless of the employee’s vaccination status.

Reprinted courtesy of Matthew C. Lewis, Payne & Fears and Nicole R. Kardassakis, Payne & Fears Mr. Lewis may be contacted at mcl@paynefears.com Ms. Kardassakis may be contacted at nrk@paynefears.com Read the court decision
Read the full story...
Reprinted courtesy of

A New AAA Study Confirms that Arbitration is Faster to Resolution Than Court – And the Difference Can be Assessed Monetarily

June 05, 2017 — John P. Ahlers - Ahlers & Cressman PLLC
There has been a perception among some litigators that arbitration is more expensive than court due to several factors. Among them:

The “upfront” costs are higher in that filing fees for arbitration exceed those in court. Arbitrators are paid, whether hourly or a flat rate, and the three arbitration panels can become very expensive.
Some arbitration clauses preserve statutory discovery rights, basically defeating the advantage of a simplified arbitration process. Discovery wars are extremely expensive. Depositions are the most costly of discovery, and in arbitration, as opposed to court, depositions are limited or do not exist.
Some arbitration clauses integrate the statutory rules of civil procedure, making arbitration almost equivalent to litigation. These types of clauses do the parties no favors.

These notions are all dispelled in a recent American Arbitration Association (AAA) study comparing the length of time in court, based on published federal court statistics, to the length of time in arbitration, based on data from the AAA. The study demonstrates that federal courts take much longer to resolve cases by trial and appeal than arbitration by AAA. Read the court decision
Read the full story...
Reprinted courtesy of John P. Ahlers, Ahlers & Cressman PLLC
Mr. Ahlers may be contacted at jahlers@ac-lawyers.com

Meet Orange County Bar Associations 2024 Leaders

April 08, 2024 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
Bremer Whyte Brown & O’Meara, LLP is proud to share that CEO/Founding Partner Nicole Whyte and Orange County Bar Association’s (“OCBA”) leaders are featured in the Orange County Lawyer (“OCL”) publication, Who’s Who In The OCBA, that was released earlier this month. To see this year’s 2024 board of directors, section leaders, committee chairs, task forces, and charitable fund board, please click here. Nicole Whyte provides individualized counseling and representation in all areas of Family Law. She has served on various OCBA legal committees and boards for over two decades and was elected to OCBA’s Board of Directors in 2024. She is committed to supporting the needs of the OCBA and its thriving and diverse OC legal community. Read the court decision
Read the full story...
Reprinted courtesy of Dolores Montoya, Bremer Whyte Brown & O'Meara LLP

Customer’s Agreement to Self-Insure and Release for Water Damage Effectively Precludes Liability of Storage Container Company

December 16, 2019 — Christopher Kendrick & Valerie A. Moore – Haight Brown & Bonesteel LLP
In Kanovsky v. At Your Door Self Storage (No. B297338; filed 11/25/19), a California appeals court held that a waiver of liability and agreement to self-insure in a storage container contract barred coverage for water damage to goods stored in the container. In Kanovsky, plaintiffs contracted for portable storage containers when moving. They loaded their washing machine into one of the containers without checking whether it was fully drained. They locked the containers and reopened them four years later to discover water damage to the contents. They sued the storage company, alleging causes of action for breach of contract; tortious breach of covenant; negligence; and violation of the Consumer Legal Remedies Act, Civil Code section 1750. The storage company’s insurer intervened and moved for summary judgment, which was granted. The appeals court affirmed. The storage company’s contract contained a release of liability stating that personal property was stored “at the customer’s sole risk” and the owners “shall not be liable for any damage or loss,” including water damage. Further, the contract stated that the containers were not waterproof, and again that the storage company was not liable for water damage. The contract attached an addendum further stating that the owner was “a landlord renting space, is not a warehouseman, and does not take custody of my property.” The addendum went on with an acknowledgement that the owner: “2. Is not responsible for loss or damage to my property; 3. Does not provide insurance on my property for me; and 4. Requires that I provide my own insurance coverage or be ‘Self-Insured’ (personally assume risk of loss or damage).” Reprinted courtesy of Christopher Kendrick, Haight Brown & Bonesteel LLP and Valerie A. Moore, Haight Brown & Bonesteel LLP Mr. Kendrick may be contacted at ckendrick@hbblaw.com Ms. Moore may be contacted at vmoore@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES