Cambridge Massachusetts Building Expert Directory

The Texas Storm – Guidance for Contractors

March 08, 2021 — Curtis W. Martin & Paulo Flores - Peckar & Abramson, P.C.
The Texas snow and ice storm of February 2021 will long be remembered. It has affected everyone across the State, and its impacts continue to be felt a week later. This Alert provides the construction industry with guidance and recommendations for navigating commercial risk resulting from the storm. The potential impacts to your projects may be wide reaching. Consequences on a project site can include damage to the site, delays to work from the storm or from government orders, or simply the lack of help from trades who are dealing with serious personal catastrophes. Offsite impacts can cover a much broader scope of issues, including supply production issues or transportation interruptions. So, what can contractors facing such impacts do to avoid losses, mitigate the impacts, and prepare for what’s to come? Reprinted courtesy of Curtis W. Martin, Peckar & Abramson, P.C. and Paulo Flores, Peckar & Abramson, P.C. Mr. Martin may be contacted at cmartin@pecklaw.com Mr. Flores may be contacted at PFlores@Pecklaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Identifying and Accessing Coverage in Complex Construction Claims

September 29, 2021 — Jeffrey J. Vita & Michael V. Pepe - Saxe Doernberger & Vita, P.C.
I. Introduction First-party, third-party, builder’s risk, professional liability, commercial general liability, wrap-ups, and additional insured status are all potential sources of insurance coverage for a large construction loss. Therefore, it is critical for construction industry participants, from owners and developers to general contractors and their subcontractors, to have a functional knowledge of the different types of insurance coverage available to them and how those coverages intersect to respond to a loss. This paper presents a brief overview of the various types of coverage available to contractors, construction managers, and owners in a large construction loss and the risks each coverage is designed to insure. In general, there are two forms of coverage: (1) First-party liability coverage, which protects an insured’s own losses on a project during construction; and (2) Third-party liability coverage, which insures the project participants for losses that become the subject of claims or suits brought against the project participants by third parties. When a loss occurs, such as property damage, both types of coverage can be implicated. For example, if a fire burns down a building under construction, the contractor likely would incur first-party losses such as cleanup costs. The contractor may also have third-party exposure if the owner alleges that the contractor was responsible for the fire. On the other hand, when a bodily injury occurs, all losses to the contractor will be third-party losses. A broad overview of each of these policies is provided below. Reprinted courtesy of Jeffrey J. Vita, Saxe Doernberger & Vita and Michael V. Pepe, Saxe Doernberger & Vita Mr. Vita may be contacted at JVita@sdvlaw.com Mr. Pepe may be contacted at MPepe@sdvlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Faulty Workmanship Causing Damage to Other Property Covered as Construction Defect

September 30, 2011 — Tred R. Eyerly - Insurance Law Hawaii

In yet another recent construction defect case, the Illinois Court of Appeal found for coverage. See Milwaukee Mut. Ins. Co. v. J.P. Larsen, Inc., 2011 Ill. App. Ct. LEXIS 872 (Ill. Ct. App. Aug. 15, 2011).

Weather-Tite, Inc. hired Larson as a subcontractor to apply sealant to windows installed by Weather-Tite in a condominium building. The windows subsequently leaked and caused water damage. The homeowner’s association sued Weather-Tite for breach of express and implied warranties. Weather-Tite filed a third-party complaint against Larsen alleging that, if it was liable to the association for breach of warranty, Larsen was liable for contribution as a joint tortfeasor. Weather-Tite and Larsen both tendered defenses to Milwaukee Insurance. The tenders were denied and Milwaukee Insurance filed suit to determine rights under the policy.

Cross-motions for summary judgment were filed by all parties. The trial court granted Milwaukee Insurance’s summary judgment motion as to Weather-Tite, but granted Larsen’s cross-motion against Milwaukee Insurance.

On appeal, the appellate court considered whether the underlying pleadings alleged facts demonstrating "property damage" resulting from an "occurrence" within the terms of the policy.

Read the full story…

Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii. Mr. Eyerly can be contacted at te@hawaiilawyer.com

Read the court decision
Read the full story...
Reprinted courtesy of

Traub Lieberman Attorneys Recognized as 2021 New York – Metro Super Lawyers®

October 18, 2021 — Traub Lieberman
Traub Lieberman is pleased to announce that six Partners from the Hawthorne, NY Office have been selected to the 2021 New York - Metro Super Lawyers list. 2021 New York – Metro Super Lawyers

Jonathan Harwood – Professional Liability
Lisa Rolle – Construction Litigation
Christopher Russo – Professional Liability
Lisa Shrewsberry – Professional Liability
Stephen Straus – Insurance Coverage
Richard Traub – Insurance Coverage

Read the court decision
Read the full story...
Reprinted courtesy of Traub Lieberman

Construction Law Client Alert: California’s Right to Repair Act (SB 800) Takes Another Hit, Then Fights Back

February 25, 2014 — Steven M. Cvitanovic and Whitney L. Stefko - Haight Brown & Bonesteel, LLP
Last week, the California appellate courts decided two cases with ramifications under the Right to Repair Act. The first case, Burch, addresses whether the Right to Repair Act is the exclusive remedy for the homeowner. The second case, KB Home, addresses a situation where a homeowner or the homeowner's insurer fails to follow the procedures under the Right to Repair Act. Last August, the Fourth Appellate District announced its decision in Liberty Mutual Ins. Co. v. Brookfield Crystal Cove LLC (2013) 219 Cal.App.4th 98 holding that SB 800 is not a homeowner’s exclusive remedy in situations where defects cause actual damage. Many lawyers believed that Liberty Mutual would be a one-off because of its facts – it was a subrogation case brought by an insurance company. So much for that. Now the Second Appellate District is getting into the act. In Burch v. The Superior Court of Los Angeles County, et al., the Second Appellate District overturned an order granting summary adjudication in favor of a developer, general contractor, and their respective owners, in a construction defect action brought by a residential homeowner. The trial court found that the Right to Repair Act precluded the homeowner’s negligence and implied warranty claims but the Court of Appeal reversed. Reprinted courtesy of Steven M. Cvitanovic, Haight Brown & Bonesteel, LLP and Whitney L. Stefko, Haight Brown & Bonesteel, LLP Mr. Cvitanovic may be contacted at scvitanovic@hbblaw.com, Ms. Stefko may be contacted at wstefko@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Partners Nicole Whyte and Karen Baytosh are Selected for Inclusion in Best Lawyers 2021 and Nicole Nuzzo is Selected for Inclusion in Best Lawyers: Ones to Watch

September 28, 2020 — Bremer Whyte Brown & O’Meara, LLP
Bremer Whyte Brown & O’Meara, LLP is proud to announce that Partners Nicole Whyte and Karen Baytosh have been chosen for inclusion in Best Lawyers 2021 Edition! CEO/Founding Partner Nicole Whyte has been selected for the 2nd time by her peers for inclusion in the 27th Edition of The Best Lawyers in America, for her work in Family Law. Reno Partner Karen Baytosh is also being recognized by her peers for her work in Commercial Litigation. This is an outstanding recognition as only the top 5% of talent in the United States are chosen for inclusion in this publication. BWB&O is also excited to share Partner Nicole Nuzzo has been selected by her peers for her inclusion in the edition of Best Lawyers: Ones to Watch, for her work in Family Law. The “Ones to Watch” award gives recognition to attorneys who are earlier in their careers for outstanding professional excellence in private practice in the United States. Read the court decision
Read the full story...
Reprinted courtesy of Bremer Whyte Brown & O’Meara, LLP

Old Case Teaches New Tricks

March 16, 2017 — Angela A.L. Connor & Curtis W. Martin - Peckar & Abramson, P.C.
Eight years after completion of the wharf project, Zachry and the Port of Houston continue to slug it out in the appellate courts and continue to refi ne Texas construction law along the way. In the latest appellate opinion, the Court of Appeals details the general contractor’s control of the means and methods of their work without interference from a governmental entity. It also supports a subcontractor’s use of a pass-through claim as a cost efficient way to recover damages. By now most of us are familiar with the project and the previous decisions. Zachry sued the Port claiming breach after the Port denied Zachry the right to continue construction using its frozen cutoff wall. The Texas Supreme Court upheld the jury’s $20 million verdict for Zachry, ruling that the Port’s “no damages for delay” clause would not bar Zachry’s claim in light of the Port’s active interference with Zachry’s work. The Supreme Court then sent the case back to the Court of Appeals to consider other arguments that the Port had made. That led to the most recent decision. In December, 2016, the Houston Fourteenth Court of Appeals ruled in favor of Zachry on all issues and affirmed the jury verdict. In doing so, the Court of Appeals provides several lessons or reminders on Texas Construction law. Reprinted courtesy of Angela A.L. Connor, Peckar & Abramson, P.C. and Curtis W. Martin, Peckar & Abramson, P.C. Ms. Connor may be contacted at aconnor@pecklaw.com Mr. Martin may be contacted at cmartin@pecklaw.com Read the court decision
Read the full story...
Reprinted courtesy of

That’s Common Knowledge! Failure to Designate an Expert Witness in a Professional Negligence Case is Not Fatal Where “Common Knowledge” Exception Applies

June 03, 2019 — Lyndsey Torp - Snell & Wilmer Real Estate Litigation Blog
In reversing summary judgment for defendants, the California Fourth District Court of Appeal recently held that homeowners suing their real estate broker for negligence did not need an expert witness to establish the elements of their causes of action. Ryan v. Real Estate of the Pacific, Inc. (2019) 32 Cal. App. 5th 637. Typically, expert witnesses are required to establish the standard of care in professional negligence cases. But in Ryan, the court of appeal held that the “common knowledge” exception applied despite this general rule, because the conduct required by the particular circumstance of the case was within the common knowledge of a layman. The conduct in question here? The broker’s failure to disclose to his client that the client’s neighbor told him that she planned extensive renovations that would obstruct the client’s property’s ocean views. Ryan and Patricia Ryan (the Ryans) hired defendant Real Estate of the Pacific, Inc., doing business as Pacific Sotheby’s International Realty (Sotheby’s) and defendant real estate broker to sell their residence in La Jolla, California. During an open house at the residence, a neighbor informed the Ryan’s real estate broker that she planned extensive renovations at her home that would, among other things, permanently obstruct the Ryan’s westerly ocean views and take several years to complete. The real estate broker never informed the Ryans of this, nor the subsequent buyer. The subsequent buyer purchased the property for $3.86 million, and defendants received $96,500 as commission for the sale. The day after escrow closed, the buyers learned of the renovations, and sought to rescind the purchase. Based on advice of defendants, the Ryans refused, and the dispute proceeded to arbitration. The buyer obtained a rescission of the purchase, with the Ryans order to pay damages, interest, and attorneys’ fees and costs in excess of $1 million. The Ryans then sued Sotheby’s and the real estate broker to recover these amounts and damages caused by defendants’ alleged negligence. Read the court decision
Read the full story...
Reprinted courtesy of Lyndsey Torp, Snell & Wilmer
Ms. Torp may be contacted at ltorp@swlaw.com

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES