FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Not So Fast, My Friend: Pacing and Concurrent Delay

April 25, 2022 — William E. Underwood - ConsensusDocs
When critical path activities are delayed by the owner (or another party), contractors will sometimes “pace,” or slow down, other activities to match the owner-caused delay. After all, why should the contractor hurry up and wait? But paced activities can often appear as concurrent delays on a project’s overall schedule. And all too often, contractors fail to contemporaneously document their efforts to pace work. Not only can this create avoidable disputes with owners and other contractors, but it can also create future roadblocks to the recovery of delay damages. This article examines the interplay between pacing and concurrent delay[1] and what contractors should do to minimize risk and preserve their rights to obtain more than a simple time extension for project delays. Pacing versus Concurrent Delay As a basic matter, most contracts allocate responsibility/liability for a schedule delay to the party that caused the delay. For example, if an owner is contractually required to provide equipment for a contractor to install, then the owner likely bears responsibility for any delays caused if the equipment is delivered late. If, however, the contractor was also behind schedule on other activities during this time and the project would have been delayed regardless of the owner’s late deliveries, then the delay is probably concurrent. And the contractor will generally be entitled to only an extension of time, and no other monetary relief. Read the court decision
Read the full story...
Reprinted courtesy of William E. Underwood, Jones Walker LLP (ConsensusDocs)
Mr. Underwood may be contacted at wunderwood@joneswalker.com

---

Avoid a Derailed Settlement in Construction

March 28, 2022 — Patrick Barthet - Construction Executive
More and more construction cases are settling because lawyers know juries can prove to be unpredictable. The litigation process, as well as any actual trial, can be stressful, expensive and quite lengthy. Settlements are, for the most part, private while suits are public. Current reports find more than 90% of civil cases filed in state circuit courts are disposed of before trial. When that doesn't happen, things could go very poorly, as the case below illustrates. The Case Adam was seriously injured in a collision with a dump truck owned by Bang and driven by Tomas. While suit by Adam against Bang and Tomas was pending, Adam suggested they settle by having Bang pay him. Upon receipt of the offer, Bang's lawyer reached out confirming that his client was okay with the settlement amount but wished to add that the settlement also include the satisfaction of a lien filed by Adam's workers' compensation carrier. Adam's attorney refused that additional request, but that didn't stop Bang's lawyer. Based on the fact that Adam had agreed to the settlement amount, the lawyer filed a boiler plate notice of acceptance of settlement and had Bang issue a settlement check payable to Adam in the amount Adam had requested. Adam remained unwilling to compromise. He continued to resist the modified terms, which added satisfaction of the worker’s compensation lien. Bang then filed a motion to enforce settlement, arguing that since there was agreement on the settlement amount, Adam was required to do the deal. Reprinted courtesy of Patrick Barthet, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of
Mr. Barthet may be contacted at pbarthet@barthet.com

---

Construction Firm Sues City and Engineers over Reservoir Project

October 28, 2011 — CDJ STAFF

The city of Fremont, Ohio and Arcadis have been sued by Trucco Construction. Trucco had been hired by the city to build a reservoir designed by Arcadis, the News-Messenger reports. Peter Welin, attorney for Trucco, said that he found “startling evidence of the company’s negligence” when he deposed Arcadis engineers. “This project could never be built the way they bid it.”

Their suit alleges that Arcadis and the city were aware that the site was not conducive to construction and also that Arcadis failed to be a neutral party in discussions between Trucco and the city regarding compensation.

Sam Wamper, an attorney for Fremont, said he was going to file a motion which would include “quite an interesting story,” but declined to elaborate.

Read the full story...

Read the court decision
Read the full story...
Reprinted courtesy of

---

Construction Law Client Advisory: What The Recent Beacon Decision Means For Developers And General Contractors

August 20, 2014 — Steven M. Cvitanovic and Whitney L. Stefko - Haight Brown & Bonesteel LLP
On July 3, 2014, the California Supreme Court (the “Court”) came out with its decision in Beacon Residential Community Association v. Skidmore, Owings & Merrill, et al. The Beacon decision settled a long-standing dispute in California about whether design professionals such as architects and engineers owe a duty to non-client third parties. In finding that the plaintiffs in Beacon could state a claim against the architects of the Beacon project, the Court also sowed the seeds of change in the way contracts are structured between developers, architects, engineers, and even general contractors. So, how will Beacon change the landscape for developers and general contractors? It is important to understand the factual background in Beacon to predict how the decision may alter the playing field. For a detailed analysis of the Amicus briefs in the Beacon matter from the AIA, the CBIA, and the Consumer Attorneys of California, please click here. The Beacon case arose from a common development model in California: a developer conceives a multi-unit project, maps the project as a condo development but rents as apartments. Shortly after completion of the Beacon project, the developer sold the entire project and the new owner finalized the existing condominium map and placed the units on the market as condominiums. Although the architects always knew they had designed a residential structure, the project ultimately became a condominium development. The newly formed homeowners’ association filed a construction defect suit against the developers, general contractor, the subcontractors and the architects for design and construction defects. Reprinted courtesy of Steven M. Cvitanovic, Haight Brown & Bonesteel LLP and Whitney L. Stefko, Haight Brown & Bonesteel LLP Mr. Cvitanovic may be contacted at scvitanovic@hbblaw.com; Ms. Stefko may be contacted at wstefko@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Coverage for Construction Defects Barred By Exclusion j (5)

April 15, 2015 — Tred R. Eyerly – Insurance Law Hawaii
The Texas Court Appeal reversed a trial court judgment which found coverage in favor of the contractor based upon exclusion j(5). Dallas Nat'l Ins. Co. v. Calitex Corp., 2015 Tex. App. LEXIS 2002 (Tex. Ct. App. March 3, 2015). Turnkey Residential Group, Inc., was the contractor to construct a twelve-unit townhome complex in Dallas. The owner of the project was Calitex Corporation. Construction began on November 2006. The project was to be completed by Turnkey by October 27, 2007. Calitex filed suit against Turnkey and some of its subcontractors in February 2008. Calitex alleged problems with Turnkey's work included: (1) the stone exterior was not properly treated and leaked, and some areas were left uncovered with stone; and (2) windows leaked. It was further alleged that the quality of materials, labor and craftsmanship did not meet the standards of the contract and resulted in damages. Turnkey submitted a notice of claim to its insurer, Dallas National Insurance Company (DNIC). Coverage was denied. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

New York Court Enforces Construction Management Exclusion

March 14, 2018 — Traub Lieberman Straus & Shrewsberry LLP
In its recent decision in Houston Cas. Co. v. Cavan Corp. of NY, Inc., 2018 N.Y. App. Div. LEXIS 1138 (N.Y. 1st Dep’t Feb. 20, 2018), a New York appellate court had occasion to consider the application of a construction management exclusion in a general liability policy. Read the court decision
Read the full story...
Reprinted courtesy of Traub Lieberman Straus & Shrewsberry LLP

---

I.M. Pei, Architect Who Designed Louvre Pyramid, Dies at 102

July 01, 2019 — James S. Russell - Bloomberg
I.M. Pei, a dominant figure in American architecture for more than three decades who designed the Louvre’s crystal pyramid and the angular East Building of Washington’s National Gallery of Art, has died. He was 102. His son Li Chung Pei said on Thursday that his father had died overnight, the New York Times reported. Pei gave “this century some of its most beautiful interior spaces and exterior forms,” said the jury of the Pritzker Architecture Prize, which Pei won in 1983. Though reserved and supremely diplomatic, Pei’s face, always crowned by round thick-rimmed glasses, could break unexpectedly into a wide, dazzling smile. He approached clients with charm and a quick wit, and they usually succumbed happily. Read the court decision
Read the full story...
Reprinted courtesy of James S. Russell, Bloomberg

---

Washington State Updates the Contractor Registration Statute

June 17, 2015 — Beverley BevenFlorez-CDJ STAFF
Ryan W. Sternoff of Ahlers & Cressman PLLC, analyzed SHB 1749, which recently amended RCW 18.27.010, Washington State’s legislature’s contractor’s registration statute. According to Sternoff, “a broad reading of the contractor’s registration statute, RCW Ch. 18.27, would require just about any person or entity, other than a residential homeowner, who is involved at any level in improving real property to be registered as a ‘Contractor,’ irrespective if that person or entity hired a licensed contractor to perform work on real property that they own.” SHB 1749 amended the statute “so that those who ‘offer to sell their property without occupying or using the structures, projects, developments or improvements’ are excluded from the definition of ‘contractor’ and not required to be registered, provided that the person or entity ‘contracts with a registered general contractor and does not superintend the work.’” Read the court decision
Read the full story...
Reprinted courtesy of

---