Fairfield Connecticut Building Expert Directory

Georgia Local Government Drainage Liability: Nuisance and Trespass

November 29, 2021 — David R. Cook Jr. - Autry, Hall & Cook, LLP
A long-running dispute between a landowner and a municipality has escalated to the Georgia Court of Appeals and in the federal court for the Northern District of Georgia.[1] The municipality maintained a stormwater system that discharged on property uphill from the landowner’s property. The uphill property was used as an illegal dump, and debris washed downhill from the dump to the landowner’s property. The debris clogged the landowner’s surface water drainage system, which caused flooding of the property and a building. State Case The landowner sued for trespass, nuisance, takings, and inverse condemnation. While the other claims were barred by the four-year statute of limitations, the court addressed the plaintiff-landowner’s claim for continuing nuisance. Municipalities may be liable when they negligently construct or maintain a sewer or drainage system that causes repeated flooding of property, such that it results in a continuing, abatable nuisance.[2] For a municipality to be liable for maintenance of a nuisance:

the municipality must be chargeable with performing a continuous or regularly repetitious act, or creating a continuous or regularly repetitious condition, which causes the hurt, inconvenience or injury; the municipality must have knowledge or be chargeable with notice of the dangerous condition; and, if the municipality did not perform an act creating the dangerous condition, . . . the failure of the municipality to rectify the dangerous condition must be in violation of a duty to act.[3]

Read the court decision
Read the full story...
Reprinted courtesy of David R. Cook Jr., Autry, Hall & Cook, LLP
Mr. Cook may be contacted at cook@ahclaw.com

The Sky is Falling! – Or is it? Impacting Lives through Addressing the Fear of Environmental Liabilities

March 30, 2016 — John Van Vlear and Karl Foster – Newmeyer & Dillion, LLP
Six months ago, a couple anxiously relayed to N&D lawyers how the sky was falling – with environmental liabilities at the center of their seemingly real Chicken Little fears. The couple owned two properties in a central California town, one being a former gas station which an oil company had abandoned alleging the lease was void given partial eminent domain actions. Before interviewing us, the couple had spent in excess of $100,000 in legal fees with another law firm trying to force the oil company to take responsibility for potential environmental impacts under the disputed lease. Reprinted courtesy of John Van Vlear, Newmeyer & Dillion, LLP and Karl Foster, Newmeyer & Dillion, LLP Mr. Van Vlear may be contacted at john.vanvlear@ndlf.com. Mr. Foster may be contacted at karl.foster@ndlf.com Read the court decision
Read the full story...
Reprinted courtesy of

Washington Court Tunnels Deeper Into the Discovery Rule

July 09, 2019 — Lian Skaf - The Subrogation Strategist
Often times, properly analyzing when a statute of limitations begins to run – not just how long it runs – is crucial to timely pleading. In Dep’t of Transp. v. Seattle Tunnel Partners, 2019 Wash.App. LEXIS 281 (Was. Ct. App. Feb. 5, 2019), Division Two of the Court of Appeals of Washington addressed when the discovery rule starts the statute of limitations clock on a negligence cause of action. The court held that the statute of limitations begins to run when the plaintiff knows that the factual elements of the claim against the defendant exist. The clock starts to run even if the plaintiff wants to investigate the possibility of other contributing factors or the defendant identifies opposing viewpoints on the theory of the claim. In this matter, the Washington State Department of Transportation (WSDOT) contracted with an engineering firm, WSP USA, Inc. (WSP), for an evaluation of the Alaskan Way Viaduct in 2001. As part of this project, WSP retained the services of Shannon and Wilson (S&W), another engineering firm, to conduct geological profile logs, groundwater-pumping tests, and prepare technical memoranda. In 2002, WSP and S&W installed a pumping well with an eight-inch steel casing (TW-2). In 2009, apparently based on the work done by WSP and S&W, WSDOT determined that a bored underground tunnel was the best option for replacing the viaduct. Read the court decision
Read the full story...
Reprinted courtesy of Lian Skaf, White and Williams LLP
Mr. Skaf may be contacted at skafl@whiteandwilliams.com

South Carolina Legislature Defines "Occurrence" To Include Property Damage Arising From Faulty Workmanship

May 26, 2011 — Tred R. Eyerly - Insurance Law Hawaii

On May 17, 2011, South Carolina passed legislation to combat the restrictive interpretation of what constitutes an "occurrence" under CGL policies. S.C. Code Ann. sec. 38-61-70.

The legislation reversed a decision by the state's Supreme Court issued earlier this year. See Crossman Communities of North Carolina, Inc. v. Harleysville Mut. Ins. Co., 2011 W.L. 93716 (S.C. Jan. 7, 2011). Crossman had overruled an earlier decision by the South Carolina Supreme Court that holding that defective construction was an “occurrence.” Crossman, however, reversed course, holding that damages resulting from faulty workmanship were the “natural and probable cause” of the faulty work and, as such, did not qualify as an “occurrence.”

Read the full story…

Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii. Mr. Eyerly can be contacted at te@hawaiilawyer.com

Read the court decision
Read the full story...
Reprinted courtesy of

Delays Caused When Government (Owner) Pushes Contractor’s Work Into Rainy / Adverse Weather Season

January 13, 2020 — David Adelstein - Florida Construction Legal Updates
There are a number of horizontal construction projects where a contractor’s sequence of work and schedule is predicated on avoiding the rainy season (or certain force majeure events). The reason is that the rainy season will result in delays due to the inability to work (and work efficiently) during the adverse weather (including flooding caused by the weather). If the work is pushed into the rainy season, is such delay compensable if the government (or owner) delayed the project that pushed work out into the rainy season? It very well can be. For example, in Meridian Engineering Co. v. U.S., 2019 WL 4594233 (Fed. Cl. 2019), a contractor was hired by the Army Corps of Engineers to construct a flood control project for a channel in Arizona. Due to delays, including those caused by the government, the project was pushed into the monsoon season, which caused additional delays largely due to flooding caused by the heavy rain. One issue was whether such delays were compensable to the contractor – the government raised the argument that the contractor assumed the risk of potential flooding from the rainy season. The Court found this argument unconvincing:

[The contractor’s] initial construction schedule planned for a completion of the channel invert work, a necessary step in protecting the site from flooding, to be completed by late June 2008…[M]any issues arose in the project’s early stages that led to cumulative substantial delay, including those caused by the government’s failure….The government cannot now claim that [the contractor] assumed the risk of flooding from monsoon season when the government was largely responsible for [the contractor’s] inability to complete the project prior to the beginning of the monsoon season. Simply put, the government cannot escape liability for flood damages when the government is responsible for causing the contractor to be working during the flood-prone season. Meridian Engineering, 2019 WL at *7 (internal citations omitted)

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Insurer Must Pay Portions of Arbitration Award Related to Faulty Workmanship

October 21, 2019 — Tred R. Eyerly - Insurance Law Hawaii
The court determined that portions of an arbitration award against the insured contractor based upon faulty workmanship were covered by the policy. Wallace v. Nautilus Ins. Co., 2019 U.S. Dist. LEXIS 122219 (D. N. H. July 23, 2010). Plaintiffs, owners of adjoining homes, hired McPhail Roofing, LLC to replace the roofs of their houses. After installation, the plaintiffs found several problems with their roofs and withheld roughly a third of the agreed-upon contract price from final payments due to McPhail. A roofing consultant found evidence of water leaking through both roofs during rainstorms. Improper installation of the shakes on the roofs allowed rain to seep through to the roof decks (the plywood underneath the roofs) and eventually into the houses. The only way to cure the installation defects was to remove and replace the roofs entirely. Plaintiffs and McPhail went to arbitration. Plaintiffs sought compensation for the damage caused by the leaking and for the replacement costs of the roofs. McPhail sought the remaining payment under the contracts. Nautilus defended McPhail under this CGL policy. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

NAHB Examines Single-Family Detached Concentration Statistics

April 01, 2014 — Beverley BevenFlorez-CDJ STAFF
In the National Association of Builders’ (NAHB) publication Eye on Housing, the NAHB examined “the share of homeowners living in single-family detached housing” statistics as reported in the 2012 American Community Survey (ACS). Wausau, Wisconsin had the highest share of homeowners living in single-family detached housing within a metropolitan area. Interestingly, NAHB found that “[w]ith the exception of Modesto, CA, all of the metropolitan areas in the top ten [were] located in the Midwest.” The New York-White Plains-Wayne (New York) division had the lowest share of homeowners living in single-detached housing. Read the court decision
Read the full story...
Reprinted courtesy of

Real Estate & Construction News Roundup (7/31/24) – International Homebuying Shrinks Commercial Real Estate Focus on Sustainability, and U.S. Banks Boost Provisions for Credit Losses

September 09, 2024 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
In our latest roundup, mortgage rates drop to lowest levels since March, hotel construction activity highest since February 2023, Biden administration calls for legislation regarding property owners, and more!

International buyers bought 54,300 existing homes from April 2023 to March 2024 – a 36% drop from the year before. (Diana Olick, CNBC)
The Biden administration called on Congress to pass legislation penalizing property owners for rent increases above a certain level as part of its plan to lower housing costs through a series of administrative actions. (Mary Salmonsen, Multifamily Dive)
U.S. banks have boosted their provisions for credit losses as deteriorating commercial real estate (CRE) loans and high interest rates fuel fears of defaults. (Manya Saini, Niket Nishant and Matt Tracy, Reuters)

Read the court decision
Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES