SEATTLE WASHINGTON BUILDING EXPERT
DIRECTORY AND CAPABILITIES

No Damage for Delay? No Problem: Exceptions to the Enforceability of No Damage for Delay Clauses

October 18, 2021 — Chris Broughton, Jones Walker LLP - ConsensusDocs
Introduction: Under a no-damage-for-delay clause, the owner is not liable for any monetary damages resulting from delays on the project. In lieu of monetary recovery, the contractor’s remaining remedy is a non-compensatory time extension. These clauses are common at the contractor-subcontractor interface as well. While no-damage-for-delay clauses are enforced in most jurisdictions, some states, either by statute or case law, have limited the enforceability of no-damage-for-delay clauses. Other states have also limited the enforceability of these clauses on state government contracts, and a select few have outlawed them on all projects regardless if they are publicly or privately owned. Additionally, for subcontractors on federal projects, the Miller Act may provide a way to avoid no-damage-for-delay and recover against the general contractor’s payment bond. This article provides an overview of no-damage-for-delay clauses and the exceptions to enforcement of these clauses. However, due to the consequences of a no-damage-for-delay clause, it is important to know the terms of your contract and the law that governs your project. Read the court decision
Read the full story...
Reprinted courtesy of Chris Broughton, Jones Walker LLP
Mr. Broughton may be contacted at cbroughton@joneswalker.com

---

Rhode Island Finds Pollution Exclusion Ambiguous, Orders Coverage for Home Heating Oil Leak

March 06, 2023 — Kayla S. O'Connor - Saxe Doernberger & Vita, P.C.
The Rhode Island case of Regan Heating and Air Conditioning, Inc. v. Arbella Protection Insurance Company, Inc., et. al.1 provides much-needed guidance regarding ambiguity and the term “pollution.” In Regan, the Rhode Island Supreme Court held that a pollution exclusion contained in the Plaintiff’s “Commercial Package Policy” was ambiguous as to whether home heating oil that escaped into a customer’s basement constituted a “pollutant” under the policy. This case stems from a 2015 incident wherein Regan was in the process of removing an older heating system and installing a new heating system in a customer’s home when that customer discovered 170 gallons of home heating oil in his basement. The customer sued Regan, alleging negligence and demanding remediation for the property damage caused by the oil leak. Read the court decision
Read the full story...
Reprinted courtesy of Kayla S. O'Connor, Saxe Doernberger & Vita, P.C.
Ms. O'Connor may be contacted at KOconnor@sdvlaw.com

---

California Appellate Court Rules That Mistakenly Grading the Wrong Land Is Not an Accident

June 27, 2022 — Jared De Jong & Scott S. Thomas - Payne & Fears
In a decision that further muddies the already murky waters of “occurrence” jurisprudence, the California Court of Appeal has ruled that a general liability policy does not cover a homeowner who mistakenly grades the wrong piece of land because the act of grading land is not “accidental.” In Ghukasian v. Aegis Security Insurance Company, ___ Cal. App. 5th ___, 2022 WL 1421511 (2022), a homeowner instructed her contractor to clear and level a piece of land that the homeowner believed was part of her property. Unfortunately, the land was owned by a neighbor, who sued the homeowner and the contractor for trespass and negligence. The homeowner tendered to her insurer, Aegis. The homeowner’s policy contained a standard insuring agreement creating coverage for property damage caused by an “occurrence,” defined by the policy as an “accident, including continuous or repeated exposure to substantially the same general harmful conditions.” The insurer denied coverage, arguing that intentionally grading land is not an accident. Coverage litigation ensued. Reprinted courtesy of Jared De Jong, Payne & Fears and Scott S. Thomas, Payne & Fears Mr. De Jong may be contacted at jdj@paynefears.com Mr. Thomas may be contacted at sst@paynefears.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Wendel Rosen Construction Attorneys Recognized by Super Lawyers

July 30, 2018 — Garret Murai - California Construction Law Blog
Wendel Rosen Construction Practice Group Co-Chairs, Garret Murai and Quinlan Tom, have been selected for inclusion as 2018 Northern California Super Lawyers in the area of Construction Litigation. Murai and Tom are among 26 other attorneys at the firm who were selected as either 2018 Northern California Super Lawyers or Rising Stars by Thompson Reuters. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel, Rosen, Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

---

11th Circuit Affirms Bad Faith Judgement Against Primary Insurer

July 24, 2023 — Ashley Kellgren - Traub Lieberman Insurance Law Blog
In American Builders Insurance Co. v. Southern-Owners Ins. Co., 2023 U.S. Dist. LEXIS 15386, No. 21-13496 (11th Cir. June 20, 2023), the Eleventh Circuit affirmed a bad faith judgment against a primary insurer. On April 1, 2019, Ernest Guthrie fell from a roof, causing him to became paralyzed from the waist down. At the time of the accident, Guthrie was employed by his own subcontracting company and was performing work for Beck Construction. Beck Construction was insured under a general liability policy issued by American Builders and an excess policy issued by Evanston. Each of those policies provided $1 million in liability limits. Guthrie’s company was insured under a policy issued by Southern-Owners, which provided a per occurrence limit of $1 million. Under the Southern-Owners policy, Beck Construction was an additional insured and coverage was provided to Beck Construction on a primary basis. Read the court decision
Read the full story...
Reprinted courtesy of Ashley Kellgren, Traub Lieberman
Ms. Kellgren may be contacted at akellgren@tlsslaw.com

---

New Home Construction Booming in Texas

October 24, 2022 — Jason Daniel Feld & Ron Raydon - Kahana Feld

With the rapid relocation trends of families moving to Texas, it was reported that new residential construction permits in Texas grew to a total value in excess of $2 billion and over 7,500 new construction permits in September 2022 alone. D.R. Horton lead the way with 1,139 new permits, while Lennar Homes clocked 696 new permits. Other leading homebuilders including KB Homes (239 permits) and Pulte Homes (253 permits) remained active heading into the 4th Quarter of 2022. The following is a breakdown of new permits and average home values in the 4 largest cities in Texas (Houston, Dallas, Austin and San Antonio) for September 2022:

Houston

Last month, there were approximately 340 home builders with new permits on record in the Houston area, and the following ranked as the top five total new permits:

Builder	Total Permits	Average Value
1-D.R. Horton	483	$ 129,812.00
2-Camillo Properties	190	$ 147,790.00
3-Lennar Homes	188	$ 195,503.00
4-Meritage Homes	124	$ 248,597.00
5-Wan Pacific Real Estate Development	117	$ 165,044.00

Dallas

In Dallas, there were more than 290 contractors with new residential construction activity on record with HBW last month, and the following ranked as the top five for total new permits:

Builder	Total Permits	Average Value
1-D.R. Horton	555	$ 179,430.00
2-Lennar Homes	232	$ 202,318.00
3-Trophy Signature Homes	111	$ 274,016.00
4-Bloomfield Homes	97	$ 405,235.00
5-Meritage Homes	92	$ 267,425.00

 Austin

Last month, there were nearly 125 home builders with new construction activity on record in the Austin area, and the following ranked as the top five for total new permits for the one-month period:

Builder	Total Permits	Average Value
1-Lennar Homes	150	$ 154,390.00
2-KB Homes	147	$ 253,606.00
3-D.R. Horton	99	$ 200,416.00
4-Taylor Morrison Homes	79	$ 365,183.00
5-David Weekley Homes	64	$ 436,978.00

 San Antonio

In San Antonio, there were nearly 120 contractors with new residential construction activity on record last month, and the following ranked as the top five for total new permits:

Builder	Total Permits	Average Value
1-Lennar Homes	126	$ 174,315.00
2-KB Homes	55	$ 254,109.00
3-Pulte Homes	52	$ 241,012.00
4-M/I Homes	51	$ 237,283.00
5-LGI Homes	30	$ 202,760.00

The residential construction boom is Texas does not appear to be slowing down anytime soon. With new corporations relocating corporate offices to the Lone Star State each year, we expect this trend to continue for the foreseeable future. And with increased home production, we will closely monitor the increase in construction related litigation over the next five to ten years.

The increase in market activity attracts new or inexperienced builders and tradesman, making the importance of a proactive approach to construction management all the more important. Given the labor shortages and supply chain issues. It is imperative that Texas homebuilders take extra precautions to ensure quality construction practices and oversight to minimize potential litigation.

Reprinted courtesy of Jason Daniel Feld, Kahana Feld and Ron Raydon, Kahana Feld

Mr. Feld may be contacted at jfeld@kahanafeld.com

Mr. Raydon may be contacted at rraydon@kahanafeld.com

Read the court decision
Read the full story...
Reprinted courtesy of

---

Subsurface Water Exclusion Found Unambiguous

July 14, 2016 — Tred R. Eyerly – Insurance Law Hawaii
The Eighth Circuit rejected the policyholder's appeal on the ambiguity of a subsurface water exclusion. Bull v. Nationwide Mut. Fire Ins. Co., 2016 U.S. App. LEXIS 9703 (8th Cir. May 27, 2016). Michael Bull, the insured, experienced a leak from a buried pipe beneath his garage slab. The leak caused settling and mold, including the settling and cracking of his foundation, a brick walkway, and interior walls. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Building 47 Bridges in Two Years

December 23, 2023 — Dan Sopczak - Construction Executive
Every construction project has its challenges, but some truly push the boundaries of what is achievable in the heavy civil industry. When the Indiana Department of Transportation sought to modernize its I-65/I-70 North Split Interchange in Indianapolis, Indiana, its request for proposals included building 47 new bridges and rehabilitating six additional bridges on an ambitious two-year timeline—905 days to substantial completion. “Three design-build teams responded to the RFQ, and the same three teams responded to the RFP,” according to INDOT Strategic Communications Director Natalie Garrett. “Proposals were scored and evaluated using the best-value evaluation process defined by INDOT. The score was a combination of a technical proposal score and a price score.” Reprinted courtesy of Dan Sopczak, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

---