FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

In Louisiana, Native Americans Struggle to Recover From Ida

August 07, 2022 — The Associated Press (Rebecca Santana) - Bloomberg
Along Bayou Pointe-Au-Chien, La. (AP) -- Driving through her village along a southeastern Louisiana bayou, tribal official Cherie Matherne points out the remnants of house after house — including her own — wrecked nine months ago when Hurricane Ida roared through the Pointe-au-Chien Indian Tribe community. Beige trailers from the Federal Emergency Management Agency and travel campers sit next to pilings that elevated homes 14 feet (4.3 meters) off the ground to protect them from flooding. But it was the wind that got them this time. For hours, the Category 4 hurricane tore off roofs and siding, ripped out insulation and scattered treasured belongings. It destroyed shrimp boats and tossed crab traps. “It’s going to take years before people can get back to their lives. The majority of people are still at a standstill,” said Matherne, the tribe’s cultural heritage and resiliency coordinator. Read the court decision
Read the full story...
Reprinted courtesy of Bloomberg

---

2019 Legislative Changes Affecting the Construction Industry

July 09, 2019 — Melinda S. Gentile & Cadian T. Baker - Peckar & Abramson, P.C.
The 2019 Florida Legislative Session recently concluded and a number of important construction-related House Bills (HB) and Senate Bills (SB) were presented during the Session. Below is a summary of those construction-related bills set to become law in 2019. Bills Becoming Law in 2019 HB 1247: Relating to Construction Bonds. This bill passed both the House and the Senate and is awaiting the Governor’s signature. Once the Governor has approved the bill it becomes effective as of October 1, 2019. This bill addresses how to properly perfect a claim against a contractor’s payment bond. (1) The Notice of Nonpayment that must be served on the contractor and the surety, must be made under oath and include the following provisions: The nature of the labor or services performed or to be performed; The materials furnished or to be furnished; The amount paid on the account; and if known, the amount owed and the amount to become due. A Notice of Nonpayment that includes the sums for retainage must specify the portion of the amount claimed for retainage. (2) A subcontractor, laborer, or material supplier (claimant) who files a fraudulent Notice of Nonpayment loses their rights under the bond. The filing of a fraudulent notice is a complete defense to claimant’s claim against the bond. A notice is fraudulent if the claimant willfully exaggerated the amount due, willfully included a claim for work not performed or materials not furnished or prepared the notice with willful and gross negligence, which resulted in willful exaggeration. However, a minor mistake in the notice, or a good faith dispute as to the amount due, is not considered fraudulent. Please note that this provision mirrors the existing statute relative to a fraudulent lien. Read the court decision
Read the full story...
Reprinted courtesy of Melinda S. Gentile, Peckar & Abramson, P.C.
Ms. Gentile may be contacted at mgentile@pecklaw.com

---

Does a No-Damage-for-Delay Clause Also Preclude Acceleration Damages?

January 27, 2020 — Ted R. Gropman & Christine Z. Fan - ConsensusDocs
Construction contracts often include a “no damage for delay” clause that denies a contractor the right to recover delay-related costs and limits the contractor’s remedy to an extension of time for noncontractor-caused delays to a project’s completion date. Depending on the nature of the delay and the jurisdiction where the project is located, the contractual prohibition against delay damages may well be enforceable. This article will explore whether an enforceable no-damage-for-delay clause is also a bar to recovery of “acceleration” damages, i.e., the costs incurred by the contractor in its attempt to overcome delays to the project’s completion date. Courts are split as to whether damages for a contractor’s “acceleration” efforts are distinguishable from “delay” damages such that they may be recovered under an enforceable no-damage-for-delay clause. See, e.g., Siefford v. Hous. Auth. of Humboldt, 223 N.W.2d 816 (Neb. 1974) (disallowing the recovery of acceleration damages under a no-damage-for-delay clause); but see Watson Elec. Constr. Co. v. Winston-Salem, 109 N.C. App. 194 (1993) (allowing the recovery of acceleration damages despite a no-damage-for-delay clause). The scope and effect of a no-damage-for-delay clause depend on the specific laws of the jurisdiction and the factual circumstances involved. There are a few ways for a contractor to circumvent an enforceable no-damage-for-delay clause to recover acceleration damages. First, the contractor may invoke one of the state’s enumerated exceptions to the enforceability of the clause. It is helpful to keep in mind that most jurisdictions strictly construe a no-damage-for-delay clause to limit its application. This means that, regardless of delay or acceleration, courts will nonetheless permit the contractor to recover damages if the delay is, for example, of a kind not contemplated by the parties, due to an unreasonable delay, or a result of the owner’s fraud, bad faith, gross negligence, active interference or abandonment of the contract. See Tricon Kent Co. v. Lafarge N. Am., Inc., 186 P.3d 155, 160 (Colo. App. 2008); United States Steel Corp. v. Mo. P. R. Co., 668 F.2d 435, 438 (8th Cir. 1982); Peter Kiewit Sons’ Co. v. Iowa S. Utils. Co., 355 F. Supp. 376, 396 (S.D. Iowa 1973). Reprinted courtesy of Ted R. Gropman, Pepper Hamilton LLP and Christine Z. Fan, Pepper Hamilton LLP Mr. Gropman may be contacted at gropmant@pepperlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Discussion of History of Construction Defect Litigation in California

September 10, 2014 — William M. Kaufman – Construction Lawyers Blog
California literally wrote the book on construction defect litigation. Construction defects began to surface after World War II due to cheap track homes being constructed haphazardly on a large scale. Throughout the 1960s, developers began utilizing the services of subcontractors to build massive developments. Rather than having their own employees perform the work, developers began relying more heavily on the specialty subcontractors to perform quality control functions. In 1969, the California Supreme Court expanded liability for developers with respect to residential housing through the concept of strict liability for mass produced homes. Strict liability defendants in construction defect cases may include builders of mass-produced homes, building site developers, component part manufacturers, and material suppliers. Courts have noted that there is little distinction between the “mass production and sale of homes and the mass production and sale of automobiles, and the pertinent overriding policy considerations are the same.” Kriegler v. Eichler Homes, Inc. (1969) 269 Cal. App. 2d 224, 227 (1969). Accordingly, developers of mass-produced tract homes may be held strictly liable whether or not there is privity of contract. Ibid. Courts have held, however, that there is no strict liability against contractors or sub-contractors. See Ranchwood Communities v. Jim Beat Construction (1996) 57 Cal.Rptr.2d 386; La Jolla Village Homeowners’ Assn., Inc. v. Superior Court (1989) 261 Cal.Rptr. 146. Within ten years, attorneys in California were using strict liability theories to seek compensation for homeowners. The initial strict liability lawsuits in California in the 70s and 80s generally applied to condominium projects. The Construction defect “industry” began to take off in the 1980s due to the housing boom and the enforcement of strict liability claims by the courts. Reprinted courtesy of William M. Kaufman, Lockhart Park LP Mr. Kaufman may be contacted at wkaufman@lockhartpark.com, and you may visit the firm's website at www.lockhartpark.com Read the court decision
Read the full story...
Reprinted courtesy of

---

U.K. Construction Unexpectedly Strengthens for a Second Month

March 05, 2015 — Bloomberg News
(Bloomberg) -- U.K. construction growth unexpectedly accelerated for a second month in February, led by a strengthening in homebuilding. Markit Economics said its Purchasing Managers’ Index rose to 60.1, the highest in four months, from 59.1 in January. It fell to a 17-month low of 57.6 in December. Economists forecast the gauge would slip to 59 in February, according to the median estimate in a Bloomberg News survey. Read the court decision
Read the full story...
Reprinted courtesy of Bloomberg News
Scott Hamilton may be contacted at shamilton8@bloomberg.net

---

Real Estate & Construction News Round-Up (03/08/23) – Updates on U.S. Mortgage Applications, the Inflation Reduction Act, and Multifamily Sector

March 20, 2023 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
This week’s round-up explores the cooling housing market and plummeting mortgage applications, potential tax-savings as a result of the 2022 Inflation Reduction Act (IRA), and new developments in the multifamily sector.

• Rising interest rates are impacting affordability and cooling the U.S. housing market, driving mortgage applications to lowest levels in decades. (Nicole Friedman, The Wall Street Journal)
• A number of companies are going all out to entice workers back to the office, and as new data on New York City emerges, upscale offices might help do the trick. (Emily Peck, Axios)
• For real estate developers and investors across the U.S., tax-saving opportunities are popping up as a result of the Inflation Reduction Act of 2022. (David Harlan & Laura Theiss, Dallas Business Journal)

Read the court decision
Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

---

Unit Owners Have No Standing to Sue under Condominium Association’s Policy

February 10, 2012 — Tred R. Eyerly - Insurance Law Hawaii

If a condominium owner suffers damage caused by a leak from another unit, may it sue the insurer for the Association of Apartment Owner (AOAO) for coverage? The federal district court for Hawaii said "no" in a decision by Judge Mollway. See Peters v. Lexington Ins. Co., 2011 U.S. Dist. LEXIS 148734 (D. Haw. December 27, 2011).



Two cases were consolidated. In each case, Plaintiffs owned condominium units at the Watercrest Resort on Molokai. Water leaking from another unit damaged Plaintiffs’ units.



Watercrest Resort was insured by Lexington pursuant to a policy maintained by the AOAO. Plaintiffs filed claims with Lexington. Lexington hired an adjustor.



Unhappy with the adjustment of their claims, Plaintiffs sued Lexington and the adjustor.

Read the full story…



Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii. Mr. Eyerly can be contacted at te@hawaiilawyer.com

Read the court decision
Read the full story...
Reprinted courtesy of

---

Code Changes Pave Way for CLT in Tall Buildings and Spark Flammability Debate

May 13, 2019 — Sam Barnes - Construction Executive
Although nothing new, the debate over which is better as a building material—wood or concrete—intensified in December following the preliminary approval of new codes for cross-laminated timber and mass timber in tall structures. The discussion among industry professionals has been less about CLT’s structural capabilities and more about its perceived flammability, with either side offering decidedly different perspectives. Comparatively new to the United States, CLT and mass timber products are constructed of several layers of pressed lumber board stacked in alternating directions. In December, the International Code Council released the unofficial voting results on several code change proposals, including passage of the entire package of 14 tall mass timber codes. The proposals were presented by the ICC’s Ad Hoc Committee on Tall Wood Buildings, comprised mostly of engineers, architects, building and fire code officials, fire service, materials and testing lab representatives. Reprinted courtesy of Sam Barnes, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

---