How the Cumulative Impact Theory has been Defined
November 30, 2020 —
David Adelstein - Florida Construction Legal UpdatesLargely in the federal contract arena, there is a theory referred to as “cumulative impacts” used by a contractor to recover unforeseeable costs associated with a multitude of changes that have an overwhelming ripple effect on its efficiency, particularly efficiency dealing with its original, base contract work. In other words, by dealing with extensive changes, there is an unforeseeable impact imposed on the contractor relative to its unchanged or base contract work. Under this theory, the contractor oftentimes prices its cumulative impact under a total cost approach with an examination on its cost overrun. However, this is not an easy theory to prevail on because there needs to be a focus on the sheer number of changes, causation supporting the impact, and whether there were concurrent impacts or delays that played a role in the ripple effect. See, e.g., Appeals of J.A. Jones Const. Co., ENGBCA No. 6348, 00-2 BCA P 31000 (July 7, 2000) (“However, in the vast majority of cases such claims are routinely denied because there were an insufficient number of changes, contractor-caused concurrent delays, disruptions and inefficiencies and/or a general absence of evidence of causation and impact.”).
To best articulate how the cumulative impact theory has been defined, I want to include language directly from courts and board of contract appeals that have dealt with this theory. This way the contractor knows how to best work with their experts with this definition in mind–and, yes, experts will be needed–to persuasively package and establish causation and damages stemming from the multitude of changes. While many of these definitions are worded differently, you will see they have the same focus dealing with the unforeseeable ripple effect of the extensive changes.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Wisconsin Federal Court Addresses Scope Of Appraisal Provision In Rental Dwelling Policy
September 05, 2022 —
James M. Eastham - Traub LiebermanIn Higgins v. State Farm Fire & Cas. Co., No. 22-C-198, 2022 U.S. Dist. LEXIS 117477 (E.D. Wis. July 5, 2022), the Court addressed the often disputed question of whether an appraisal provision in an insurance policy is limited to disputes over valuation or extends beyond valuation to causation and/or coverage. The underlying loss in the Higgins case involved a fire at a rental dwelling owned by the Plaintiff and insured by State Farm under a Rental Dwelling policy for, among other things, fire losses. Subsequent to being notified of the fire, State Farm investigated and provided the Plaintiff with its estimated cost of repair. Plaintiff disputed the estimate, including the repairs necessary, and also sought additional sums for debris removal and lost rent.
The insurance policy at issue in Higgins included an appraisal provision which provided: “If you and we fail to agree on the amount of loss, either one can demand that the amount of the loss be set by appraisal.” Pursuant to this provision, Plaintiff demanded that State Farm submit to an appraisal to resolve the parties' disagreements. State Farm responded by indicating that it would enter into appraisal over the areas where there were "pricing differences" but not areas where there were "scope differences." According to State Farm, there were a number of issues regarding the scope of repairs necessary to restore the dwelling to its pre-loss condition. Plaintiff disagreed with State Farm's position and did not seek to move forward with the appraisal process on only the items State Farm identified as appropriate for appraisal.
Read the court decisionRead the full story...Reprinted courtesy of
James M. Eastham, Traub LiebermanMr. Eastham may be contacted at
jeastham@tlsslaw.com
Lien Attaches To Landlord’s Interest When Landlord Is Party To Tenant Improvement Construction Contract
January 03, 2022 —
David Adelstein - Florida Construction Legal UpdatesIf you are a landlord / lessor, then you want to maximize the protections afforded to you under Florida’s Lien Law in Florida Statute s. 713.10. These protections are designed to protect your property from liens for improvements performed by your tenant / lessee. The intent is that if you comply with s. 713.10, then a tenant improvement contractor’s recourse is against the leasehold interest, and NOT against the interest of the real property (or your interest as the landlord / lessor). Needless to say, it is imperative that a landlord / lessor make efforts to comply with this section when a tenant is performing tenant improvements, even when the landlord is contributing money to those improvements.
Section 713.10 provides in material part:
(1) Except as provided in s. 713.12, a lien under this part shall extend to, and only to, the right, title, and interest of the person who contracts for the improvement as such right, title, and interest exists at the commencement of the improvement or is thereafter acquired in the real property. When an improvement is made by a lessee in accordance with an agreement between such lessee and her or his lessor, the lien shall extend also to the interest of such lessor.
(2)(a) When the lease expressly provides that the interest of the lessor shall not be subject to liens for improvements made by the lessee, the lessee shall notify the contractor making any such improvements of such provision or provisions in the lease, and the knowing or willful failure of the lessee to provide such notice to the contractor shall render the contract between the lessee and the contractor voidable at the option of the contractor.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Nevada Bill Would Bring Changes to Construction Defects
February 21, 2013 —
CDJ STAFFIf Nevada Senate Republicans get there way, changes are afoot for construction defect law in Nevada. Senate Minority Leader Michael Roberson has introduced a bill that, according to the Las Vegas Sun, “redefines what constitutes a construction defect, reduces the time in which lawsuits can be filed, and removed automatic awarding of attorney fees.” Roberson notes that over the last six years, construction defect claims have more than tripled.
Read the court decisionRead the full story...Reprinted courtesy of
Insurer Unable to Declare its Coverage Excess In Construction Defect Case
January 06, 2012 —
CDJ STAFFThe Ninth Circuit Court of Appeals has upheld a summary judgment in the case of American Family Mutual Insurance Co. v. National Fire & Marine Insurance Co. Several other insurance companies were party to this case. In the earlier case, the US District Court of Appeals for Arizona had granted a summary judgment to Ohio Casualty Group and National Fire & Marine Insurance Company. At the heart of it, is a dispute over construction defect coverage.
The general contractor for Astragal Luxury Villas, GFTDC, contracted with American Family to provide it with a commercial liability policy. Coverage was issued to various subcontractors by Ohio Casualty and National Fire. These policies included blanket additional insured endorsements that provided coverage to GFTDC. The subcontractor policies had provisions making their coverage excess over other policies available to GFTDC.
The need for insurance was triggered when the Astragal Condominium Unit Owners Association filed a construction defect claim in the Arizona Superior Court. CFTDC filed a third-party claim against several subcontractors. The case was settled with American Family paying the settlement, after which it filed seeking reimbursement from the subcontractor’s insurers. The court instead granted summary judgment in favor of Ohio Casualty and National Fire.
American Family appealed to the Ninth Circuit for a review of the summary judgment, arguing that the “other insurance” clauses were “mutually repugnant and unenforceable.” The Ninth Circuit cited a case from the Arizona Court of Appeals that held that “where two policies cover the same occurrence and both contain ‘other insurance’ clauses, the excess insurance provisions are mutually repugnant and must be disregarded. Each insurer is then liable for a pro rate share of the settlement or judgment.”
The court noted that unlike other “other insurance” cases, the American Family policy “states that it provides primary CGL coverage for CFTDC and is rendered excess only if there is ‘any other primary insurance’ available to GFTDC as an additional insured.” They note that “the American Family policy purports to convert from primary to excess coverage only if CFTDC has access to other primary insurance as an additional insured.”
In comparison, the court noted that “the ‘other insurance’ language in Ohio Casualty’s additional insured endorsement cannot reasonably be read to contradict, or otherwise be inconsistent with, the ‘other primary insurance’ provision in the American Family policy.” They find other reasons why National Fire’s coverage did not supersede American Family’s. In this case, the policy is “written explicitly to apply in excess.”
Finally, the Astragal settlement did not exhaust American Family’s coverage, so they were obligated to pay out the full amount. The court upheld the summary dismissal of American Family’s claims.
Read the court’s decision…
Read the court decisionRead the full story...Reprinted courtesy of
9th Circuit Plumbs Through the Federal and State False Claims Acts
January 16, 2024 —
Garret Murai - California Construction Law BlogYou may have heard of the False Claims Act and know that it penalizes companies and individuals in contract with the government who present false claims. The federal False Claims Act was signed into law by President Abraham Lincoln in 1863 to penalize profiteers during the Civil War who were selling the Union Army moth eaten blankets, boxes of sawdust instead of guns, and sometimes re-selling the Army calvary horses several times over. Since then, many states, including California, as well as municipalities, have enacted their own false claim statutes.
As currently written, the federal False Claims Act provides for statutory penalties against any person who:
- “[K]nowingly presents, or causes to be presented, a false or fraudulent claim for payment or approval”;
- “[K]nowingly makes, uses or causes to be made or used, a false record or statement material to a false or fraudulent claim”;
- “[H]as possession, custody, or control of property or money used, or to be used, by the Government an knowingly delivers, or causes to be delivered, less than all of that money or property”;
Read the court decisionRead the full story...Reprinted courtesy of
Garret Murai, Nomos LLPMr. Murai may be contacted at
gmurai@nomosllp.com
Real Estate & Construction News Roundup (7/10/24) – Strong Construction Investment in Data Centers, Increase Use of Proptech in Hospitality and Effects of Remote-Work on Housing Market
August 05, 2024 —
Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law BlogIn our latest roundup, renters stay in their units longer, GenAI change how commercial real estate operates, and banks continue high exposure due to commercial real estate.
- Strong investor interest, particularly in opportunistic and value-add segments, signals a strong market for construction firms specializing in high-yield projects. (Sebastian Obando, Construction Dive)
- A growing number of renters are staying in their units for longer periods of time than they did a decade ago with over one-third of U.S. renters have lived in the same apartment for more than five years. (Mary Salmonsen, Multifamily Dive)
- Several U.S. regional and mid-sized banks continue to face the squeeze from high exposure to the commercial real estate sector that has been shaken by higher-for-longer interest rates and empty office buildings. (Reuters)
Read the court decisionRead the full story...Reprinted courtesy of
Pillsbury's Construction & Real Estate Law Team
Breach of Fiduciary Duty Claim Against Insurer Survives Motion to Dismiss
June 10, 2015 —
Tred R. Eyerly – Insurance Law HawaiiWhile some of their claims were dismissed, plaintiffs' breach of fiduciary duty survived the insurer's motion to dismiss. Senft v. Fireman's Fund Ins. Co., 2015 U.S. Dist. LEXIS 61870 (D. N.J. May 12, 2015).
Plaintiffs' waterfront home was insured by Fireman's Fund. Plaintiffs alleged that the broker represented that the policy would provide (1) coverage in the event of a hurricane,(2) the "highest level of protection" offered by Fireman's Fund, and (3) "exceptional" services in the event of a catastrophe. The policy included a 2% hurricane deductible because of the home's proximity to the ocean.
Hurricane Sandy badly damaged plaintiffs' home. Plaintiffs alleged that the winds from Sandy battered their home long before the storm surge reached the structure.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Insurance Law HawaiiMr. Eyerly may be contacted at
te@hawaiilawyer.com
