Seattle Washington Building Expert Directory

Does a No-Damage-for-Delay Clause Also Preclude Acceleration Damages?

January 27, 2020 — Ted R. Gropman & Christine Z. Fan - ConsensusDocs
Construction contracts often include a “no damage for delay” clause that denies a contractor the right to recover delay-related costs and limits the contractor’s remedy to an extension of time for noncontractor-caused delays to a project’s completion date. Depending on the nature of the delay and the jurisdiction where the project is located, the contractual prohibition against delay damages may well be enforceable. This article will explore whether an enforceable no-damage-for-delay clause is also a bar to recovery of “acceleration” damages, i.e., the costs incurred by the contractor in its attempt to overcome delays to the project’s completion date. Courts are split as to whether damages for a contractor’s “acceleration” efforts are distinguishable from “delay” damages such that they may be recovered under an enforceable no-damage-for-delay clause. See, e.g., Siefford v. Hous. Auth. of Humboldt, 223 N.W.2d 816 (Neb. 1974) (disallowing the recovery of acceleration damages under a no-damage-for-delay clause); but see Watson Elec. Constr. Co. v. Winston-Salem, 109 N.C. App. 194 (1993) (allowing the recovery of acceleration damages despite a no-damage-for-delay clause). The scope and effect of a no-damage-for-delay clause depend on the specific laws of the jurisdiction and the factual circumstances involved. There are a few ways for a contractor to circumvent an enforceable no-damage-for-delay clause to recover acceleration damages. First, the contractor may invoke one of the state’s enumerated exceptions to the enforceability of the clause. It is helpful to keep in mind that most jurisdictions strictly construe a no-damage-for-delay clause to limit its application. This means that, regardless of delay or acceleration, courts will nonetheless permit the contractor to recover damages if the delay is, for example, of a kind not contemplated by the parties, due to an unreasonable delay, or a result of the owner’s fraud, bad faith, gross negligence, active interference or abandonment of the contract. See Tricon Kent Co. v. Lafarge N. Am., Inc., 186 P.3d 155, 160 (Colo. App. 2008); United States Steel Corp. v. Mo. P. R. Co., 668 F.2d 435, 438 (8th Cir. 1982); Peter Kiewit Sons’ Co. v. Iowa S. Utils. Co., 355 F. Supp. 376, 396 (S.D. Iowa 1973). Reprinted courtesy of Ted R. Gropman, Pepper Hamilton LLP and Christine Z. Fan, Pepper Hamilton LLP Mr. Gropman may be contacted at gropmant@pepperlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Tishman Construction Admits Cheating Trade Center Clients

December 17, 2015 — Erik Larson – Bloomberg
Tishman Construction Corp., builder of One World Trade Center in New York’s financial district, admitted to an overbilling scheme spanning a decade and agreed to pay $20 million in restitution and penalties. The scam included the World Trade Center project, the renovation of the landmark Plaza Hotel on 5th Avenue and the expansion of the Javits Convention Center in Manhattan, the U.S. Attorney’s Office in Brooklyn, New York, said Thursday. Read the court decision
Read the full story...
Reprinted courtesy of Erik Larson, Bloomberg

Prompt Payment More Likely on Residential Construction Jobs Than Commercial or Public Jobs

May 02, 2022 — Levelset
NEW ORLEANS, May 02, 2022 (GLOBE NEWSWIRE) -- In construction, no line of work guarantees prompt and in-full payments, but contractors working on residential jobs say their rate of prompt payment is significantly better than commercial or public jobs, according to the 2022 Levelset Cash Flow and Payment Report. However, the report revealed that residential construction jobs require increased communication to improve the chance of prompt payment when compared to commercial or public jobs. Contractors working on residential projects are more than twice as likely as those working on public projects to report getting paid within 30 days, with residential construction contractors saying they are paid in 30 days or less 48% of the time and public construction contractors saying that only happens 21% of the time. Significantly slow payments of 60 days or more are three times more likely on public construction projects than on residential construction projects, according to the survey participants. Residential contractors say it happens rarely, just 6% of the time, while public project contractors say it happens nearly one out of five times (18%). For more information about the report and a detailed summary of findings, please visit: www.levelset.com/survey About Levelset Levelset's mission is to empower contractors to always get what they earn. Levelset's products help millions in the construction industry each year to make payment paperwork and compliance easier, get cash faster, monitor the risk on jobs and contractors, and better understand payment processes and rules. The results are faster payments, access to capital, and fewer surprises. Founded in 2012, Levelset is based in New Orleans, Louisiana, with offices in Austin, Texas, and Cairo, Egypt, and is owned and operated by Procore Technologies, Inc. For more information, visit www.levelset.com. Read the court decision
Read the full story...
Reprinted courtesy of

Building Permits Up in USA Is a Good Sign

November 27, 2013 — CDJ STAFF
The number of building permits for houses issued throughout the country hasn’t been higher since June 2008, a sign that the home building industry continues to recover, even in the face of higher interest rates. “These reports are unequivocally in line with our view that the housing recovery remains will on track, as the lack of supply will continue to support both construction activity and house prices,” according to Harm Bandholz, the chief U.S. economist for UniCredit Research. Building permits were up 13.9% over last year and beat projections of 930,000 permits on an annual rate. The current annual rate for building permits is 1.03 million. Permits for multifamily homes were up 20.1% in September and 15.3% in October. Single-family homes were up 0.8% in October, but had fallen 1.9% the month before. Read the court decision
Read the full story...
Reprinted courtesy of

Should I Stay or Should I Go? The Supreme Court Says “Stay”

June 10, 2024 — Brendan J. Witry - The Dispute Resolver
In the construction industry, arbitration is a frequently agreed-upon and utilized dispute resolution method. The Federal Arbitration Act (the “FAA”), 9 U.S.C. 1, et seq., provides the underpinning and framework for how courts should handle litigation in connection with arbitration agreements. Where a party asserts that a claim brought in court should be subject to arbitration, Section 3 of the FAA provides that the action should be stayed. However, some courts have entertained a party’s request to dismiss a suit where the claim is subject to an arbitration agreement, creating a circuit split in the federal appeals courts. In Smith v. Spizzirri, 2024 WL 2193872, issued on May 16, 2024, the Supreme Court held that, absent some other defect (such as the lack of personal or subject matter jurisdiction), Section 3 of the FAA requires a court which finds a claim is subject to an arbitration must stay the lawsuit during the arbitration proceedings rather than dismissing the action.[1] In so doing, the Court addressed a question that for years it left unanswered. While most Circuits held, prior to Smith, that Section 3 requires a court to stay the litigation pending an arbitral award; the First, Fifth, Eighth, and Ninth Circuits each held that a court could dismiss an action in lieu of staying. In Smith, both parties acknowledged the underlying claims were arbitrable, but when the district court compelled arbitration, the court dismissed the action rather than staying the court proceedings. The Ninth Circuit (relying on its prior precedent) affirmed, with two judges noting that the Ninth Circuit’s approach was incorrect. The Supreme Court granted certiorari and reversed. Read the court decision
Read the full story...
Reprinted courtesy of Brendan J. Witry, Laurie & Brennan LLP
Mr. Witry may be contacted at bwitry@lauriebrennan.com

What You Need to Know About Notices of Completion, Cessation and Non-Responsibility

June 30, 2016 — Garret Murai – California Construction Law Blog
We talk a lot about contractors on the California Construction Law Blog. Owners? Not so much. So this one’s for you. Why are Notices of Completion, Cessation and Non-Responsibility Important to Owners? California recognizes three types of statutory notices on construction projects available to owners: