Fairfield Connecticut Building Expert Directory

Fundamental Fairness Trumps Contract Language

September 24, 2014 — Craig Martin – Construction Contractor Advisor
The Texas Supreme Court recently ruled that a “no-damages-for-delay” clause would not be enforced where the delay was caused by the owner. The court’s ruling flies squarely in the face of the contract language that attempted to insulate the owner from any delay claims, even those it caused. In the case of Zachary Construction v. Port of Houston underlying contract, proposed by the Port of Houston, was heavy handed, to say the least. The contract provided: “[Contractor] shall receive no financial compensation for delay or hindrance to the Work. In no event shall the Port Authority be liable to [Contractor] … for any damages arising out of or associated with any delay or hindrance to the Work, regardless of the source of the delay or hindrance, including events of Force Majeure, AND EVEN IF SUCH DELAY OR HINDRANCE RESULTS FROM, ARISES OUT OF OR IS DUE IN WHOLE OR IN PART, TO THE NEGLIGENCE, BREACH OF CONTRACT OR OTHER FAULT OF THE PORT AUTHORITY. [Contractor’s] sole remedy in any such case shall be an extension of time.” Wow, that’s some one-sided language. If the contract was enforced, the contractor could not get any damages for delay, even those damages caused by the active interference of the Port of Houston. Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

Fluor Agrees to $14.5M Fixed-Price Project Cost Pact with SEC

September 25, 2023 — Debra K. Rubin - Engineering News-Record
Fluor Corp. has agreed to pay $14.5 million to resolve a U.S. Securities and Exchange Commission investigation for alleged “improper accounting” and "overly optimistic" cost and timing estimates in bidding two legacy fixed-price projects that forced the company to restate its 2020 financial results, the agency said on Sept. 6. Reprinted courtesy of Debra K. Rubin, Engineering News-Record Ms. Rubin may be contacted at rubind@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

New York Construction Practice Team Obtains Summary Judgment, Dismissal of Labor Law §240(1) Claim Against Municipal Entities

August 19, 2024 — Lewis Brisbois Newsroom
New York, N.Y. (August 8, 2024) – In Josan v. City of New York, et al., New York Associate Jonathan A. Bartlett, a member of New York Partner Meghan A. Cavalieri’s Construction Practice Team, recently obtained summary judgment and dismissal of the plaintiffs’ Labor Law §240(1) claim against the City of New York, the New York City School Construction Authority, and the New York City Department of Education. The plaintiff alleged to have sustained injuries as the result of a construction site accident occurring on January 9, 2020, while in the scope of his employment as a forklift operator in connection with the construction/renovation of a school building in Brooklyn, New York. Specifically, the plaintiff alleged that he was injured when a forklift he was operating in order to lift scaffold frame materials tipped over, causing him disabling injuries. The plaintiffs’ counsel articulated an eight-figure initial settlement demand. Read the court decision
Read the full story...
Reprinted courtesy of Lewis Brisbois

Colorado Senate Revives Construction Defects Reform Bill

March 01, 2017 — Beverley BevenFlorez-CDJ STAFF
A re-booted construction defects reform bill recently passed its first Senate committee, according to the Denver Business Journal. Next, Senate Bill 156, sponsored by Sen. Owen Hill, R-Colorado Springs, heads to the Senate floor for debate. SB 156 “would require that condominium owners alleging construction defects take their disputes to arbitration or mediation if requested by builders,” the Denver Business Journal reported. “It also would require that homeowners be informed of the consequences of filing legal actions over purported disputes and that a majority of all owners in a condominium complex vote to proceed with legal action, rather than just a majority of homeowners association board members.” However, it is almost identical to the failed measures that were introduced in 2014 and 2015. Homeowners association group members and owners of defective condominiums argued against the measure, stating “that the effort would not improve the quality of building in the state, but simply would block aggrieved Coloradans from taking their complaints before a jury of their peers.” Proponent of the bill, Tom Clark, CEO of Metro Denver Economic Development Corp., said “that Denver’s housing costs have risen since the first bill was introduced in 2013 to the sixth-most-expensive in the country – and are tops for any metro area not on a coast.” Read the court decision
Read the full story...
Reprinted courtesy of

Update: Where Did That Punch List Term Come From Anyway?

December 21, 2016 — Duane Craig – Construction Informer
I’ve often wondered just where the term “punch list” came from, and I’ve found a few sources that seem to make sense, while others not so much. Enter the Realm of Conjecture and Opinion One person claims it came from the telephone installer process of “punching down” terminals on a block. That seems a bit of a stretch though. A blog writer said it had to do with the term ‘punch’ since it means to “punch something up” as in fix it. Another blog writer thought it had something to do with a long forgotten practice. Apparently subcontractors used to each have their own hole punches that would punch a hole with a shape unique to them. They would use these punches to indicate they had corrected the deficiency that was their responsibility. Read the court decision
Read the full story...
Reprinted courtesy of Duane Craig, Construction Informer
Mr. Craig may be contacted at dtcraig@constructioninformer.com

Harmon Tower Demolition on Hold

December 11, 2013 — CDJ STAFF
CityCenter has raised a scenario out of a blockbuster movie in which an earthquake causes the tower to fall onto the Cosmopolitan or the Crystals mall, leading to lawsuits, investigations, and “plummeting stock prices.” But that didn’t sway Clark County District Judge Elizabeth Gonzales from putting a hold on the demolition of the tower. FM Global, CityCenter’s insurer, has requested more time to examine the building’s problems in order to determine how to act on CityCenter’s claim of total loss. Tutor Perini, the company that built the tower, agrees with the delay, since any monies from FM Global would reduce Tutor Perini’s liability. If FM Global denies the claim, the price for the builder would go up, should they fail at trial. That trial is now scheduled for April. Read the court decision
Read the full story...
Reprinted courtesy of

Harmon Tower Demolition on Hold Due to Insurer

November 27, 2013 — CDJ STAFF
Permission for CityCenter to demolish Harmon Tower over claims of dangerous construction defects have been withdrawn by the judge in the case after the building’s insurer said it needed more time to investigate. After they were granted permission to demolish the building on August 23, CityCenter filed a claim of total loss with their insurer FM Global on August 27. Now FM Global is saying that they need to further inspect the building. Meanwhile, a demolition contractor has already gained approval to start removing the exterior glass. And things stand, it looks as if that won’t be happening on the planned date of December 2. CityCenter contends that FM Global has already done their inspections, describing FM Global’s prior actions as “the most extensive investigation of anyone,” according to Mark Ferrario, an attorney for CityCenter. Also, the initial plan to implode the building has been rejected. Should demolition proceed, the building will be dismantled floor by floor. Read the court decision
Read the full story...
Reprinted courtesy of

Let the 90-Day Countdown Begin

February 11, 2019 — Amy L. Pierce & Robert A. James - Gravel2Gavel Construction & Real Estate Law Blog
Most contractors are diligent about making sure that they pay their licensing fees, renew worker’s compensation insurance, and maintain the required bonds. What may be less obvious is how critically important it is to have current company personnel listed on the company’s licensing records with the Contractor’s State Licensing Board. Only personnel listed on the CSLB’s records are authorized to act on behalf of the licensee with respect to CSLB-related matters. Although this may sound simple enough, all such personnel will be required to comply with fingerprinting (and background check) requirements before their applications to be added to the company’s licensing records can be approved. No new personnel will be associated with the licensee until their application is determined to be acceptable and all other requirements are met. Unforeseeable processing delays could result in this new personnel being unable to timely act on behalf of the licensee. Reprinted courtesy of Amy L. Pierce, Pillsbury and Robert A. James, Pillsbury Ms. Pierce may be contacted at amy.pierce@pillsburylaw.com Mr. James may be contacted at rob.james@pillsburylaw.com Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES