SEATTLE WASHINGTON BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Delaware Strengthens Jurisdictional Defenses for Foreign Corporations Registered to Do Business in Delaware

April 28, 2016 — Randall MacTough, Timothy Martin & Christian Singewald – White & Williams LLP
The days of companies being sued in Delaware based solely upon their compliance with Delaware’s registration statutes appear over. Recently, the Delaware Supreme Court, in Genuine Parts Co. v. Cepec[1], held that Delaware Courts cannot exercise jurisdiction over a foreign corporation registered to do business in Delaware for claims unrelated to its conduct in Delaware. In Delaware, foreign corporations must register to do business and designate a registered agent in Delaware to accept service of process to sell its products or services.[2] Since 1988, Delaware has construed these registration laws as foreign corporations’ express consent to general jurisdiction.[3] Reprinted courtesy of White & Williams LLP attorneys Randall MacTough, Timothy Martin and Christian Singewald Mr. MacTough may be contacted at mactoughr@whiteandwilliams.com Mr. Martin may be contacted at martint@whiteandwilliams.com Mr. Singewald may be contacted at singewaldc@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

---

The Privette Doctrine and Its Exceptions: Court of Appeal Grapples With the Easy and Not So Easy

November 18, 2024 — Garret Murai - California Construction Law Blog
In CBRE v. Superior Court, 102 Cal.App.5th 639 (2024), the 4th District Court of Appeal grappled with a thorny and not-so-thorny issue involving injured parties under the Privette doctrine. The less thorny issue was whether application of the Privette doctrine depends on whether a written contract exists between the parties. Spoiler: It does not. The thorny issue was whether the Hooker exception to the Privette doctrine – which applies when a landowner exercises control over a project – should apply where a landowner directs a contractor to perform work that is at odds with legal requirements. The CBRE Case Property Reserve, Inc. owns an office building managed by CBRE in San Diego, California. On April 9, 2019, PRI entered into a lease agreement with a new tenant for a suite in the building. The lease required that PRI perform certain tenant improvements. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

---

Travelers’ 3rd Circ. Win Curbs Insurers’ Asbestos Exposure

November 21, 2017 — Gregory D. Podolak - Saxe Doernberger & Vita, P.C.
Originally published by CDJ on May 3, 2017 In breaking news this week, LAW360.com posted that the Third Circuit ruled Friday that “a common exclusion found in a Travelers policy bars coverage for claims arising out of asbestos in any form, limiting insurers’ potential exposure to asbestos injury claims by precluding policyholders from arguing that the exclusionary language is ambiguous and doesn’t extend to products containing the carcinogen.” In its detailed analysis of the decision, LAW360 turned to Greg Podolak for his analysis. Gregory D. Podolak, managing partner of Saxe Doernberger & Vita PC’s Southeast office, said the ruling is a cautionary tale that should galvanize policyholders and their insurance brokers to take a closer look at policies to delete or curtail broad “arising out of” language in exclusions. Otherwise, insureds could find themselves without any coverage for claims even remotely related to a certain product, he said. Read the court decision
Read the full story...
Reprinted courtesy of Gregory D. Podolak, Saxe Doernberger & Vita, P.C.
Mr. Podolak may be contacted at gdp@sdvlaw.com

---

How the Jury Divided $112M in Seattle Crane Collapse Damages

April 04, 2022 — Richard Korman - Engineering News-Record
The jury verdict in a wrongful death lawsuit against companies involved in a 2019 Seattle crane collapse that killed four people split damages among three different companies—and also blamed a fourth firm that wasn't a defendant—but not in a way that matched the state safety fines proposed against the firms. Reprinted courtesy of Richard Korman, Engineering News-Record Mr. Korman may be contacted at kormanr@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

---

Buffett Says ‘No-Brainer’ to Get a Mortgage to Short Rates

October 08, 2014 — Noah Buhayar – Bloomberg
Warren Buffett, the billionaire chairman of Berkshire Hathaway Inc. (BRK/A), said he was puzzled by the sluggish rebound in U.S. home construction amid near record-low interest rates and a broader recovery in the economy. “You would think that people would be lining up now to get mortgages to buy a home,” Buffett said today at a conference hosted by Fortune magazine in Laguna Niguel, California. “It’s a good way to go short the dollar, short interest rates. It is a no-brainer. But so far home construction pickup has been slower than I had anticipated.” Housing starts slumped in August from the highest level in almost seven years to a 956,000 annualized rate, Commerce Department data show. Slow wage growth and tighter lending standards have kept some would-be borrowers from buying a home. Read the court decision
Read the full story...
Reprinted courtesy of Noah Buhayar, Bloomberg
Mr. Buhayar may be contacted at nbuhayar@bloomberg.net

---

Recovering Unabsorbed Home Office Overhead Due to Delay

May 30, 2022 — David Adelstein - Florida Construction Legal Updates
In the preceding article, I discussed the use of a retrospective as-built delay analysis in a case before the Civilian Board of Contract Appeals (CBCA). This case also discussed a damages component in certain delay claims known as unabsorbed home office overhead—a challenging damages component to recover because this deals with indirect costs as opposed to direct costs. Unabsorbed home office overhead is a damages component when the contractor is on standby, but this is NOT as easy as just claiming standby thereby you are automatically entitled to unabsorbed home office overhead. There are requirements that MUST be met.

To obtain an equitable adjustment for unabsorbed home office overhead as compensation for being on standby, [the contractor] must initially show “[1] a government-caused delay of uncertain duration,” that “[2] the delay extended the original time for performance” or precluded the contractor from finishing earlier than scheduled, and that “[3] the contractor [was] on standby and unable to take on other work during the delay period. CTA I, LLC v. Department of Veteran Affairs, CBCA 5826, 2022 WL 884710 (CBCA 2022) quoting Nicon, Inc. v. U.S., 331 F.3d 878, 883 (Fed. Cir. 2003).

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

That’s Common Knowledge! Failure to Designate an Expert Witness in a Professional Negligence Case is Not Fatal Where “Common Knowledge” Exception Applies

June 03, 2019 — Lyndsey Torp - Snell & Wilmer Real Estate Litigation Blog
In reversing summary judgment for defendants, the California Fourth District Court of Appeal recently held that homeowners suing their real estate broker for negligence did not need an expert witness to establish the elements of their causes of action. Ryan v. Real Estate of the Pacific, Inc. (2019) 32 Cal. App. 5th 637. Typically, expert witnesses are required to establish the standard of care in professional negligence cases. But in Ryan, the court of appeal held that the “common knowledge” exception applied despite this general rule, because the conduct required by the particular circumstance of the case was within the common knowledge of a layman. The conduct in question here? The broker’s failure to disclose to his client that the client’s neighbor told him that she planned extensive renovations that would obstruct the client’s property’s ocean views. Ryan and Patricia Ryan (the Ryans) hired defendant Real Estate of the Pacific, Inc., doing business as Pacific Sotheby’s International Realty (Sotheby’s) and defendant real estate broker to sell their residence in La Jolla, California. During an open house at the residence, a neighbor informed the Ryan’s real estate broker that she planned extensive renovations at her home that would, among other things, permanently obstruct the Ryan’s westerly ocean views and take several years to complete. The real estate broker never informed the Ryans of this, nor the subsequent buyer. The subsequent buyer purchased the property for $3.86 million, and defendants received $96,500 as commission for the sale. The day after escrow closed, the buyers learned of the renovations, and sought to rescind the purchase. Based on advice of defendants, the Ryans refused, and the dispute proceeded to arbitration. The buyer obtained a rescission of the purchase, with the Ryans order to pay damages, interest, and attorneys’ fees and costs in excess of $1 million. The Ryans then sued Sotheby’s and the real estate broker to recover these amounts and damages caused by defendants’ alleged negligence. Read the court decision
Read the full story...
Reprinted courtesy of Lyndsey Torp, Snell & Wilmer
Ms. Torp may be contacted at ltorp@swlaw.com

---

Insurer’s “Failure to Cooperate” Defense

November 14, 2018 — David Adelstein - Florida Construction Legal Updates
The “failure to cooperate” defense is a defense an insurer may raise when its insured fails to cooperate with it in the defense of the claim against the insured. If an insurer takes this position, it will typically be denying both defense and indemnification obligations, meaning the insured could be forfeiting coverage that otherwise exists through his/her/its failure to cooperate with the insurer. This defense by the insurer is not absolute as recently explained by the Fourth District in Barthelemy v. Safeco Ins. Co. of Illinois, 43 Fla.L.Weekly D2379a (Fla. 4th DCA 2018) discussing the elements of this failure to cooperate defense. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---