FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Mutual Or Concurrent Delay Caused By Subcontractors

March 23, 2020 — David Adelstein - Florida Construction Legal Updates
How are delay damages treated when two subcontractors cause a mutual or concurrent delay to the project? Assume multiple subcontractors concurrently contributed to an impact to the critical path resulting in a delay to the project. The delay caused the prime contractor to: (1) be assessed liquidated damages from the owner and (2) incur extended general conditions. The prime contractor will be looking to the subcontractors for reimbursement for any liquidated damages it is assessed along with its extended general conditions costs. There is really no great case that addresses this point when two (or more) subcontractors mutually or concurrently delay the project. It is also not uncommon, and frankly expected, that a subcontractor will point the finger at another subcontractor for the cause of the delay or that another subcontractor was concurrently delaying the project. The prime contractor should absolutely, without any exception, undertake efforts with a scheduling consultant to allocate the delay caused by subcontractors. Taking an approach that joint and several liability applies between multiple subcontractors and/or not trying to apportion delay because the subcontractors concurrently delayed the critical path at the same time is probably not the best approach. The prime contractor should have an expert render an opinion as to the allocation of the delay period amongst responsible subcontractors that delayed the critical path. Not doing so, in my opinion, is a mistake. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Florida Supreme Court: Notice of Right to Repair is a CGL “Suit,” SDV Amicus Brief Supports Decision

January 10, 2018 — Gregory Podolak & Brian Clifford - SD&V Case Alert
Construction policyholders in Florida have been given substantial ammunition to compel general liability insurers to provide a defense against pre-suit accusations of defective work. Florida is one of approximately thirty (30) states that require property owners to serve contractors with notice and an opportunity to repair construction defects before filing suit. Only a few states have addressed whether a CGL policy should provide a defense for similar processes. Altman Contractors, Inc. v. Crum & Forster Specialty Ins. Co., decided late in December by the Florida Supreme Court, acknowledged that the 558 process is a “suit,” thus impeding insurers from refusing a defense during this notice period. Section 558.004(1), Florida Statutes (2012) requires a property owner alleging construction defects to serve a written notice to repair on the contractor before filing an action in court. Altman Contractors built a condominium in Broward County, Florida. In 2012, the condominium owners alleged defects in accordance with Section 558. Altman demanded that its general liability carrier, Crum & Forster, defend and indemnify it against the 558 notices. Crum & Forster denied coverage, claiming that 558 notices are not a “suit” as defined by the policy. Reprinted courtesy of Gregory Podolak, Saxe Doernberger & Vita, P.C. and Brian Clifford, Saxe Doernberger & Vita, P.C. Mr. Podolak may be contacted at gdp@sdvlaw.com Mr. Clifford may be contacted at bjc@sdvlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Loan Snarl Punishes Spain Builder Backed by Soros, Gates

July 30, 2014 — Katie Linsell, Manuel Baigorri and Ruth David – Bloomberg
Pressure is mounting on Esther Koplowitz to refinance personal loans before a deadline tomorrow and allow a Spanish builder that counts Bill Gates and George Soros among investors to resolve its own debt tangle. Koplowitz is renegotiating about 1 billion euros ($1.8 billion) of debt tied to her controlling stake in Fomento de Construcciones & Contratas SA, according to two people familiar with the matter, who asked not to be identified because it’s private. Her determination to retain control means that she is unlikely to approve any plan by FCC to raise equity until she refinances her own debt, the people said. Ms. Linsell may be contacted at klinsell@bloomberg.net; Mr. Baigorri may be contacted at mbaigorri@bloomberg.net; Ms. David may be contacted at rdavid9@bloomberg.net Read the court decision
Read the full story...
Reprinted courtesy of Katie Linsell, Manuel Baigorri and Ruth David, Bloomberg

---

Three Key Takeaways from Recent Hotel Website ADA Litigation

April 26, 2021 — Shane Singh & Grace Mehta - Lewis Brisbois
Despite the COVID-19 pandemic and its chill on the hospitality industry, ADA-related digital lawsuits increased by approximately 23% in 2020. Many of these lawsuits are filed against hotels. The complaints allege that a hotel’s online reservation system failed to provide enough detail for individuals with disabilities to decide if the hotel meets their accessibility needs. These plaintiffs will often claim that it is insufficient to describe an aspect of a hotel or room as “accessible” because the term is an opinion or conclusion. Plaintiffs argue that a hotel’s reservation system must report specific information, such as the dimensions of space under accessible desks and sinks, the slopes of surfaces, doorway clearance, and numerous other technical requirements under the ADA. Many hotels are fighting back, arguing that the detail provided is sufficient and in compliance with the ADA. So far this year, in February 2021, two judges in the U.S. District Court for the Central District of California, Judge Percy Anderson and Judge Cormac Carney, agreed with the defendants, dismissing three cases with prejudice. Reprinted courtesy of Shane Singh, Lewis Brisbois and Grace Mehta, Lewis Brisbois Mr. Singh may be contacted at Shane.Singh@lewisbrisbois.com Ms. Mehta may be contacted at Grace.Mehta@lewisbrisbois.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Housing to Top Capital Spending in Next U.S. Growth Leg: Economy

September 24, 2014 — Shobhana Chandra – Bloomberg
Bruce Hottle’s $10,000 computer systems upgrade in February at his Pennsylvania concrete plant may be his last investment for another two years. More than 1,100 miles south in suburban Miami, Maggie Cruz-Ledon and her husband have set a 2015 deadline to buy a house, upping their budget in the process. Hottle’s and Cruz-Ledon’s plans represent a sneak peek into the next leg of the expansion. Housing and business capital spending, two areas closely tied to swings in the world’s largest economy, are poised to diverge as home construction gives growth more of a boost in the long run while investment in new plants and equipment shows less promise, according to economists at Goldman Sachs Group Inc. and Morgan Stanley. Read the court decision
Read the full story...
Reprinted courtesy of Shobhana Chandra, Bloomberg
Ms. Chandra may be contacted schandra1@bloomberg.net

---

In South Carolina, Insurer's Denial of Liability Does Not Waive Attorney-Client Privilege for Bad Faith Claim

October 14, 2019 — Ashley L. Cooper & Bethany L. Barrese - Saxe Doernberger & Vita, P.C.
Determining the scope of discovery can be challenging, particularly when an insurance bad faith claim is involved. Courts often face the difficult decision of weighing the importance of preserving attorney-client privilege with the public policy rationale of protecting an insured against their insurer’s bad faith behavior. The Supreme Court of South Carolina recently recognized this dilemma by rejecting a hardline approach to bad faith discovery disputes and adopting a case-by-case analysis. The case, In re Mt. Hawley Ins. Co.,1 arose out of a construction defect claim. ContraVest Construction Company (“ContraVest”) constructed a development in South Carolina and was later sued for alleged defective construction. ContraVest sought coverage for the lawsuit from its insurers, including Mount Hawley Insurance Company (“Mount Hawley”), which had provided excess commercial liability insurance to ContraVest during the relevant timeframe. Mount Hawley denied the claim, which prompted ContraVest to sue it for bad faith, breach of contract, and unjust enrichment. Reprinted courtesy of Ashley L. Cooper, Saxe Doernberger & Vita, P.C. and Bethany L. Barrese, Saxe Doernberger & Vita, P.C. Ms. Cooper may be contacted at alc@sdvlaw.com Ms. Barrese may be contacted at blb@sdvlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

In Hong Kong, You Can Find a Home Where the Buffalo Roam

September 17, 2014 — Shai Oster – Bloomberg
To city dwellers worried about mice and rats, spare a thought for Hong Kongers confronting half-ton feral beasts. A few miles from some of the most densely populated neighborhoods in the world, more than 1,000 cows and buffalo from abandoned farms roam the countryside. Development now is pushing them into harm’s way and onto roads. Hong Kong represents an extreme example of the task many communities face of balancing conservation and growth. Wolves sniff near the suburbs of Paris, bears roam Lake Tahoe and moose stumble across the roads of Halifax. There’s a new word to describe how undomesticated animals adapt to man-made environments: synurbanization. Read the court decision
Read the full story...
Reprinted courtesy of Shai Oster, Bloomberg
Shai Oster may be contacted at soster@bloomberg.net

---

Rent Increases During the Coronavirus Emergency Part II: Avoiding Violations Under California’s Anti-Price Gouging Statute

April 06, 2020 — Dan Schneider - Newmeyer Dillion
In my earlier article, Profiting From Fear: What You Need to Know About Price Gouging During the Coronavirus Emergency, I discuss price gouging and how the anti-price gouging statute, California Penal Code 396 (“CPC 396”), protects buyers of goods and services deemed vital and necessary for the health, safety and welfare of consumers. Part II of the article provides guidance to landlords on the parameters applicable to acceptable price increases and focuses attention on the application of CPC 396 to rental housing and related issues. California Penal Code 396 As it pertains to housing, defined as “any rental housing with an initial lease term of no longer than one year,” price gouging occurs when a landlord increases the rent of an existing or prospective tenant by more than 10 percent of the previously charged or advertised price following an emergency or disaster declaration for a period of 30 days.2 A residential landlord is only allowed to increase rent in excess of 10 percent if “the increase is directly attributable to additional costs for repairs or additions beyond normal maintenance that were amortized over the rental term that caused the rent to be increased greater than 10 percent or that an increase was contractually agreed to by the tenant prior to the proclamation or declaration” (CPC 396(e).) Further, landlords are prohibited from evicting a tenant and then re-renting the property at a rate that the landlord would have been prohibited from charging the evicted tenant under the statute (CPC 396(f).)3 Read the court decision
Read the full story...
Reprinted courtesy of Dan Schneider, Newmeyer Dillion
Mr. Schneider may be contacted at daniel.schneider@ndlf.com

---