Presenting a “Total Time” Delay Claim Is Not Sufficient
September 12, 2022 —
David Adelstein - Florida Construction Legal UpdatesWhen presenting a delay-type of claim on a construction project, a claimant MUST be in a position to properly PROVE the claim. Trying to present a delay claim loosey-goosey is not a recipe for success. In fact, it can be a recipe for an easy loss. This is not what you want. To combat this, make sure you engage a delay expert that understands delay methodologies and how to calculate delay and do NOT present a total time claim. Presenting a delay claim using a total time approach, discussed below, makes it too easy to attack the flaws and credibility of the approach. Per the discussion of the case below, a total time claim with a contractor that used its project manager, versus a delay expert, to support its claim turned the contractor’s claim into a loss.
In French Construction, LLC v. Department of Veteran Affairs, 2022 WL 3134507, CBCA 6490 (CBCA 2022), a contractor submitted a delay claim to the government for almost $400,000. The contractor was hired to construct a two-story corridor to connect hospital buildings. The contractor was required to be complete within 365 days. It was not. The contractor was seeking 419 days of delay from the government. The contractor’s “delay expert” was its project manager who compared the contractor’s as-planned schedule to an as-built schedule he prepared for the claim.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Real Estate & Construction News Roundup (07/05/23) – A Hospitality Strike in Southern California, Agencies Step in With Lenders and the Social in ESG
August 14, 2023 —
Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law BlogIn our latest roundup, we see promising developments for climate change action in commercial real estate, how homeowners are reacting to new energy concerns, the fallout of the U.S. debt ceiling fight on global M&A deals, and more!
- There are new ways the commercial real estate sector can grow its commitment to climate goals and contributions to reducing its carbon footprint. (Mahesh Ramanujam, Forbes)
- Thousands of hospitality workers in Southern California went on strike to demand higher wages, access to affordable family health care benefits and stronger workplace protections. (Julianne McShane, NBC)
Read the court decisionRead the full story...Reprinted courtesy of
Pillsbury's Construction & Real Estate Law Team
Hurry Up and Wait! Cal/OSHA Hits Pause on Emergency Temporary Standards for COVID-19 Prevention
June 14, 2021 —
Michael Studenka & Jasmine Shams - Newmeyer DillionEmployers scrambling to prepare for the June 15th Reopening announced by Governor Newsom have spent the last week pouring over the revised Emergency Temporary Standards for COVID-19 Prevention (“Revised ETS”) approved by the Cal/OSHA Standards Board on June 3, 2021. After last night’s meeting of the Standards Board, however, it’s time to hit pause.
Last night, the Cal OSHA Standards Board held a specialty meeting to reconsider its Revised ETS in light of the latest guidance on face coverings issued by the California Department of Public Health (“CDPH”) on June 7, 2021. Following a presentation by the CDPH and extensive public comment, the Cal OSHA Standards Board voted unanimously to withdraw the Revised ETS and to take up the issue again at its next scheduled meeting on June 17, 2021. The net result in the interim is that California employers who intend to reopen on June 15 must initially comply with all of the requirements of the Cal/OSHA Standards Board Emergency Temporary Standards for COVID-19 Prevention as originally issued on November 20, 2020, including but not limited to, its social distancing, physical partitioning and mask wearing requirements.
Reprinted courtesy of
Michael J. Studenka, Newmeyer Dillion and
Jasmine Shams, Newmeyer Dillion
Mr. Studenka may be contacted at michael.studenka@ndlf.com
Ms. Shams may be contacted at jasmine.shams@ndlf.com
Read the court decisionRead the full story...Reprinted courtesy of
Pine Island Bridge in Place as Florida Pushes Barrier Island Access in Ian's Wake
October 10, 2022 —
Derek Lacey - Engineering News-RecordA temporary bridge is in place for Pine Island, Fla., after state officials mobilized crews to restore mainland access to barrier islands cut off when Hurricane Ian washed away roads and bridges last month.
President Joe Biden (D) joined Florida Gov. Ron DeSantis (R) on Oct. 5 in touring the hardest-hit parts of the state, with the governor announcing the five-day emergency Pine Island project and plans to finish repair of the causeway to Sanibel Island by the end of October.
Reprinted courtesy of
Derek Lacey, Engineering News-Record
Mr. Lacey may be contacted at laceyd@enr.com
Read the full story... Read the court decisionRead the full story...Reprinted courtesy of
Another Colorado Construction Defect Reform Bill Dies
May 07, 2014 —
Beverley BevenFlorez-CDJ STAFFColorado construction defects reform Senate Bill 220 died when “Senate President Morgan Carroll, D-Aurora, declined to call a second committee to hear” the bill, according to Ed Sealover writing for the Denver Business Journal. Sen. Carroll declared that the “bill backers” did not incorporate any of the “suggestions she or House Speaker Mark Ferrandino had given them.”
“SB 220 would have required condo-unit owners to submit to alternative-dispute resolution such as arbitration or mediation if the unit developer required it,” Sealover reported. “And it would have required that a majority of members of a homeowners association agree to file a lawsuit, a standard significantly larger than the two-person bar that now must be met.”
Bill Cosponsor Sen. Mark Scheffel, R-Castle Rock, “believes litigation reform” will become “an election issue and” that it “has strong momentum heading into the 2015 session.”
Read the court decisionRead the full story...Reprinted courtesy of
Were Quake Standards Illegally Altered for PG&E Nuclear Power Plant?
October 29, 2014 —
Beverley BevenFlorez-CDJ STAFFAn environmental group has brought a lawsuit alleging that “[f]ederal regulators secretly and illegally revised the license for California’s last nuclear power facility — PG&E’s Diablo Canyon — to mask the aging plant’s vulnerability to earthquakes,” according to SF Gate.
Friends of the Earth’s “suit claims that the Nuclear Regulatory Commission and Pacific Gas and Electric Co. last year changed a key element of the plant’s license related to seismic safety without allowing public input as required by law — or even notifying the public at all.”
However, spokesman Blair Jones claimed that “Friends of the Earth continues to mischaracterize the facts regarding seismic safety at Diablo Canyon. The facts are Diablo Canyon was built with earthquake safety at the forefront, is a seismically safe facility, and is in compliance with NRC licensing requirements.”
Read the court decisionRead the full story...Reprinted courtesy of
Retrofitting Buildings Is the Unsexy Climate Fix the World Needs
November 19, 2021 —
Marc Champion - BloombergYou may not have noticed unless you live in London, but protesters have been gluing their hands to the asphalt of the city’s thundering eight-lane M25 ring road, to the weirdly technocratic war cry of “Insulate Britain!” Frustrated commuters and the police officers who’ve had to peel these sticky activists from the road find them irritating. Yet they have a point. Among top producers of climate-harming emissions that world leaders plan to address at COP26 in Glasgow in November, buildings are the summit’s largely ignored Cinderella.
Making homes and offices leak less heat and persuading the construction industry to give up its addiction to demolition and to energy-intensive materials such as concrete, plastics, and steel have so far proved less than appealing to governments in search of solutions to the climate challenge. Retrofitting is costly and disruptive for the voters who happen to live, in the U.K. alone, in the 28 million homes that need an upgrade. It also demands the systemic transformation of a fragmented industry that’s riddled with vested interests, says Stephen Good, chief executive of the Construction Scotland Innovation Centre along Glasgow’s southern underbelly.
Read the court decisionRead the full story...Reprinted courtesy of
Marc Champion, Bloomberg
SEC Recommendations to Protect Against Cybersecurity Threats
March 09, 2020 —
Shaia Araghi and Jeffrey Dennis – Newmeyer DillionWhat Happened?
The Securities and Exchange Commission's Office of Compliance Inspections and Examinations ("OCIE") issued a detailed
report on January 27, 2020 regarding various ways for organizations to safeguard data and protect against security and data breaches. Cyber threat actors are now invading data in a more sophisticated manner than ever before, and implementation of the SEC's recommended practices are essential in order to protect from outside vulnerabilities.
What is at Risk?
If market participants fail to implement these recommended policies, they will become more vulnerable to external attacks and data breaches. This can weaken an organization or firm if all employees are not properly trained and informed of the increasing dangers of cybersecurity breaches.
What Can You Do to Protect Yourself from a Cybersecurity Threat?
1.
Governance and Risk Management. Senior leaders should make efforts to improve the cyber safety at their organization. Some of these efforts may include:
- Devote attention to overseeing the organization's cybersecurity and resilience programs;
- Develop a risk assessment process to identify and mitigate cybersecurity risks to the organization;
- Adopt and implement policies and procedures regarding these risks;
- Promptly respond and adapt to changes by updating policies and procedures when necessary; and
- Establish communication policies and procedures to provide timely information to customers, employees, and others when needed.
2.
Access Rights and Controls. Implement updated controls to determine appropriate users for organization systems, limit access as appropriate to authorized users (including the set-up of multi-factor authentication) and monitor user access.
3.
Data Loss Prevention. OCIE has recommended various important data loss prevention measures for organizations:
- Establish a vulnerability management program;
- Implement capabilities that can monitor network traffic and detect threats on endpoints;
- Establish a patch management program covering all software and hardware;
- Maintain an inventory of hardware and software assets;
- Encrypt data and implement network segmentation;
- Create an insider threat program to monitor any suspicious behaviors; and
- Secure legacy systems and equipment through disposal of sensitive information from hardware and software and by reassessing vulnerability and risk assessments.
4.
Mobile Security. Establish policies and procedures for mobile device use, manage use of mobile devices through a mobile device management application, implement security measures for internal and external users, and train employees on mobile device policies and effective practices.
5.
Incident Response and Resiliency. Detect and disclose material information regarding incidents in a timely manner and assess appropriateness of corrective actions taken in response to incidents. Organizations should develop a plan if an incident occurs, address applicable reporting requirements, assign staff to execute specific areas of the plan, and test and assess the plan. In the event that a data breach occurs, an organization should improve its resiliency by maintaining an inventory of core business services and prioritizing business operations based on an assessment of risks.
6.
Vendor Management. Establish a vendor management program to ensure that vendors meet your organization's security requirements. Organizations should aim to understand all contract terms with vendors to ensure that all parties are in agreement regarding risk and security. Organizations should also monitor third-party vendors and ensure that the vendor continues to meet the organization's security requirements.
7.
Training and Awareness. Train staff to implement cybersecurity policies of the organization. Organizations should provide cybersecurity and resiliency training and re-evaluate the effectiveness of training procedures.
A Final Reminder for Organizations
Organizations should strive to implement as many of the SEC's recommended protection measures as possible. Ensuring that senior members of an organization are leading the initiative in increased awareness about cybersecurity threats through training of employees will lead to greater cyber safety for the overall organization. Although prevention of all breaches cannot be guaranteed, developing data loss prevention plans to keep the organization and its core businesses safe from attack will benefit the entire organization.
How We Can Help
If you feel that your business falls below the SEC's recommended security measures, our firm can assist with compliance. Contact us for a free initial consultation to determine a reasonable and practical way for your business to become compliant with these guidelines.
Shaia Araghi is an associate in the firm's Privacy & Data Security, and supports the team in advising clients on cyber-related matters, including compliance and prevention that can protect their day-to-day operations. For more information on how Shaia can help, contact her at shaia.araghi@ndlf.com.
Jeff Dennis (CIPP/US) is the Head of the firm's Privacy & Data Security practice. Jeff works with the firm's clients on cyber-related issues, including contractual and insurance opportunities to lessen their risk. For more information on how Jeff can help, contact him at jeff.dennis@ndlf.com.
About Newmeyer Dillion
For 35 years, Newmeyer Dillion has delivered creative and outstanding legal solutions and trial results that achieve client objectives in diverse industries. With over 70 attorneys working as a cohesive team to represent clients in all aspects of business, employment, real estate, environmental/land use, privacy & data security and insurance law, Newmeyer Dillion delivers holistic and integrated legal services tailored to propel each client's success and bottom line. Headquartered in Newport Beach, California, with offices in Walnut Creek, California and Las Vegas, Nevada, Newmeyer Dillion attorneys are recognized by The Best Lawyers in America©, and Super Lawyers as top tier and some of the best lawyers in California and Nevada, and have been given Martindale-Hubbell Peer Review's AV Preeminent® highest rating. For additional information, call 949.854.7000 or visit www.newmeyerdillion.com.
Read the court decisionRead the full story...Reprinted courtesy of
