Fairfield Connecticut Building Expert Directory

When Can Customers Sue for Delays?

September 18, 2023 — Scott L. Baker - Los Angeles Litigation Blog
Construction projects are subject to many internal and external factors. Due to this, delays are not an uncommon occurrence. Whether delays are the result of bad weather conditions or supply chain issues, contractors and their clients cannot control every aspect of the project. Delay issues are very common construction disputes. Therefore, new and experienced contractors alike need to know when their clients may have a reason for a delay claim. 2 particular types of delays that pose a risk Common obstacles that contractors faced during the height of the COVID-19 global pandemic involved supply chain issues. The lack of materials put various projects on hold across California and the country. This widespread issue was out of contractors’ and clients’ control, meaning they were excusable delays. Read the court decision
Read the full story...
Reprinted courtesy of Scott L. Baker, Baker & Associates
Mr. Baker may be contacted at slb@bakerslaw.com

Lane Construction Sues JV Partner Skanska Over Orlando I-4 Project

February 08, 2021 — Scott Judy - Engineering News-Record
One of Florida’s most troubled construction projects is now in court, with one partner in a design-build joint venture pitted against another. Reprinted courtesy of Scott Judy, Engineering News-Record Mr. Judy may be contacted at judys@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Subsequent Purchaser Can Assert Claims for Construction Defects

October 17, 2022 — David Adelstein - Florida Construction Legal Updates
Can a subsequent purchaser pursue construction defect claims relating to the original construction of the property? This was the threshold issue on a motion for summary judgment by a drywall manufacturer against a subsequent purchaser of a home in Karpel v. Knauf Gips KG, 2022 WL 4366946 (S.D. Fla. 2022). This matter deals with the defective Chinese drywall that was installed in homes years ago. The plaintiffs, which were subsequent purchasers of a home, sued the manufacturer of the defective drywall for various theories including negligence, negligence per se, strict liability, breach of express and/or implied warranty, private nuisance, unjust enrichment, and Florida’s Deceptive and Unfair Trade Practices Act. The trial court noted, from the onset, that Florida does NOT have a subsequent purchaser rule that prohibits subsequent purchasers from asserting construction defect claims. With this consideration in mind, the trial court went through the claims the plaintiff, as a subsequent purchaser, asserted against the manufacturer to determine whether they were viable claims as a matter of law. Negligence Claim The trial court found that a subsequent purchaser could sue in negligence. “Florida courts have long allowed subsequent purchasers to sue for negligence including in construction defect litigation.” Karpel, supra, at *2. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Contractual Waiver of Consequential Damages

January 21, 2019 — David Adelstein - Florida Construction Legal Updates
Contractual waivers of consequential damages are important, whether they are mutual or one-sided. I believe in specificity in that the types of consequential damages that are waived should be detailed in the waiver of consequential damages provision. Standard form construction agreements provide a good template of the types of consequential damages that the parties are agreeing to waive. But, what if there is no specificity in the waiver of consequential damages provision? What if the provision just states that the parties mutually agree to waive consequential damages or that one party waives consequential-type damages against the other party? Let me tell you what would happen. The plaintiff will argue that the damages it seeks are general damages and are NOT waived by the waiver of consequential damages provision. The defendant, on the other hand, will argue that the damages are consequential in nature and, therefore, contractually waived. FOR THIS REASON, PARTIES NEED TO APPRECIATE WHAT DAMAGES ARE BEING WAIVED OR LIMITED, AND POTENTIALLY THOSE DAMAGES NOT BEING WAIVED OR LIMITED, WHEN AGREEING TO A WAIVER OF CONSEQUENTIAL DAMAGES PROVISION! Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

You Cannot Always Contract Your Way Out of a Problem (The Case for Dispute Resolution in Mega and Large Complex Construction Projects)

September 16, 2024 — Lisa D. Love - The Dispute Resolver
Most experienced commercial transaction and construction attorneys strive to negotiate a concisely written and well-drafted contract that addresses all scenarios and issues that creative and highly contemplative professionals can conjure. Although contracts are extremely important in construction projects, “you can’t generally contract your way out of a problem,” states Michael Loulakis, a founder of Capital Project Strategies, LLC and a nationally recognized expert on project delivery systems in complex public sector design-build projects and public-private partnership programs. Loulakis adds, “the contract certainly matters. But particularly when the losses are big, litigators prosecuting the contractors often find effective ways to argue that facts and circumstances trump the contract.” However, “the difference between the best construction projects and the worst construction projects is not the written words of the contracts but how the parties have committed to engage collaboratively and with trust to complete the project,” notes Robynn Thaxton, an attorney and consultant with Thaxton Parkinson PLLC and Progressive Design-Build Consulting, LLC and one of the leading experts in construction law and alternative procurement on a national basis.[i] In large, complex construction projects, the need for parties to collaboratively resolve disputes is highlighted by the judicial acceptance of the “Doctrine of the Contextual Contract”[ii] to interpret construction contracts. “As construction’s increasing technological and managerial complexity came to be recognized, some common law courts began turning away from strict interpretation of language within the four corners of a contract and moving toward recognizing in the enforcement of contracts the construction industry’s own experience, customs, practices and implied conditions and duties and the factual context underlying the contract. Courts [began the journey] along the road from ‘text’ to ‘context.’”[iii] Thus, the precise wording of the contract has become less important and industry practices and other conditions provide insight for resolving disputes. Consequently, despite the specific language of any construction contract and the clear allocation of responsibilities and risks, early dispute evaluation and resolution are critical to a successful project. Read the court decision
Read the full story...
Reprinted courtesy of Lisa D. Love, JAMS

Homeowner Alleges Pool Construction Is Defective

November 13, 2013 — CDJ STAFF
A Texas man is suing the contractor who built his pool alleging that within months of construction, the pool began to crack and leak water. According to the lawsuit from Larry Merendino, when the concrete contractor, PC Construction, removed some concrete, they found PVC joints that were not glued properly and were leaking. Mr. Merendino is suing the company and five other firms, claiming that the construction of his pool was negligent and that the companies operated by deceptive trade practices. Read the court decision
Read the full story...
Reprinted courtesy of

Deck Collapse Raises Questions about Building Defects

July 31, 2013 — CDJ STAFF
The Inquisitor reports that twenty-one people were injured when a deck collapsed at a rental apartment in Ocean Isle Beach, North Carolina. Most of the injuries were not serious. The mayor of Ocean Isle Beach attributed the problem to more people crowding onto it than it was designed for. “I do not think the N.C. building code anticipates 20 to 30 to people in a small deck at one time,” she said. Read the court decision
Read the full story...
Reprinted courtesy of

Construction Defects Claims Can Be Limited by Contract Says Washington Court

February 11, 2013 — CDJ STAFF
The firm Lane Powell has issued a construction law update on the recent Washington Supreme Court decision in Washington State Major League Baseball Public Facility District v. The Baseball Club of Seattle, LP. In the underlying construction defect claim, the Public Facility District found defects in the structural steel at Seattle’s Safeco Field. The contractor, Huber, Hunt & Nichols-Kiewit Construction Company claimed that construction claims could not be made, as it was barred by the statue of repose. Washington State has a six-year limitation on its statute of repose, however, the court noted that the contract contained a clause that, as noted by Lane Powell, “any alleged causes of action automatically accrue at substantial contemplation,” instead of within six years of substantial completion. The court concluded that the statue of repose could be rendered inoperative by contract. Further, the court found that these contract clauses pertained to subcontractors as well. Nevertheless, as PFD is a subdivision of the state, the court found that no statue of limitations could be appled. Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES