FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Delays Caused When Government (Owner) Pushes Contractor’s Work Into Rainy / Adverse Weather Season

January 13, 2020 — David Adelstein - Florida Construction Legal Updates
There are a number of horizontal construction projects where a contractor’s sequence of work and schedule is predicated on avoiding the rainy season (or certain force majeure events). The reason is that the rainy season will result in delays due to the inability to work (and work efficiently) during the adverse weather (including flooding caused by the weather). If the work is pushed into the rainy season, is such delay compensable if the government (or owner) delayed the project that pushed work out into the rainy season? It very well can be. For example, in Meridian Engineering Co. v. U.S., 2019 WL 4594233 (Fed. Cl. 2019), a contractor was hired by the Army Corps of Engineers to construct a flood control project for a channel in Arizona. Due to delays, including those caused by the government, the project was pushed into the monsoon season, which caused additional delays largely due to flooding caused by the heavy rain. One issue was whether such delays were compensable to the contractor – the government raised the argument that the contractor assumed the risk of potential flooding from the rainy season. The Court found this argument unconvincing:

[The contractor’s] initial construction schedule planned for a completion of the channel invert work, a necessary step in protecting the site from flooding, to be completed by late June 2008…[M]any issues arose in the project’s early stages that led to cumulative substantial delay, including those caused by the government’s failure….The government cannot now claim that [the contractor] assumed the risk of flooding from monsoon season when the government was largely responsible for [the contractor’s] inability to complete the project prior to the beginning of the monsoon season. Simply put, the government cannot escape liability for flood damages when the government is responsible for causing the contractor to be working during the flood-prone season. Meridian Engineering, 2019 WL at *7 (internal citations omitted)

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Philadelphia Court Rejects Expert Methodology for Detecting Asbestos

October 11, 2017 — Christian Singewald, Wesley Payne & Jonathan Woy - White and Williams LLP
Lawsuits against talcum powder manufacturers have recently made headlines for the multimillion dollar verdicts returned in favor of plaintiffs with ovarian cancer. However, lawsuits brought by individuals with mesothelioma who did not work in occupations traditionally associated with asbestos exposure represent another potential liability for talcum powder manufacturers and retailers. In such cases, expert testimony linking mesothelioma to trace amounts of asbestos in talcum powder should be carefully scrutinized. Reprinted courtesy of White and Williams LLP attorneys Christian Singewald, Wesley Payne and Jonathan Woy Mr. Singewald may be contacted at singewaldc@whiteandwilliams.com Mr. Payne may be contacted at paynew@whiteandwilliams.com Mr. Woy may be contacted at woyj@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

---

New Jersey Courts Speed Up Sandy Litigation

September 03, 2014 — Beverley BevenFlorez-CDJ STAFF
In order to deal with the thousand plus property damage cases related to Hurricane Sandy the “U.S. District Chief Judge Jerome Simandle of the District of New Jersey, who sits in Camden, N.J., issued a standing order dated Aug. 13 that, in effect, cuts in half the amount of time that arbitrators and mediators will have to hear disputes over coverage and issue rulings,” the New Jersey Law Journal reported. “John O’Brien, chief deputy of operations for New Jersey’s federal courts, said that, as of Wednesday, 1,240 Sandy-related lawsuits had been filed in New Jersey and that 1,051 of those cases are still pending,” according to the New Jersey Law Journal. “Sixty of those pending cases have been referred to mediation and another six have been sent to arbitration panels, according to O’Brien.” Read the court decision
Read the full story...
Reprinted courtesy of

---

Architect Named Grand Custom Home Winner for Triangular Design

November 05, 2014 — Beverley BevenFlorez-CDJ STAFF
Robert Gurney, architect, created a triangular shaped home design to deal with restricted space on a corner lot that has "stumped developers for years," according to Custom Home. "Using the wedge-shaped lot’s height limit and property line setbacks to define a structure, Gurney designed a striking triangle-plan house that not only answers its owners’ program requirements, but also makes a handsome and respectful addition to the existing streetscape," according to Custom Home. Gurney told Custom Home that the clients--two graphic designers--helped make it successful. “They’re design-oriented,” he said, “so they were pretty much on board with whatever we came up with. And, fortunately, they didn’t need a lot of space; they’re empty-nesters.” Read the court decision
Read the full story...
Reprinted courtesy of

---

Connecticut Gets Medieval All Over Construction Defects

February 10, 2012 — CDJ STAFF

The Hartford Courant reports that Connecticut is trying a very old tactic in a construction defect suit. The law library building at the University of Connecticut suffered from leaks which have now been repaired. The state waited twelve years after was complete to file lawsuit, despite that Connecticut has a six-year statute of limitations on construction defect claims. Connecticut claims that the statute of limitations does apply to the state.



The state is arguing that a legal principle from the thirteenth century allows it to go along with its suit. As befits a medieval part of common law, the principle is called “nullum tempus occurrit regi,” or “time does not run against the king.” In 1874, the American Law Register said that nullum tempus occurrit reipublicae “has been adopted in every one of the United States” and “is now firmly established law.”



In the case of Connecticut, Connecticut Solicitor General Gregory D’Auria said that “the statute of limitations does not apply to the state.” He also noted that “the state did not ‘wait’ to file the lawsuit. The lawsuit was filed only after all other options and remedies were exhausted.”



Connecticut also argued that “nullus tempus occurrit regi” applied in another construction defect case at the York Correctional Institution. The judge in that case ruled in December 2008 to let the case proceed. But in the library case, Judge William T. Cremins ruled in February 2009 that the statute of limitations should apply to the state as well. Both cases have been appealed, with the library case moving more quickly toward the Connecticut Supreme Court.

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

---

Make Sure to Properly Perfect and Preserve Construction Lien Rights

December 07, 2020 — David Adelstein - Florida Construction Legal Updates
If you recording a construction lien (referred to as a claim of lien) and looking to perfect your construction lien foreclosure rights, it is imperative that you work with counsel to ensure your rights are properly preserved. This is good practice! A claim of lien must be served on an owner within 15 days after recording. Florida Statute s. 713.08(4)(c) says: “The claim of lien shall be served on the owner. Failure to serve any claim of lien in the manner provided in s. 713.18 before recording or within 15 days after recording shall render the claim of lien voidable to the extent that the failure or delay is shown to have been prejudicial to any person entitled to rely on the service.” Florida Statute s. 713.18, hyperlinked for your review, includes the statutory ways to serve “notices, claims of lien, affidavits, assignments, and other instruments permitted or required under [Florida Statutes Chapter 713].” Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

San Francisco House that Collapsed Not Built to Plan

February 14, 2014 — Beverley BevenFlorez-CDJ STAFF
Last December, a San Francisco, California “developer’s Twin Peaks house collapsed and slid down a hill during renovations.” The San Francisco Chronicle reported that the house “was being supported by three reinforcing towers, rather than the nine required under its approved plans, according to documents provided to city building inspectors.” According to a report by Department of Building Inspection chief Tom Hui, developer Mel Murphy "’failed to follow and implement the approved plans and the sequence of construction’ in his permit,” as quoted by The San Francisco Chronicle. The report also stated that the work “was not independently inspected as required” though this is “vehemently disputed by Murphy.” Read the court decision
Read the full story...
Reprinted courtesy of

---

Another Reminder that Contracts are Powerful in Virginia

February 08, 2021 — Christopher G. Hill - Construction Law Musings
Regular readers of this construction law blog are likely tired of my refrain that the contract is king here in Virginia. With few exceptions, some of which have been passed in the last few years, the contract can and does essentially set the “law” for the transaction. A recent opinion from the 4th Circuit Court of Appeals confirms this principle. In Bracey v. Lancaster Foods, LLC, the Court looked at the question as to whether parties can contractually limit the statute of limitations in which a plaintiff or arbitration claimant can file its claim for relief. In Bracey, Michael Bracey, a truck driver, sued his former employer, Lancaster Foods, asserting various employment law claims. Lancaster moved to dismiss and compel arbitration based on the terms of an alternative dispute resolution agreement Bracey signed when he was hired, under which he consented to arbitration of any employment-related claim and waived all rights he may otherwise have had to a trial. Bracey challenged the arbitration clause, one that also included a 1-year limitation on the time in which Bracey was allowed to file any claim, as unconscionable. A federal judge in Maryland agreed and granted the motion to dismiss. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

---