Cambridge Massachusetts Building Expert Directory

Takeaways From Schedule-Based Dispute Between General Contractor and Subcontractor

September 09, 2024 — David Adelstein - Florida Construction Legal Updates
A recent opinion out of the Southern District of Florida, Berkley Insurance Co. v. Suffolk Construction Co., Case 1:19-cv-23059-KMW (S.D.Fla. July 22, 2024), provides valuable takeaways on schedule-based disputes between a general contractor and subcontractor on a high-rise project. In a nutshell, the general contractor’s original project schedule was abandoned due to project delays and the project wasn’t being built by any updated project schedule. The subcontractor claimed the general contractor was mismanaging the schedule putting unreasonable manpower and supervision constraints on it, i.e., it was working inefficiently. A bench trial was conducted and the Court found in favor of the subcontractor’s arguments. The Court found the general contractor had unrelated delays and that work activities were no longer methodical but, simply, piecemeal demands. The Court also rejected any inadequate manpower arguments finding the subcontract did not place any manpower requirements on the subcontractor. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

U.S. Home Prices Climbed 0.1% in July as Gains Slowed

September 24, 2014 — Prashant Gopal – Bloomberg
U.S. home prices rose less than economists estimated in July as investors pull back from the property market. Prices climbed 0.1 percent on a seasonally adjusted basis from June, the Federal Housing Finance Agency said today in a report from Washington. The average economist estimate was for a 0.5 percent increase, according to data compiled by Bloomberg. Investors who helped drive up prices are retreating as fewer foreclosures and other discounted homes become available. All-cash purchases in August fell to about 23 percent of the market from the usual 33 percent, the National Association of Realtors reported yesterday. Investors accounted for 12 percent, the least since late 2009. Read the court decision
Read the full story...
Reprinted courtesy of Prashant Gopal, Bloomberg
Mr. Gopal may be contacted at pgopal2@bloomberg.net

Texas Law Bars Coverage under Homeowner’s Policy for Mold Damage

July 13, 2011 — Tred R. Eyerly - Insurance Law Hawaii

Although the insurer paid for some of the mold damage at the insured’s home, the Fifth Circuit eventually determined the homeowner’s policy did not cover such damage. Rooters v. State Farm Lloyds, 2011 U.S. App. LEXIS 12306 (5th Cir. June 15, 2011).

The policy excluded loss caused by hail to personal property unless the direct force of wind or hail made an opening in the roof allowing rain to enter. Further, the policy excluded loss caused by mold or other fungi.

In 1999, hail and rain caused water damage to the roof and interior of the residence. State Farm paid $19,000 to repair the roof. Another $1,800 was paid for repairs to the interior of the building. In 2002, the insured noticed black mold. State Farm issued an additional check for $4,402 for mold abatement.

Read the full story…

Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii. Mr. Eyerly can be contacted at te@hawaiilawyer.com

Read the court decision
Read the full story...
Reprinted courtesy of

Latest Updates On The Coronavirus Pandemic

March 30, 2020 — ENR Editors - Engineering News-Record
Coronavirus has struck a heavy blow against the world economy as it forces countries into lockdown with "closed for business" signs, hollows out the tourism, travel and hospitality sectors, turns out the lights on business gatherings and events, sends employees home to work and drives the stock market into a dizzying tumble. ENR Editors ENR may be contacted at ENR.com@bnpmedia.com Read the full story for ENR's ongoing reporting, analysis and commentary on construction sector developments Read the court decision
Read the full story...
Reprinted courtesy of

Security on Large Construction Projects. The Payment Remedy You Probably Never Heard of

May 07, 2015 — Garret Murai – California Construction Law Blog
California has a number of statutory payment remedies available on construction projects. Some, such as the mechanics lien, are relatively well known and often utilized. Others, such as the stop payment notice, are somewhat less so. However, there’s one statutory payment remedy you may not have heard of at all. And that is, security requirements for large projects. What is security for large projects? Security is required on certain large construction projects to guarantee the payment by owners to direct contractors, and applies if either: 1. Fee Interest and Contract of Greater Than $5 million: The owner contracting for a work of improvement holds a fee interest in the property being improved and enters into a construction contract for the improvement of the property greater than $5 million; or 2. Less Than Fee Interest, Including Leasehold Interest, and Contract of Greater Than $1 million: The owner contracting for a work of improvement holds less than a fee interest (including a leasehold interest) in the property being improved and enters into a construction contract for the improvement of the property greater than $1 million. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

Estoppel Certificate? Estop and Check Your Lease

May 06, 2019 — Lauren Podgorski - Snell & Wilmer Real Estate Litigation Blog
If you are leasing space in a building, there may come a time when you receive a request from your landlord to fill out and sign an estoppel certificate. Estoppel certificates are usually sent to tenants in connection with the sale or refinance of a building, and a third party may rely on the accuracy of the statements and information contained in the estoppel certificate in connection with that transaction. Estoppel certificates can range from a very simple, one-page document, to several pages. I’ve received an estoppel certificate in the mail. What do I do now? Consider the following: Check your lease. Your lease may require you to deliver the signed estoppel certificate and may even give you a timeframe within which you are required to return it. A form of estoppel certificate may also be included in your lease as an exhibit. If you’ve previously agreed to a form of estoppel certificate in your lease, check to ensure the one you have received matches the form you previously agreed to and if it doesn’t make sure to review it carefully to make sure it is acceptable. Review the estoppel certificate and confirm that all of the information is accurate. Be on the lookout for any terms or provisions that you did not agree to in your lease. If it seems like the landlord is trying to modify your lease, you likely do not need to consent to the change in this document. Cross off (or modify or delete, if you have an electronic copy) any information that is inaccurate. Fill in all blanks (if the blank is not applicable, write “N/A”), and if any exhibits are referenced in the body of the document, make sure they are actually attached. Read the court decision
Read the full story...
Reprinted courtesy of Lauren Podgorski, Snell & Wilmer
Ms. Podgorski may be contacted at lpodgorski@swlaw.com

Motion to Dismiss Denied Regarding Insureds' Claim For Collapse

October 29, 2014 — Tred R. Eyerly – Insurance Law Hawaii
The federal district court denied the insurer's motion to dismiss claims for loss due to the imminent collapse of the insureds' basement walls. Belz v. Peerless Ins. Co., 2014 WL 4364914 (D. Conn. Sept. 2, 2014). The insureds noticed cracks throughout their basement walls. It was discovered that the condition was the result of a chemical compound used in the concrete of certain basement walls in the late 1980s and early 1990s. The insureds contended that due to the cracking, the basement walls suffered a substantial impairment to their structural integrity making it only a matter of time until the walls collapsed. The insureds notified their insurer, Peerless. An engineer hired by Peerless determined the walls' condition was caused by poor workmanship and defective materials. On this basis, Peerless denied coverage. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Fifth Circuit Rules that Settlements in Underlying Action Constitute "Other Insurance"

April 17, 2019 — Tiffany Casanova - Saxe Doernberger & Vita, P.C.
The Fifth Circuit ruled that settlements between an insured and its subcontractors qualified as “other insurance” to the extent those settlements were used to pay for damages covered by an excess insurance policy. Policyholders should note the outcome of this case as it demonstrates the significant impact that settlements can have on coverage. Satterfield & Pontikes Construction, Inc. v. Amerisure Mutual Ins. Co.1 was the result of a construction project gone wrong. Zapata County, Texas hired Satterfield & Pontikes (“S&P”) as a general contractor for the construction of a courthouse building. When the project did not go as planned, Zapata County terminated S&P, hired new subcontractors to complete the project, and sued S&P. S&P, in turn, sought indemnification from its subcontractors, who were contractually obligated to indemnify S&P and procure insurance for any damage the subcontractors caused at the project. S&P also sought coverage from its own primary insurers, American Guarantee and Liability Insurance Company (“AGLIC”) and Amerisure Mutual Insurance Company (“Amerisure”), and its excess insurer, U.S. Fire Insurance Company (“U.S. Fire”) who provided liability coverage for S&P’s potential liabilities at the project. The policies contained exclusions for losses arising from mold and did not provide coverage for attorney’s fees or similar legal costs. Read the court decision
Read the full story...
Reprinted courtesy of Tiffany Casanova, Saxe Doernberger & Vita, P.C.
Ms. Casanova may be contacted at tlc@sdvlaw.com

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES