SEATTLE WASHINGTON BUILDING EXPERT
DIRECTORY AND CAPABILITIES

White and Williams Announces Lawyer Promotions

May 25, 2020 — White and Williams LLP
White and Williams is pleased to announce the election of Vincent Barbera and James Burger to the partnership. The firm has also promoted Victoria Fuller, Phyllis Ingram, William Johnston, Eric Porter, Gus Sara, Jenifer Scarcella, Lian Skaf and Brett Tishler from associate to counsel. The newly elected partners and promoted counsel represent the wide array of practices that White and Williams offers its clients, including education, finance, financial lines, insurance coverage, labor and employment, litigation, real estate, and subrogation. These accomplished lawyers have earned this advancement based on their contributions to the firm and their practices. “We are pleased to elect these two lawyers to the partnership and promote eight exceptional associates to counsel. The group demonstrates the legal talent and breadth of services White and Williams offers clients,” said Patti Santelle, Managing Partner of the firm. “The contributions of these lawyers have enhanced the growth and reputation of our firm and reflect our deep commitment to clients. We look forward to their continued success.” Read the court decision
Read the full story...
Reprinted courtesy of White and Williams LLP

---

Schools Remain Top Priority in Carolinas as Cleanup From Storms Continues

November 06, 2018 — Joanna Masterson - Construction Executive
A month after Hurricane Florence dumped more than 30 inches of rain on the Carolinas, Hurricane Michael delivered additional flash flooding, power outages and wind damage. While the construction-related impact of Hurricane Michael is still being assessed (stay tuned for more on that front in the coming weeks), Moody’s Analytics estimates total property damage from Florence at $17 billion to $22 billion, factoring in losses from homes, roads, crops, livestock, coal ash ponds and more. While it’s difficult to pinpoint which counties were hit the hardest, the majority of the damage was in the eastern coastal areas of North Carolina. According to Rob Beale, a vice president in W.M. Jordan’s Wilmington, North Carolina, office, Carteret and Onslow counties took the brunt of the storm, while Columbus and Brunswick counties experienced the biggest flooding impact. Reprinted courtesy of Joanna Masterson, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

---

Contractor’s Burden When It Comes to Delay

October 26, 2020 — David Adelstein - Florida Construction Legal Updates
When a contractor is challenging the assessment of liquidated damages, or arguing that it is entitled to extended general conditions, the contractor bears a burden of proof to establish there were excusable delays that impacted the critical path and, in certain scenarios, the delays were not concurrent with contractor-caused delay:

When delays are excusable, a contractor is entitled to a time extension, such that the government may not assess liquidated damages for those delays. The government bears the initial burden of proving that the contractor failed to meet the contract completion date, and that the period of time for which the government assessed liquidated damages was correct. If the government makes such a showing, the burden shifts to the contractor to show that its failure to timely complete the work was excusable. To show an excusable delay, a contractor must show that the delay resulted from “unforeseeable causes beyond the control and without the fault or negligence of the Contractor.” “In addition, the unforeseeable cause must delay the overall contract completion; i.e., it must affect the critical path of performance.” Further, the contractor must show that there was no concurrent delay.

Ken Laster Co., ASBCA No. 61292, 2020 WL 5270322 (ASBCA 2020) (internal citations omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

New Jersey Court Rules on Statue of Repose Case

May 26, 2011 — CDJ STAFF

A three-judge panel issued a per curium ruling on May 23 in Fairview Heights Condo. v. Investors (N.J. Super., 2011), a case which the members of a condominium board argued: “that the judge erred by: 1) dismissing plaintiff’s claims against RLI based upon the statute of repose; 2) dismissing the breach of fiduciary duty claims against the Luppinos based upon a lack of expert opinion; 3) barring the testimony of Gonzalez; and 4) barring the May 23, 1989 job site report.” The court rejected all claims from the condominium board.

The court found that the building must be unsafe for the statute of repose to apply. They noted, “the judge made no findings on whether the water seepage, or the property damage caused by such seepage, in any way rendered the building, or any of the units, unsafe.” Further, “without a specific finding on the question of whether the defects had rendered the building ‘unsafe,’ defendants were not entitled to the benefit of the ten-year statute of repose.“

On the second point, the court also upheld the lower court’s findings regarding the management company:

“The report submitted by Berman establishes that the EIFS product was defective in its design and would therefore have failed from the outset. The defects in that product were, according to Berman, not prone to repair or other mitigation. Therefore, even if defendants did not appropriately inspect or repair the EIFS, their failure to do so would have had no impact on the long-term performance of the EIFS exterior cladding. As plaintiff failed to raise a genuine issue of material fact on these questions, the judge properly granted summary judgment to the Luppinos on plaintiff’s breach of fiduciary duty claim.”

On the final two points, the judges noted “plaintiff maintains that the judge committed reversible error when he excluded the Gonzalez certification and the 1989 job site report prepared by Raymond Brzuchalski.” They saw “no abuse of discretion related to the exclusion of the Gonzalez certification, and reject plaintiff’s arguments to the contrary.” Of the job site report, they found, “no abuse of discretion in the judge's finding that the Brzuchalski 1989 job site report did not satisfy the requirements of N.J.R.E.803(c)(6).”

Read the court’s decision

Read the court decision
Read the full story...
Reprinted courtesy of

---

Eighth Circuit Affirms Judgment for Bad Faith after Insured's Home Destroyed by Fire

January 21, 2019 — Tred R. Eyerly - Insurance Law Hawaii
The Eighth Circuit affirmed the district court's judgment that the insurer acted in bad faith when it denied the insured's claim based upon misrepresentations in the application after destruction of his house by fire. Hayes v. Metropolitan Pro. and Cas. Ins. Co., 2018 U.S. App. LEXIS 31813 (8th Cir. Nov. 9, 2018). Hayes' home was insured by Met under a homeowner's policy. Hayes used the detached garage as part of a home base for his plumbing business. He also rented out the second and third levels of the residence to a tenant and her two children. When Hayes applied for the policy in 2007, Met argues he indicated on the application that the premises were not used to conduct business, and were not used as rental property. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Mandatory Energy Benchmarking is On Its Way

April 22, 2019 — Christopher G. Hill - Construction Law Musings
We have discussed the issue of benchmarking and energy reporting on several occasions here at Musings. As the January 18, 2010 issue of ENR Magazine discusses, now cities and states are getting on board in a big way. Washington, D.C. began requiring building owners to use the EPA Energy Star Portfolio Manager tool on January 1, 2010 and New York City passed a similar measure in December. The D.C. law is the first to require mandatory public disclosure of energy performance. Such disclosure will create a public database of energy performance data. While I understand that this data and its reporting will create energy accountability in a way that non-disclosure of this data would not, the possibilities for misuse or uses that impact the construction world abound. This energy reporting is a step beyond that of the LEED program in that the data is not just reported to the USGBC, but to a public database. As such, the ease of access will impact contracts and contractors in an even bigger way than the USGBC requirements. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

---

Don MacGregor To Speak at 2011 West Coast Casualty Construction Defect Seminar

January 01, 2011 — CDJ STAFF

“Challenges for Experts in Construction Defect Claims and Litigation” will be held Thursday May 13, 2011 between 1:30 and 3:00 PM at this year’s West Coast Casualty Construction Defect Seminar. Among the various topics covered will be of Right to Repair/Opportunity to Repair statutes, improper testing methodologies, new challenges where a case involves a Wrap Policy, OCIPS, CCIPS, and other owner controlled insurance programs, as well as the need for realistic testing protocols for the party the expert is retained to represent.



During the presentation Mr. MacGregor will be working in connection with a group of construction and design experts each of which have extensive experience with construction defect and claims related litigation. This particular session is expected to attract a standing-room only crowd, drawing in excess of 1700 attendees.



The West Coast Casualty Construction Defect Seminar is the largest seminar of its type. This year’s event is scheduled for will take place on May 12 and 13, 2011, at The Disneyland Hotel and Resort. For more information regarding the years event please visit http://www.westcoastcasualty.com/dyncat.cfm?catid=3322

http://www.westcoastcasualty.com/dyncat.cfm?catid=3322 Read the court decision
Read the full story...
Reprinted courtesy of

---

Condemnation Actions: How Valuable Is Your Evidence of Property Value?

November 06, 2018 — Erica Stutman - Snell & Wilmer Real Estate Litigation Blog
When a government condemns (takes) private property for a public use, the property owner is entitled to receive “just compensation” equal to the property’s market value. Value is typically determined by appraisals, but if the parties cannot agree, a judge or jury will determine the amount in a condemnation lawsuit. The parties may seek to present various forms of evidence of value, though it will be admissible only if the evidence is relevant and its value is not substantially outweighed by the risk of causing unfair prejudice, confusion, undue delay or waste of time, does not mislead the jury, and is not needlessly cumulative. See, e.g., Fed. R. Evid. 403. Read the court decision
Read the full story...
Reprinted courtesy of Erica Stutman, Snell & Wilmer
Ms. Stutman may be contacted at estutman@swlaw.com

---