Cambridge Massachusetts Building Expert Directory

Construction Contract Basics: No Damages for Delay

May 06, 2024 — Christopher G. Hill - Construction Law Musings
After WAY too long a hiatus, I am back with another in my series of “Construction Contract Basics” posts. In past posts, I’ve covered venue provisions, attorney fee provisions, and indemnity clauses. In this post, I’ll share a few thoughts (or “musings”) on the topic of so-called “no damages for delay” clauses. These clauses essentially state that a subcontractor’s only remedy for a delay caused by any factor beyond its control (including the fault of the general contractor), after proper notice to the owner or general contractor, is an extension of time to complete the work. These types of clauses generally make it impossible for a subcontractor (if found in a Subcontract) or Contractor (if found in a Prime Contract) that is delayed through no fault of its own to recover any damages relating to the expenses that are inevitably caused by such delays. Such expenses/damages could include additional supervisory time (including more high-dollar superintendent payments), acceleration costs, demobilization/mobilization costs, and other related expenses. These can add up to real money. Couple that with the inevitable liquidated damages or delay damages that will occur should a contractor or subcontractor cause any delay, and this becomes a very one-sided proposition. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Putting for a Cure: Don’t Forget to Visit BHA’s Booth at WCC to Support Charity

April 28, 2016 — Beverley BevenFlorez-CDJ STAFF
Bert L. Howe & Associates, Inc., (BHA) is excited to announce the return of their very popular Sink a Putt for Charity at the 2016 West Coast Casualty Construction Defect Seminar. This year, participant’s efforts on the green will help benefit the Susan G. Komen Race for the Cure. As in years past, sink a putt in the BHA golf challenge and win a $25 gift card, and for every successful putt made, BHA will make a $25 cash donation in the golfer’s name to the Susan G. Komen Foundation. But it doesn’t stop there. Breast cancer touches so many lives, with wives, mothers, sisters, aunts, cousins and daughters all affected by this insidious disease. To further assist in their noble fight, BHA is doubling down. During three Championship Rounds on Thursday morning, afternoon, and evening, BHA will up the ante. For every putt ATTEMPTED (sink or miss), BHA will make a $50 donation to Susan G. Komen, and for every putt MADE, the golfer will also win a $50 gift card. These Championship Rounds will occur during the Thursday morning break, the afternoon break, and during the first hour of the Thursday evening cocktail party. Bert L. Howe & Associates, Inc., strongly supports the goals and principles of the Susan G. Komen Race for the Cure, and is honored to assist in fulfilling its mission of supporting research, community health, global outreach and public policy initiatives. While at the booth, don’t forget to test out BHA’s industry leading data collection and inspection analysis systems. BHA has recently added video overviews to their data collection process, as well as next-day viewing of inspection data via their secured BHA Client Access Portal. Discover meaningful cost improvements that translate to reduced billing while providing superior accuracy and credibility. Attendees can also enter to win Dodger baseball tickets or one of three new iPad Pros! Other BHA giveaways include USB charging blocks, pocket tape measures, multi-tools, laser pointers, foam stress balls, and Callaway golf balls. For more information on the Susan G. Komen Foundation, please visit their website. Read the court decision
Read the full story...
Reprinted courtesy of

Breaking News: Connecticut Supreme Court Decides Significant Coverage Issues in R.T. Vanderbilt

December 16, 2019 — Patricia B. Santelle & Ciaran B. Way - White and Williams LLP
On October 4, 2019 (almost two years after granting certification), the Connecticut Supreme Court affirmed the Appellate Court’s rulings on four key coverage issues in R.T. Vanderbilt Company v. Hartford Accident & Indemnity Company, et al. The coverage dispute in Vanderbilt concerns underlying actions alleging that talc and silica mined and sold by the insured contained asbestos and/or caused asbestos-related disease. The case has been proceeding in phases, two of which have been tried to date, resulting in the matter on appeal. (1) “Continuous Trigger” Theory of Coverage Applies: The Court affirmed and adopted the Appellate Court’s opinion applying a “continuous trigger” for the underlying claims at issue, and agreed that the trial court properly excluded testimony from medical experts the insurers had proffered to prove that the asbestos disease process did not support a continuous trigger. (2) The “Unavailability of Insurance” Exception to Time-on-Risk Pro Rata Allocation Applies: The Court affirmed and adopted the Appellate Court’s ruling that (a) damages and defense costs should not be allocated to any period in which insurance was “unavailable” in the market, (b) the insurers bear the burden of proving that coverage for asbestos liabilities was available to the policyholder after the date asbestos exclusions were added to the policies and (c) the insured bears the burden of proving that it was unable to obtain asbestos coverage prior to 1986 (when such insurance was generally available). The Appellate Court recognized that, in certain circumstances, there could be an “equitable exception” to the unavailability rule if the insured continued to manufacture products containing asbestos after 1986 with the knowledge that such products were hazardous and uninsurable (circumstances which the court found were not present in this case). Reprinted courtesy of Patricia B. Santelle, White and Williams LLP and Ciaran B. Way, White and Williams LLP Ms. Santelle may be contacted at santellep@whiteandwilliams.com Ms. Way may be contacted at wayc@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

After Fatal House Explosion, Colorado Seeks New Pipeline Regulations

May 10, 2017 — Mark Shaw - Engineering News-Record
Colorado Gov. John Hickenlooper (D) has ordered comprehensive inspections, along with new monitoring and testing procedures, for all oil and gas pipelines located near houses and other buildings across the state. The action follows an April gas explosion in a northern Colorado home that killed two people. Read the court decision
Read the full story...
Reprinted courtesy of Mark Shaw, ENR
Mr. Shaw may be contacted at shawm@enr.com

Henkels & McCoy Pays $1M in Federal Overtime-Pay Case

July 19, 2021 — Tom Ichniowski - Engineering News-Record
In a consent judgment in a federal labor case, major specialty contractor Henkels & McCoy Inc. has paid about $1.1 million in back pay and damages for allegedly not paying required overtime wages to 362 current and former workers in five states, the U.S. Dept. of Labor says. Reprinted courtesy of Tom Ichniowski, Engineering News-Record Mr. Ichniowski may be contacted at ichniowskit@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

New Mexico Architect Is Tuned Into His State

February 08, 2021 — David M. Brown - Engineering News-Record
For 40-plus years, Van Gilbert has combined his love for the topography, history and culture of New Mexico with an equally passionate dedication to designing not just structures, but buildings that help create communities. Reprinted courtesy of David M. Brown, Engineering News-Record ENR may be contacted at ENR.com@bnpmedia.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Court Makes an Unsettling Inference to Find that the Statute of Limitations Bars Claims Arising from a 1997 Northridge Earthquake Settlement

April 15, 2015 — David W. Evans and Stephen J. Squillario – Haight Brown & Bonesteel LLP
In Britton v. Girardi (No. B249232 – Filed 4/1/2015), the Second Appellate District upheld the trial court’s dismissal due to the statute of limitations based on an inference it drew from a letter attached to the complaint, while reaffirming its prior application of the limitations period in Probate Code section 16460 for fraud claims in the related case of Prakashpalan v. Engstrom, Lipscomb & Lack (2/27/2014) 223 Cal.App.4th 1105. In Britton, just as in Prakashpalan, the plaintiffs sued the attorneys who had represented them in connection with claims against their insurer arising out of the Northridge earthquake. In 1997, the attorneys had settled that litigation for more than $100 million. The plaintiffs allege that the attorneys breached their fiduciary duty by (1) failing to provide an accounting for the settlement, (2) failing to obtain their informed consent to the settlement, and (3) concealing their misappropriation of the settlement funds. They claim that they did not discover this wrongdoing until nearly fifteen years later, in 2012, when the Prakashpalans contacted them about their settlement. Significantly, the plaintiffs attached as an exhibit to the complaint a page of the November 3, 1997 letter to the Prakashpalans (rather than the plaintiffs), which stated that a retired judge who presided over the settlement had determined the allocations and the attorneys could not distribute the proceeds until the plaintiffs signed the “Master Settlement Agreement” by which the plaintiffs agreed to its terms and to give up all claims against the insurer. Reprinted courtesy of David W. Evans, Haight Brown & Bonesteel LLP and Stephen J. Squillario, Haight Brown & Bonesteel LLP Mr. Evans may be contacted at devans@hbblaw.com Mr. Squillario may be contacted at ssquillario@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

California Attempts to Tackle Housing Affordability Crisis

December 22, 2019 — Garret Murai - California Construction Law Blog
It’s a bit too early yet for our 2020 Construction Law Update but here’s a preview of some of the new laws taking effect next year. Earlier this month, Governor Gavin Newsom signed a slate of 18 bills to boost housing production in an effort to tackle the state’s housing affordability crisis. First, a bit of background. California currently ranks 49th among the states in housing units per resident. Experts say that the state needs to double its current rate of housing production of 85,000 unit per year just to keep up with population growth and four times the current rate to reduce housing costs. Anecdotally, here in the San Francisco Bay Area, the median rent for a one-bedroom apartments in San Francisco is currently $3,690 per month or $44,280 per year. However, as of May 2018, according to the U.S. Bureau of Statistics, the annual mean wage of a teller is just $32,840, for farmworkers $34,700, and for teachers $48,250. And that’s before taxes. Let that sink in for a moment. The result is one in five Californians live in poverty, the highest rate in the nation, when factoring in the cost of living. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES