Differing Site Conditions: What to Expect from the Court When You Encounter the Unexpected
September 05, 2022 —
Margarita Kutsin - Ahlers Cressman & Sleight[
1]Seattle Tunnel Partners (“STP”), a joint venture of Dragados USA and Tutor Perini, entered into a $1.4 billion contract with the Washington State Department of Transportation (“WSDOT”) to replace the Highway 99 viaduct. In December 2013, a tunnel boring machine (“TBM”) bearing the moniker “Bertha,” then the largest TBM ever built, measuring 425 feet long and 57 feet in diameter, struck an underground pipe. Shortly after the impact, Bertha overheated and eventually could no longer make forward progress. A massive repair effort ensued causing a 2.5-year delay in reaching substantial completion.
WSDOT sued STP for the delay, seeking liquidated damages of $57 million. In response, STP argued its delay was excusable because it was caused by Bertha’s impact with the pipe, and the steel well casing was a Differing Site Condition (DSC) undisclosed in the contract documents. STP asserted counterclaims against WSDOT, alleging breach of contract and seeking $300 million in damages. Ultimately, a jury found that the steel well casing on the pipe was not a DSC, foreclosing STP’s excusable delay defense and counterclaims, and resulting in a $57 million verdict, plus interest, in favor of WSDOT.
Read the court decisionRead the full story...Reprinted courtesy of
Margarita Kutsin, Ahlers Cressman & SleightMs. Kutsin may be contacted at
margarita.kutsin@acslawyers.com
A Look Back at the Ollies
May 03, 2018 —
Beverley BevenFlorez-CDJ STAFFThe Jerrold S. Oliver Award of Excellence, also known as the “Ollie” award, is presented to “an individual who is outstanding or has contributed to the betterment of the construction defect community.” West Coast Casualty asks members of the construction defect community to nominate those they feel are deserving of the award, and then members vote for one of four nominees. The award is presented at the West Coast Casualty Seminar. Those recognized receive a plaque and a donation in the winner’s name to Habitat for Humanity as well as a local California and Nevada charity.
Jerrold S. Oliver was a “’founding father’ in the alternate resolution process in construction defect claims and litigation. His loyalty and commitment to this community were beyond mere words as he was a true believer in the process of resolution.”
Past Award Winners:
1996 - Awarded to Ross R. Hart, Esq. (Mediator - American Arbitration Assoc.)
1997 - Awarded to Merv Thompson, Esq. (Mediator in private practice)
1999 - Awarded to Tom Craigo, (Adjuster - C.N.A. Insurance Company)
2000 - Awarded to Kristi Cole, (Adjuster - Safeco Insurance Company)
2001 - Awarded to Karen Rice, (Claims Manager - ACE / USA)
2002 - Awarded to Stephen Henning, Esq. (Wood, Smith, Henning and Berman, LLP)
2003 - Awarded to Ross Feinberg, Esq. (Feldscott, Lee, Feinberg, Grant and Mayfield LLP)
2004 - Awarded to Janet Shipes (Adjuster – C.N.A. Insurance Company)
2005 - Awarded to Edward Martinet (Expert – MC Consultants)
2006 - Awarded to Hon. Victoria V. Chaney (Judge – Los Angeles Superior Court)
2007 - Awarded to Bruce Edwards, Esq. (Mediator) JAMS
2008 - Awarded to Gerald Kurland, Esq. (Mediator) JAMS
2009 - Awarded to Keith Koeller, Esq. (Koeller, Nebecker, Carlson and Haluck, LLP)
2010 - Awarded to Terry Wolcott – (Construction Defect Manager – Travelers Ins. Co.)
2011 - Awarded to George Calkins, Esq. (Mediator) JAMS
2012 - Awarded to Joyia Greenfield, Esq. (Lorber, Greenfield and Polito, LLP)
2013 - Awarded to Margee Luper (Claim Manager – XL Insurance Group)
2014 - Awarded to Matt Liedle, Esq. (Liedle, Lounsbery, Larson & Lidl, LLP)
2015 - Awarded to Robert A. Bellagamba, Esq. (Special Master/Mediator, Castle & Dekker)
2016 - Awarded to Lisa Unger, (Senior Claims Examiner, Global Management Liability Markel)
2017 - Awarded to Caryn Siebert, (Vice President, Claims, Knight Insurance Group)
Read the court decisionRead the full story...Reprinted courtesy of
Eight Things You Need to Know About the AAA’s New Construction Arbitration Rules
August 19, 2015 —
Garret Murai – California Construction Law BlogI just finished a construction arbitration this past week, which also explains my sporadic posts as of late, sorry.
Coincidentally, on July 1, 2015, the American Arbitration Association (“AAA”) implemented their newly revised Construction Industry Arbitration and Mediation Procedures.
For those of you who follow our blog, you know I’m not a big fan of arbitration, which, from my experience, doesn’t deliver on its promise of better, faster, or cheaper, and ends up being pretty much the same thing as trial without the benefit of discovery, the rules of evidence, or appealability.
The AAA is trying to change all of that though and in a news release announced that its new “Rules” “directly address preferences of users for a more streamlined, cost-effective, and tightly managed arbitration process that avoids the high costs of litigation.” Which makes you wonder whether they had to survey their “users” to come to this realization. But I digress.
With the AAA’s new Rules come eight new changes, as follows:
1.Fast Track Procedures: Newly revised Rule F-1 now applies to two-party cases where no party’s claim or counterclaim exceeds $100,000. Under old Rule F-1 the monetary cap was $75,000.
Read the court decisionRead the full story...Reprinted courtesy of
Garret Murai, Wendel Rosen Black & Dean LLPMr. Murai may be contacted at
gmurai@wendel.com
Real Property Alert: Recording Notice of Default as Trustee Before Being Formally Made the Trustee Does Not Make Foreclosure Sale Void
February 18, 2015 —
Krsto Mijanovic and Annette F. Mijanovic – Haight Brown & Bonesteel LLPIn Ram, et al. v. OneWest Bank, FSB, et al. (filed 2/6/15, No. A139055), the California Court of Appeal held that a nonjudicial foreclosure sale is not void merely because the notice of default was recorded by an entity who had not yet been substituted as trustee. The court also held that because the sale was voidable, rather than void, the plaintiffs were required to allege an ability and willingness to tender their debt in addition to alleging that they were prejudiced by the irregularity in the foreclosure process.
Plaintiffs were borrowers who purchased a home subject to a deed of trust. After they defaulted on their loan, nonjudicial foreclosure proceedings were initiated, and the beneficiary of the deed of trust, OneWest Bank, FSB ("OneWest"), purchased the property at the foreclosure sale. Plaintiffs sued OneWest and other entities for wrongful foreclosure, alleging that the sale was void because the entity identified as the trustee on the notice of default, Aztec Foreclosure Corporation ("Aztec"), had not been formally substituted as trustee until after the notice of default was recorded. The trial court sustained OneWest's demurrer and plaintiff appealed.
Reprinted courtesy of
Krsto Mijanovic, Haight Brown & Bonesteel LLP and
Annette F. Mijanovic, Haight Brown & Bonesteel LLP
Mr. Mijanovic may be contacted at kmijanovic@hbblaw.com
Ms. Mijanovic may be contacted at amijanovic@hbblaw.com
Read the court decisionRead the full story...Reprinted courtesy of
The Air in There: Offices, and Issues, That Seem to Make Us Stupid
October 28, 2015 —
Eric Roston – BloombergIt's tempting to conclude from the climate change debate that all that carbon dioxide in the air is making everybody dumber.
In fact, all that carbon dioxide in the air is making everybody dumber.
Workers showed diminished cognitive functioning after spending several hours in office air that had normal levels of CO2 and chemical pollutants and ordinary ventilation, in a study published this week in Environmental Health Perspectives. Researchers tinkered with the levels of carbon dioxide and volatile organic compounds (airborne chemicals) and the amount of outside air pumped in, while the subjects did their regular work, though at a Syracuse University lab. The levels were chosen to simulate the indoor environment of conventional offices, LEED Platinum "green" buildings, and green buildings with an elevated outdoor ventilation rate ("Green+"). The 24 participants, including architects, engineers, and marketing professionals, were exposed to different conditions on different days during the six-day study, not knowing of the changes.
At 3 pm every day, the researchers administered computer-based cognitive tests of strategy-setting and focus, for example, and recorded the results and the kind of air the participants had been breathing. A day spent in the air of an extra-ventilated green building correlated with the best performance on the tests. Participants performed 61 percent better in green-building air than in conventional air, and 101 percent higher in the Green+ scenario. The research was supported in part by a United Technologies gift to Harvard's T.H. Chan School of Public Health. United Technologies, which makes building systems, wasn't involved in the experiment itself.
Read the court decisionRead the full story...Reprinted courtesy of
Eric Roston, Bloomberg
How to Fix America
July 11, 2021 —
Bloomberg CityLabIn 2011, then-President Barack Obama stood in front of the deteriorating Brent Spence Bridge linking Ohio and Kentucky with a plea to Republican leadership: Pass the jobs bill to rebuild America. (It did not pass.) Six years later, when asked about the same bridge, then-President Donald Trump answered “we’re going to get it fixed.” (It did not get fixed.)
It took two trucks colliding on the Brent Spence’s lower deck — leading to a massive fire — just before 3 a.m. on Nov. 11, 2020, for work to begin. A post-crash inspection found the bridge structurally sound, and more than $3 million in repairs were made by year-end. But with traffic volume at around double its intended capacity, much more work is needed to alleviate persistent jams and accidents.
Such has been the state of infrastructure in the U.S. for decades — fixes get put off until they’re absolutely necessary, and U.S. airports, roads and public transportation draw frequent comparisons to those in nations with far fewer resources. Meanwhile, countries in Europe, Asia and the Middle East have leapt ahead with so-called smart cities, high-speed trains and eco-friendly buildings. In 2019, the U.S. ranked 13th in the world in a broad measure of infrastructure quality — down from fifth place in 2002, according to the World Economic Forum’s Global Competitiveness Report.
Read the court decisionRead the full story...Reprinted courtesy of
Bloomberg
Fannie Mae, Freddie Mac Shares Fall on Wind-Down Measure
March 12, 2014 —
Clea Benson and Cheyenne Hopkins – BloombergCommon shares of Fannie Mae and Freddie Mac experienced their biggest intraday drop in 10 months after leaders of the Senate Banking Committee announced plans to eliminate the companies in a new bill.
Fannie Mae shares tumbled as much as 44 percent, paring the losses to 31 percent to close in New York at $4.03, after Edwin Groshans, a managing director at Washington-based equity research firm Height Analytics LLC, described the proposal as holder-negative. Freddie Mac fell 27 percent to close at $4.04. Preferred shares also dropped, some by as much as 12 percent.
The bipartisan measure, drafted with input from President Barack Obama’s administration, would replace the U.S.-owned mortgage financiers with government bond insurance that would kick in only after private capital suffered losses of at least 10 percent, Senate Banking Committee Chairman Tim Johnson and Senator Mike Crapo said in a statement today. The bill would require most borrowers to make down payments of at least 5 percent.
Ms. Benson may be contacted at cbenson20@bloomberg.net; Ms. Hopkins may be contacted at chopkins19@bloomberg.net
Read the court decisionRead the full story...Reprinted courtesy of
Clea Benson and Cheyenne Hopkins, Bloomberg
Colorado House Bill 1279 Stalls over 120-day Unit Owner Election Period
April 20, 2017 —
Luke Mecklenburg - Snell & Wilmer Real Estate Litigation BlogWith the session more than halfway through, the Colorado Legislature’s 2017 attempts at meaningful construction defect reform may fail again. This year, the Legislature did not attempt a single-bill construction defect overhaul like those that have failed over the last half-decade. Rather, it has sought to enact reforms on a piecemeal basis, with several smaller bills addressing specific issues that have been affecting condominium construction along Colorado’s booming Front Range.
This new approach appears to be headed towards much the same outcome as the failed efforts of the past. House Bill 1169 would have given developers a statutory right to repair before being sued by homeowners, and Senate Bill 156 would mandate arbitration or mediation. Both have been assigned to the House State, Veterans, and Military Affairs Committee (often viewed as the “bill-kill committee”), and have little chance of being resuscitated this session.
This was also the fate of House Bill 1279, but bipartisan support had many believing that it still had a chance of passing—at least until last week. House Bill 1279 would require an executive board of a homeowners association to satisfy several prerequisites before suing a developer or builder, namely to (1) notify all unit owners and the developer or builder against whom the lawsuit is being considered; (2) call an association meeting where the builder or developer could present relevant facts and arguments; and (3) get approval from the majority of the unit owners after providing detailed disclosures about the lawsuit, including the potential costs and benefits thereof.
Read the court decisionRead the full story...Reprinted courtesy of
Luke Mecklenburg, Snell & WilmerMr. Mecklenburg may be contacted at
lmecklenburg@swlaw.com
