FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

There Are Consequences to Executed Documents Such as the Accord and Satisfaction Defense

October 01, 2024 — David Adelstein - Florida Construction Legal Updates
A federal government contractor in Jackson Construction Co., Inc. v. U.S., 62 Fed.Cl. 84 (Fed.Cl. 2024) sought delay damages against the government. It lost. The reason for the loss is a crucial reminder that documents parties sign ALWAYS matter. ALWAYS!! In Jackson Construction Co., the contractor’s delay claim was premised on relocating a waterline. The contractor, however, received additional money for relocating the waterline, but no additional time, and this was memorialized in a modification to the contract (i.e., a change order). In executing the modification for the additional work, the contractor did NOT reserve rights for time or money. Indeed, the modification reflected that the monetary adjustment constitutes full compensation for the additional work including delay, namely:

The contract period of performance remains the same. It is further understood and agreed that this adjustment constitutes compensation in full on behalf of the contractor and his subcontractors and suppliers for all costs and markup directly or indirectly, including extended overhead, attributable to the change order, for all delays related thereto, and for performance of the change within the time frame stated.

Jackson Construction Co., supra, at 90.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Application of Efficient Proximate Cause Doctrine Supports Coverage

January 06, 2012 — Tred R. Eyerly - Insurance Law Hawaii

Relying on the efficient proximate cause doctrine, the court determined coverage potentially existed for damage caused by water. Union Sav. Bank v. Allstate Indem. Co., 2011 U.S. Dist. LEXIS 134398 (S.D. Ind. Nov. 21, 2011).

The Tods purchased property that was mortgaged by Union Savings. The Tods obtained a Landlords Policy for the property from Allstate. When the Tods were in default on their loan, Union Savings notified them that foreclosure proceedings would commence. Union Savings sent an appraiser to the property who discovered water in the basement. Water and electricity to the building were off. Union Savings notified Allstate and later filed a formal claim under the mortgagee clause in the Landlords Policy. This clause stated, "A covered loss will be payable to the mortgagees named on the policy declaration. . . ."

Allstate denied coverage, citing exclusions for water damage.

Read the full story…

Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii. Mr. Eyerly can be contacted at te@hawaiilawyer.com

Read the court decision
Read the full story...
Reprinted courtesy of

---

Construction Lien Does Not Include Late Fees Separate From Interest

December 30, 2019 — David Adelstein - Florida Construction Legal Updates
Construction liens can include unpaid finance charges. But, what about late fees? You know, the late fees that certain vendors like to include in their contract or purchase order unrelated to finance charges. An added cost for being delinquent with your payment. Can a late fee be tacked onto the lien too? In a recent case, Fernandez v. Manning Building Supplies, Inc., 2019 WL 4655988 (Fla. 1st DCA 2019), a residential owner hired a contractor for a renovation job. The contractor entered into a contract with a material supplier. The terms of the supplier’s contract with the contractor provided that there would be a 1.5% delinquency charge for late payments and it seemed apparent that the delinquency charge was separate from finance charges. Florida Statute s. 713.06(1) provides in relevant portion:

A materialman or laborer, either of whom is not in privity with the owner, or a subcontractor or sub-subcontractor who complies with the provisions of this part and is subject to the limitations thereof, has a lien on the real property improved for any money that is owed to him or her for labor, services, or materials furnished in accordance with his or her contract and with the direct contract and for any unpaid finance charges due under the lienor’s contract.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

A Reminder to Get Your Contractor’s License in Virginia

April 25, 2023 — Christopher G. Hill - Construction Law Musings
How are ducks and contractors alike? A question I get often, particularly from construction contractors outside of Virginia is whether they need to get a Virginia contractor’s license. The answer is almost invariably “yes.” The next question is why? The answer is almost always “Because state law says so.” With some minor exceptions for material suppliers and the like, Virginia law requires that all of those that perform construction for others carry the proper license and specialization for the work performed. There is no exception for the proverbial “paper contractor” that takes money from an owner and subcontracts all of the actual physical work. It does not matter if you use a different term for what you do for the owner. If it walks like a duck and quacks like a duck. . .its a duck. If you take money to perform construction, you’re a contractor. Some of the consequences of contracting without a license (aside from possible criminal charges) include among other things, the inability to perfect a mechanic’s lien under Va. Code 43-3(D) and, with minor exceptions, the ability to enforce a contract (meaning it really hurts your ability to get paid). Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

---

“Genuine” Issue of “Material” Fact and Summary Judgments

December 18, 2022 — David Adelstein - Florida Construction Legal Updates
This is short article on summary judgments. A motion for summary judgment, as you may already know, is a procedural vehicle to try to dispose of issues or claims in a lawsuit, either partially or fully. The objective is that the moving party claims that there is no genuine issue of material fact and that they are entitled to a judgment (partially or finally) as a matter of law. See Florida Rule of Civil Procedure 1.510. In May of 2021, Florida adopted the federal summary judgment standard which theoretically means trial courts should grant more summary judgments, not less, based on the more rigorous standard. There have been many articles that discuss Florida’s new summary judgment standard including how the standard used to be versus how it is supposed to be now that it is modeled after the federal standard. That isn’t the point of this posting. (Here is an article published in the Florida Bar Journal that provides a primer on summary judgments in case you are interested.) The point of this posting is to understand the words “genuine” and “material” as underlined above when moving for or defending against a summary judgment. These words have important meaning in the context of motions for summary judgment. In other words, what is a genuine issue of material fact? This is a question that should not be overlooked because these are the facts you want to focus on and frame your arguments on when moving for or defending against a summary judgment. Notably, these are also the facts you want to introduce and emphasize at trial. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Real Estate & Construction News Round-Up (08/17/22) – Glass Ceilings, Floating Homes and the Inflation Reduction Act

September 12, 2022 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
This week’s round-up features the construction industry’s latest happenings: the Inflation Reduction Act, women shattering the glass ceiling, eco-friendly floating homes, and more.

• The Inflation Reduction Act contains approximately $5 billion for programs to accelerate the construction industry’s shift toward green building materials. (Julie Strupp, Construction Dive)
• According to a new analysis from consultancy Rider Levett Bucknall, the speed of growth for construction costs has only gotten faster. (Erik Sherman, Globe St.)
• Record vacancies in the construction industry has created the opportunity for women to step into what’s previously been an all-male business. (Craig Torres & Maria Paula Mijares Torres, Bloomberg)
• A midlife crisis hits office buildings, with the late-30s/early-40s stable of office product accounting for about a third of the national market today. (Commercial Observer)

Read the court decision
Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

---

Best Lawyers® Recognizes 49 White and Williams Attorneys

September 16, 2024 — White and Williams LLP
Thirty-eight White and Williams lawyers were recognized in Best Lawyers in America® 2025. Inclusion in Best Lawyers® is based entirely on peer-review. The methodology is designed to capture, as accurately as possible, the consensus opinion of leading lawyers about the professional abilities of their colleagues within the same geographical area and legal practice area. Best Lawyers® employs a sophisticated, conscientious, rational, and transparent survey process designed to elicit meaningful and substantive evaluations of quality legal services. In addition, eleven lawyers were recognized as Best Lawyers: Ones to Watch® in America. This recognition is given to attorneys who are earlier in their careers for outstanding professional excellence in private practice in the United States. The firm is also pleased to announce Best Lawyers® has recognized three attorneys as "Lawyer of the Year” including: Chuck Eppolito, Litigation - Health Care, Philadelphia, who focuses his practice on medical malpractice defense as well as other insurance-related defense; William D. Kennedy, Litigation – Insurance, Philadelphia, who focuses his practice on complex claims of injury and damage arising in both the professional and general liability contexts; and, Michael O. Kassak, Litigation – Insurance, Cherry Hill, who focuses his practice on large complex commercial matters including insurance coverage and healthcare disputes. Read the court decision
Read the full story...
Reprinted courtesy of White and Williams LLP

---

Contractors Sued for Slip

June 28, 2013 — CDJ STAFF
A man on his way to a safety meeting slipped fell on a gangway. He’s saying that the roofing paper on the gangway was improperly secured and is now suing the contractor for negligence. Donald Methvien claims that his damages exceed $50,000. Read the court decision
Read the full story...
Reprinted courtesy of

---