Seattle Washington Building Expert Directory

Is the Event You Are Claiming as Unforeseeable Delay Really Unforeseeable?

September 26, 2022 — David Adelstein - Florida Construction Legal Updates
Is the item or event you are claiming as an unforeseeable, excusable delay really unforeseeable? This is not a trick question. Just because your construction contract identifies items or events that constitute unforeseeable, excusable delay does not mean those items can be used as a blanket excuse or crutch for the contractor. That would be unfair. For instance, it is not uncommon for a construction contract to list as unforeseeable, excusable delay the following events or items: “(i) acts of God or of the public enemy, (ii) act of the Government in either its sovereign or contractual capacity, (iii) acts of another Contractor in the performance of a contract with the Government, (iv) fires, (v) floods, (vi) epidemics, (vii) quarantine restrictions, (viii) strikes, (ix) freight embargoes, (x) unusually severe weather, or (xi) delays of subcontractors or suppliers at any tier arising from unforeseeable causes beyond the control and without the fault or negligence of both the Contractor and the subcontractors or suppliers.” See, e.g., F.A.R. 52.249-10(b)(1). While the itemization of excusable delay may be worded differently, the point is there may be a listing as to what items or events constitute excusable delay. An excusable delay would justify additional time and, potentially, compensation to the contractor. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Be Careful with Good Faith Payments

February 24, 2020 — Christopher G. Hill - Construction Law Musings
Sometimes doing the expedient thing and what looks good at the time can come back to bite you. Just ask 3M Company. In Faneuil, Inc. v. 3M Co., the Virginia Supreme Court considered a customer services subcontract between Faneuil and 3M relating to a toll collection contract 3M entered into with ERC. The subcontract had a “pay if paid” clause in it requiring payment to 3M from ERC before ERC was required to pay Faneuil, a written change order provision and a base monthly payment to Faneuil for the services that could be reduced in the event of less than expected toll collections. Further, the subcontract stated that if either party settled 3rd party claims, that settlement would not bind the other party to the subcontract absent consent or Court order. Faneuil was then alleged to have been required to provide “Special Services” relating to manual identification of license plates and other information necessary for toll billing due to 3M’s alleged failure to provide adequate imaging services. Faneuil requested (without written change order) and 3M promised to pay extra for these services. When 3M was slow to pay for the special services, Faneuil did what you would expect and threatened to stop providing them. Instead of contesting the right to the work, 3m made sporadic “good faith” payments to induce continued Special Services from Faneuil. Eventually 3M’s issues caused ERC to stop payments and thus 3M stopped paying Faneuil. 3M then settled the payment claims with ERC and still failed to pay Faneuil. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

The Small Stuff: Small Claims Court and Limited Civil Court Jurisdictional Limits

June 10, 2024 — Garret Murai - California Construction Law Blog
Sometimes the small stuff matters. And when it comes to legal disputes this can pose a problem for clients as well as their attorneys because litigation and arbitration, the two most frequently utilized venues to resolve legal disputes in the United States, can be and usually are expensive. Data on the cost of civil litigation is sparse. According to a 2013 survey of trial lawyers conducted by the National Center of State Courts, the median cost of litigating a contract dispute – which is the category that most construction disputes would fall under – is $90,575. And this is in 2013 dollars. With inflation, that number rises to nearly $120,000 in 2023, and based upon our experience litigating and arbitrating complex (and even not so complex) construction disputes, it can be many multiples over that. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

Texas res judicata and co-insurer defense costs contribution

March 23, 2011 — CDCoverage.com

In Truck Ins. Exchange v. Mid-Continent Casualty Co., No. 03-08-00526-CV (Tex. App. 3d Aug. 27, 2010), insured contractor DCI was sued by the project owner seeking damages for defective construction. DCI tendered its defense to its CGL insurers Truck and Mid-Continent. Truck agreed to defend while Mid-Continent denied a defense. While the underlying suit was pending, Mid-Continent sued DCI, but not Truck, and obtained a judicial declaration of no duty to defend or indemnify DCI in the underlying suit. After settling the underlying suit, Truck sued Mid-Continent seeking contribution towards defense costs and indemnity payments. The state trial court entered summary judgment for Mid-Continent. The intermediate appellate court affirmed.

Read the full story...

Reprinted courtesy of CDCoverage.com

Read the court decision
Read the full story...
Reprinted courtesy of

Expired Contract Not Revived Due to Sovereign Immunity and the Ex Contractu Clause

September 15, 2016 — David R. Cook Jr. – AHHC Construction Law Blog
A few months ago, a decision by the Supreme Court of Georgia in Georgia Department of Labor v. RTT Associates, Inc. provided a strict rule for contractors who work with state agencies to determine whether a state agency has waived its sovereign immunity. The issue as framed by the Court was “whether an agency’s waiver of immunity from a breach of contract claim as a result of entering into a written contract remains intact in the event the contract is extended without a written document signed by both parties expressly amending the contract, as required by its terms.” The case involved a contract executed on March 1, 2012, by a contractor, RTT Associates, Inc. (RTT), and the Georgia Department of Labor (DOL), whereby RTT was to develop certain computer software for the DOL by the completion date, June 30, 2012. The contract required that amendments be in writing and fully executed by both parties. Time was of the essence and RTT’s obligation under the contract survived the expiration or termination of the contract. Read the court decision
Read the full story...
Reprinted courtesy of David R. Cook Jr., Autry, Hanrahan, Hall & Cook, LLP
Mr. Cook may be contacted at cook@ahclaw.com

U.K. Broadens Crackdown on Archaic Property Leasehold System

October 23, 2018 — Sree Vidya Bhaktavatsalam - Bloomberg
The U.K. government is cracking down on what it called “unfair” leasehold practices as part of sweeping reforms to its housing system, in a move that would modernize the property market to bring it more in line with nations such as the U.S. Initially prompted by a malpractice scandal, the proposed scope of the focus by the Ministry of Housing, Communities & Local Government has become far broader. A consultation will seek views not only on the practice of charging buyers an annual fee for owning leasehold properties -- known as ground rents -- it will review the whole process of buying, selling and property management of leasehold homes. Read the court decision
Read the full story...
Reprinted courtesy of Sree Vidya Bhaktavatsalam, Bloomberg

Wisconsin Court Enforces Breach of Contract Exclusion in E&O Policy

July 21, 2018 — TLSS Insurance Law Blog
In its recent decision in Crum & Forster Specialty Ins. Co. v. GHD Inc.,2018 U.S. Dist. LEXIS 111827 (E.D. Wisc. July 5, 2018), the United States District Court for the Eastern District of Wisconsin had occasion to consider the application of a breach of contract exclusion in a professional liability policy. Crum’s insured, DVO, was sued in connection with its contract to construct a biogas converter mechanism. The underlying suit alleged a sole cause of action; namely, breach of contract based on DVO’s failure to have fulfilled its obligations to design the mechanism to specification. Read the court decision
Read the full story...
Reprinted courtesy of Traub Lieberman Straus & Shrewsberry LLP

Professional Services Exclusion in CGL Policies

December 05, 2022 — David Adelstein - Florida Construction Legal Updates
A professional services exclusion in a commercial general liability policy means something. It’s an exclusion an insurer will rely on to avoid insurance coverage based on “professional services” performed or rendered by the insured. Don’t take it from me. Take it from the recent opinion in Colony Insurance Company v. Coastal Construction Management, LLC, 2022 WL 16636697 (M.D.Fla. 2022) where the trial court granted a commercial general liability insurer’s motion for judgment on the pleadings based on the professional services exclusion. Here, an owner sued, among other parties, an entity performing only construction management services based on construction defects at its project. The construction manager did not perform any design or physical construction. It was hired to make site inspections of the construction, review construction quality and finish standards, ensure workmanship quality, coordinate the punchlist process, and supervise management and administration of the project. The construction manager’s commercial general liability insurer sued for declaratory relief claiming it owed no duty to defend or indemnify based on the professional services exclusion. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES