The Little Ice Age and Delay Claims
January 24, 2018 —
Wally Zimolong - Supplemental ConditionsMuch of the Eastern United States is just now emerging from a historic two week cold snap. In much of the Northeast and Mid-Atlantic, the temperature stayed below freezing for 15 days straight. Cities recorded the lowest temperatures in a quarter century. Winter Storm Grayson reeked havoc along the Eastern Coast bringing snow to places like Charleston and a crippling blizzard to Boston.
The record cold snap also impacted the construction industry. Delivery delays, the inability to apply weather sensitive applications (like cast in place concrete), and the unavailability of labor are just a few things that extreme weather can cause on a construction project. If they happen at the wrong time, delays can destroy project schedules and make previous delays even worse. Delays cost money and can mean the difference between a profitable project from both the owner and contractors perspective.
Read the court decisionRead the full story...Reprinted courtesy of
Wally Zimolong, Zimolong LLCMr. Zimolong may be contacted at
wally@zimolonglaw.com
New York Assembly Reconsiders ‘Bad Faith’ Bill
May 31, 2021 —
Copernicus T. Gaza, Robert S. Nobel, Craig Rokuson, Eric D. Suben - Traub LiebermanThe New York State Assembly is considering A07285, which creates a private right of action for bad faith “if the insurer unreasonably refuses to pay or unreasonably delays payment without substantial justification.” The bill was first introduced in 2013 but was reintroduced on May 3, 2021 and has received some recent attention. According to the bill, an insurer acts unreasonably when it (among other things):
- Fails to provide the claimant with accurate information regarding policy provisions relating to the coverage at issue; or
- Fails to effectuate in good faith a prompt, fair, and equitable settlement of a claim or portion of a claim and where the insurer failed to reasonably accord at least equal or more favorable consideration to its insured's interests as it did to its own interests, and thereby exposed the insured to a judgment in excess of the policy limits or caused other damage to a claimant; or
- Fails to provide a timely written denial of a claimant's claim, or portion thereof, with a full and complete explanation of such denial, including references to specific policy provisions wherever possible; or
- Fails to act in good faith by compelling such claimant to initiate a lawsuit to recover under the policy by offering substantially less than the amounts ultimately recovered in such suit; or
- Fails to timely provide, on request of the policy holder or the policy holder's representative, all reports or other documentation arising from the investigation of a claim; or
- Refuses to pay a claim without conducting a reasonable investigation prior to such refusal.
Reprinted courtesy of
Copernicus T. Gaza, Traub Lieberman,
Robert S. Nobel, Traub Lieberman,
Craig Rokuson, Traub Lieberman and
Eric D. Suben, Traub Lieberman
Mr. Gaza may be contacted at cgaza@tlsslaw.com
Mr. Nobel may be contacted at rnobel@tlsslaw.com
Mr. Rokuson may be contacted at crokuson@tlsslaw.com
Mr. Suben may be contacted at esuben@tlsslaw.com
Read the court decisionRead the full story...Reprinted courtesy of
It’s Not Just the Millennium Tower That’s Sinking in San Francisco
December 06, 2021 —
Beverley BevenFlorez – CDJ StaffMuch has been reported over the years regarding the sinking Millennium Tower in San Francisco, but now new reports are emerging regarding sinking sidewalks in the Mission Bay neighborhood and images from space demonstrating that the entire Downtown San Francisco area may also be sinking.
According to CBS SF BayArea, some sidewalks in Mission Bay have sunk “as much as a foot and more in some spots.” The neighborhood is built upon a landfill, which requires the buildings to be anchored to bedrock—the streets and sidewalks, however, are the property owners’ responsibility. Engineers for the UCSF Medical Center at Mission Bay “took a proactive approach.” CBS SF BayArea alleges, however, that many surrounding condo developers did not.
SFGate reported that the sidewalk issue may be difficult to solve “as any fixes to the surface only serve to increase the weight of the pavement, speeding its descent into the landfill.”
It may not just be sidewalks and streets that are sinking. U.S Geological Survey research geophysicist Tom Parsons “says earth-based and space-based observations confirm the entire downtown area around it is sinking as well.” According to the NBC Bay Area story, Parsons “estimated settlement of three inches across the entire Bay Area.”
The Millennium Tower weighs an estimated 686 million pounds, making it the third heaviest building in San Francisco. However, it is the only one that’s significantly leaning.
San Francisco building officials told NBC Bay Area that there are plans in place “to shore up the seawall that protects the Embarcadero.”
Read the full story at CBS SF BayArea...
Read the full story at SFGate...
Read the full story at NBC Bay Area...
Read the court decisionRead the full story...Reprinted courtesy of
Ohio Supreme Court Holds No Occurence Arises from Subcontractor's Faulty Workmanship
January 09, 2019 —
Tred R. Eyerly - Insurance Law HawaiiThe Ohio Supreme Court bucked the modern trend by finding that there was no coverage under CGL policy's the subcontractor's exception for faulty workmanship claimed against the insured. Ohio N. Univ. v. Charles Constr. Servs. 2018 Ohio LEXIS 2375 (Ohio Oct. 9, 2018).
The University contracted with Charles Construction Services, Inc. to build a new luxury hotel and conference center on campus. After work was completed, the University discovered extensive water damage from hidden leaks that it believed were caused by the defective work of Charles Construction and its subcontractors. Repairs were made at the cost of $6 million.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com
Lewis Brisbois Listed as Top 10 Firm of 2022 on Leopard Solutions Law Firm Index
March 27, 2023 —
Lewis Brisbois NewsroomLos Angeles, Calif. (March 17, 2023) – Lewis Brisbois has been listed among the top 10 law firms on the 2022 Leopard Law Firm Index. Billed as "the legal industry's most inclusive and up-to-date firm rating system," the index, published by Leopard Solutions, is a dynamic rating system that is updated twice weekly and focuses on law firms' profitability, viability, growth, and potential opportunity. Each year, Leopard Solutions compiles a list of the index firms' overall scores for the previous year. For 2022, Lewis Brisbois ranked 8th, with an aggregate score of 446 out of a possible 500. Other firms in the top 10 include Kirkland & Ellis, Ropes & Gray, and DLA Piper.
The Leopard Law Firm Index provides insights into law firm health and stability, using a robust list of criteria. This includes growth in attorney headcount, average attorney tenure, increases in revenue per lawyer (RPL) over a five-year period, relative success in lateral recruiting, and general retention of partners and associates, as well as the overall diversity within a firm. In an interview with Law360 Pulse, Leopard Solutions VP of Sales & Marketing Phil Flora noted that the top 10 firms are some of the largest firms with above average ethnic diversity.
Read the court decisionRead the full story...Reprinted courtesy of
Lewis Brisbois
12 Newmeyer Dillion Attorneys Named to 2022 U.S. News Best Lawyers in Multiple Practice Areas
August 23, 2021 —
Newmeyer DillionProminent business and real estate law firm Newmeyer Dillion is pleased to announce that twelve of the firm's attorneys were recently selected for inclusion and will be recognized in their respective areas in The Best Lawyers in America© 2022. Additionally, Greg Dillion has been selected to Best Lawyers 2022 Lawyer of the Year list in Construction Law.
The twelve 2022 Best Lawyers are:
Jason Moberly Caruso,
Michael S. Cucchissi,
Jeffrey M. Dennis,
Greg L. Dillion,
Joseph A. Ferrentino,
Jon J. Janecek,
Michael B. McClellan,
Thomas F. Newmeyer,
John A. O'Hara,
Thomas H. Reilly,
Bonnie T. Roadarmel and
Jane M. Samson
Best Lawyers is the oldest peer-review publication for the legal profession. Attorneys are chosen through intensive peer-review surveys in which leading lawyers evaluate their professional peers. Best Lawyers listings are published in almost 70 countries worldwide and are recognized for their reliable and unbiased selections.
About Newmeyer Dillion
For over 35 years, Newmeyer Dillion has delivered creative and outstanding legal solutions and trial results that achieve client objectives in diverse industries. With over 60 attorneys working as a cohesive team to represent clients in all aspects of business, employment, real estate, environmental/land use, privacy & data security and insurance law, Newmeyer Dillion delivers holistic and integrated legal services tailored to propel each client's operations, growth, and profits. Headquartered in Newport Beach, California, with offices in Walnut Creek, California and Las Vegas, Nevada, Newmeyer Dillion attorneys are recognized by The Best Lawyers in America©, and Super Lawyers as top tier and some of the best lawyers in California and Nevada, and have been given Martindale-Hubbell Peer Review's AV Preeminent® highest rating. For additional information, call 949.854.7000 or visit www.newmeyerdillion.com.
Read the court decisionRead the full story...Reprinted courtesy of
Playing Hot Potato: Indemnity Strikes Again
September 17, 2015 —
Garret Murai – California Construction Law BlogIndemnity can be like playing hot potato (for those of you closer to the Minecraft generation, in the game of hot potato, a metaphoric “hot potato” is tossed between (ahem amongst) players while music is playing, and when the music stops, the player holding the hot potato is out. It’s a barrel of monkeys, trust me.).
Anyway, like hot potato, with indemnity an owner typically requires its general contractor to indemnify the owner (sometimes the property owner in TI projects and occasionally design professionals) from and against any and all claims arising out of, related to . . . blah, blah, blah . . . the general contractor’s scope of work . A general contractor in turn will usually require indemnity from its subcontractors. And subcontractors will require indemnity from their sub-subcontractors. And down the line it goes with each party pointing their finger at the next party down the proverbial “food chain.”
But it doesn’t always happen that way as the next case, American Title Insurance Company v. Spanish Inn, Case No D067137, California Court of Appeals for the Fourth District (August 14, 2015), illustrates.
Read the court decisionRead the full story...Reprinted courtesy of
Garret Murai, Wendel Rosen Black & Dean LLPMr. Murai may be contacted at
gmurai@wendel.com
Protect Your Right To Payment By Following Nedd
August 03, 2022 —
Denise Motta - Gordon & Rees Construction Law BlogIn order to preserve your right to payment, you must satisfy the contractual requirements supporting a change order for the increased costs or time due to the delay. The key to the successful presentation of change order claims is educating your team on the following:
1. NOTICE
- Review the change order and notice provisions of your contracts. Make your contract searchable and insert the term “Noti” and look for the items listed below.
- Who: Check the designated representative for notice.
- It may not be the project manager.
- Confirm who can authorize the change order.
- Is owner approval required?
- Ensure that the party approving the change order has authority to do so.
- What: Check for specific information required by the contract.
- Provide ALL information available.
- If certain information is not yet available, state that the information will be provided when available.
- Reserve all rights to amend and submit additional information.
- Request both an increase to the Contract Sum and Contract Time.
- Make the request even if you do not believe the delay or time necessary will cause a significant impact.
Read the court decisionRead the full story...Reprinted courtesy of
Denise Motta, Gordon Rees Scully Mansukhani, LLPMs. Motta may be contacted at
dmotta@grsm.com