SEATTLE WASHINGTON BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Washington State Supreme Court Issues Landmark Decision on Spearin Doctrine

September 29, 2021 — Cameron Sheldon - Ahlers Cressman & Sleight PLLC
The Washington State Supreme Court’s recent decision in Lake Hills Invs., LLC v. Rushforth Constr. Co. No. 99119-7, slip op. at 1 (Wash. Sept. 2, 2021) marks the first time in over 50 years that it has ruled on the Spearin doctrine. The Court’s opinion clarified the contractor’s burden when asserting a Spearin defense and affirmed the jury’s verdict in favor of contractor AP Rushforth Construction Company (AP). The decision is a major win for Ahlers Cressman & Sleight PLLC attorneys Scott Sleight, Brett Hill, and Nick Korst, who represented AP throughout its long-running dispute with Lake Hills Investments, LLC (LH), including the two-month jury trial and the appeal. Leonard Feldman of Peterson | Wampold | Rosato | Feldman | Luna and Stephanie Messplay of Van Siclen Stocks & Firkins also represented AP on appeal. At trial, the owner—Lake Hills Investments, LLC (LH)—asserted it was entitled to $3 million in liquidated damages and $12.3 million for defects it alleged were caused by AP’s deficient workmanship. AP denied responsibility for the delays and most of the defects and requested payment of $5 million. Regarding LH’s defect claims, AP argued as an affirmative defense that the defects were caused by deficiencies in the plans and specifications provided by LH. This affirmative defense was rooted in the Spearin doctrine, which states that when the contractor follows plans and specifications provided by the owner, the contractor is not responsible for defects caused by the plans and specifications. Read the court decision
Read the full story...
Reprinted courtesy of Cameron Sheldon, Ahlers Cressman & Sleight PLLC
Ms. Sheldon may be contacted at cameron.sheldon@acslawyers.com

---

Real Estate & Construction News Roundup (10/18/23) – Zillow’s New Pilot Program, Production Begins at Solar Panel Plant in Georgia, and More Diversity on Contracts for Buffalo Bills Stadium

November 27, 2023 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
In our latest roundup, Netflix announces plans to open brick-and-mortar locations, NYU develops a way to examine buildings using drones, robots and AI, distressed U.S. commercial real estate hits a 10-year high, and more!

• Zillow is piloting a new program in Arizona offering new home buyers thousands of dollars to help them with their down payments. (Oliver Staley, TIME)
• After an initial backlash regarding workforce diversity, a Gilbane-Turner joint venture has given 40% of contracts on the new Buffalo Bills’ stadium to minority-, women- or service-disabled veteran-owned companies. (Joe Bousquin, Construction Dive)
• To ensure easier compliance with New York City’s Local Law 97, researchers at NYU are developing a method using drones, robots and AI to examine building exteriors for leaks. (Nish Amarnath, Construction Dive)

Read the court decision
Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

---

When Coronavirus Cases Spike at Construction Jobsites

July 27, 2020 — Richard Korman, Scott Judy & Jeff Rubenstone - Engineering News-Record
When Covid-19 took hold in several US states in early spring, Choate Construction responded, as many contractors did, by quickly adopting federal workplace safety guidelines for disinfecting surfaces and maintaining social distancing. Enhanced by various state lockdown measures for businesses and the general public, the new safety system seemed to work with only a handful of workers on Choate’s projects testing positive. Reprinted courtesy of Engineering News-Record reporters Richard Korman, Scott Judy and Jeff Rubenstone Mr. Korman may be contacted at kormanr@enr.com Mr. Judy may be contacted at judys@enr.com Mr. Rubenstone may be contacted at rubenstonej@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

---

Ohio Court of Appeals: Absolution Pollution Exclusion Bars Coverage for Workplace Coal-Tar Pitch Exposure Claims

January 10, 2018 — Complex Insurance Coverage Reporter

On December 28, 2017, the Ohio Court of Appeals (Eighth District) held in GrafTech International, Ltd., et al. v. Pacific Employers Ins. Co., et al., No. 105258 that coverage for alleged injurious exposures to coal tar pitch was barred by a liability insurance policy’s absolute pollution exclusion. Applying Ohio law, the court concluded that Pacific Employers had no duty to defend GrafTech or pay defense costs in connection with claims by dozens of workers at Alcoa smelting plants that they were exposed to hazardous substances in GrafTech products supplied to Alcoa as early as 1942.

Read the court decision
Read the full story...
Reprinted courtesy of White and Williams LLP

---

Quick Note: Attorney’s Fees on Attorney’s Fees

June 13, 2022 — David Adelstein - Florida Construction Legal Updates
In a recent case, the appellate court held that the attorney’s fees provision in the contract was NOT broad enough to entitle the prevailing party to recover attorney’s fees for litigating the amount of attorney’s fees. This is known as “fees on fees” which is when you can recover your prevailing party attorney’s fees when you are fighting over the quantum that should be awarded to you as the prevailing party. The attorney’s fees provision at-issue stated: “In any lawsuit to enforce the Lease or under applicable law, the party in whose favor a judgment or decree has been rendered may recover its reasonable court costs including attorney’s fees from the non-prevailing party.” Language similar to this language can be found in many contracts as a prevailing party attorney’s fees provision. However, this provision was NOT broad enough to recover “fees on fees.” As explained in this article, if this is a consideration, you can negotiate or include this provision into your construction contract by expanding the scope of the prevailing party attorney’s fees provision to clarify that it entitles the prevailing party to recover attorney’s fees in litigating the amount of attorney’s fees. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Flood-Threat Assessment Finds Danger Goes Far Beyond U.S. Homes

October 18, 2021 — Leslie Kaufman, Rachael Dottle & Mira Rojanasakul - Bloomberg
If the floods don’t get you, lack of electricity or a swamped hospital might. Nearly a quarter of U.S. critical infrastructure—utilities, airports, police stations and more—is at risk of being inundated by flooding, according to a new report by First Street Foundation, a Brooklyn nonprofit dedicated to making climate risk more visible to the public. Around 25% of national critical infrastructure is at risk. Roughly 14% of Americans’ properties face direct risk from major storms, but the study shows danger extends far from those property lines. Reprinted courtesy of Leslie Kaufman, Bloomberg, Rachael Dottle, Bloomberg and Mira Rojanasakul, Bloomberg Read the court decision
Read the full story...
Reprinted courtesy of

---

Builders Arrested after Building Collapses in India

July 01, 2014 — Beverley BevenFlorez-CDJ STAFF
Deaths from a building collapse in Chennai, India is currently at nineteen, while forty-two people have been rescued, according to the New York Times, and “40 others are feared trapped in the debris,” reported BBC News. The Chennai police arrested six people, “including the partners of the construction company, the architect and the structural engineer, and charged them with criminal negligence in connection with the building collapse there,” according to P. Subramniam, a Chaennai police officer, as quoted by the New York Times. "It appears they have not adhered to approved plans,” Tamil Nadu Chief Minister J Jayalalithaa told BBC News. “The building appears to have serious structural defects." Building collapses are frequent in India, and most are “blamed on lax safety and substandard materials,” reported BBC News. The New York Times pointed out that “municipal authorities rarely condemn buildings even when they appear to have dangerous defects.” Regardless, “even unsafe buildings attract people who want to live in them because the competition for shelter is fierce among millions of city residents.” Read the full story, New York Times... Read the full story, BBC News... Read the court decision
Read the full story...
Reprinted courtesy of

---

Treble Damages Awarded After Insurer Denies Coverage for Collapse

July 03, 2022 — Tred R. Eyerly - Insurance Law Hawaii
The Fourth Circuit upheld the district court's decision that a collapse was covered, but reversed the denial of treble damages to the insured. DENC, LLC v. Phila. Indem. Ins. Co., 2022 U.S. App. LEXIS 10443 (4th Cir. April 18, 2022). The district court decision was summarized here. DENC owned The Crest, an apartment building leased to Elon University for student housing. Philadelphia Indemnity Company insured the property. In January 2018, students gathered on a second-floor breezeway for a party. Partygoers began jumping in the breezeway, which caused an abrupt collapse. Observers noticed that the breezeway was hanging down by more that a foot. DENC filed a claim with Philadelphia the next day. An adjuster was sent to inspect the breezeway. By that time, the city had condemned The Crest. The adjuster said that undiscovered "water damage which occurred over an extended period of time" caused the loss. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---