FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

What Every Project Participant Needs to Know About Delay Claims

August 05, 2024 — Andrew G. Vicknair - The Dispute Resolver
A “delay” on a construction project is defined as the stretching out of the time for completion of certain key milestone scopes of work which can impact the completion date of an entire project, due to some circumstances or events that were not reasonably anticipated when the project began. 2 Construction Law ¶ 6.01 (Matthew Bender, 2024). While delays can be caused by any number of events, the most common are defective plans and specifications; design changes; severe weather and other, similar unforeseeable events; unforeseen or differing site conditions; unavailability of materials or labor; labor inefficiencies or stoppages; contractor negligence; and owner influences, including construction changes or outright interference by the owner or its agents. If the project schedule is not recovered following a delay, then the project schedule will likely be extended, resulting in an increase in the contractor’s costs of performance. A contractor that has experienced a delay on a project can take certain actions to pursue recovery of any damages the contractor may have incurred. However, to do so it is important to understand the different types of delays and the methods for establishing the delays. I. Types of Delays Delays may be categorized as (1) critical versus non-critical delays, (2) excusable versus non-excusable delays, and (3) compensable versus non-compensable delays. A critical delay is a delay that affects the project completion date and delays the entire project. In essence, a critical delay is one that will extend the critical path of a project. A non-critical delay is a delay that has no effect on the project’s critical path. Courts have recognized that delays to work not on the critical path will generally not delay the completion of a project. G.M. Shupe, Inc. v U.S., 5 Cl. Ct. 662, 728 (1984). Such a non-critical delay may affect the completion of certain activities, but does not affect the completion date of the entire project. In order for a delay to provide the basis for a claim for additional time or money, the delay must impact critical path activities on the project schedule. Read the court decision
Read the full story...
Reprinted courtesy of Andrew G. Vicknair, D'Arcy Vicknair, LLC
Mr. Vicknair may be contacted at agv@darcyvicknair.com

---

Faulty Workmanship may be an Occurrence in Indiana CGL Policies

April 07, 2011 — Beverley BevenFlorez CDJ STAFF

The question of whether construction defects can be an occurrence in Commercial General Liabilities (CGL) policies continues to find mixed answers. The United States District Court in Indiana denied the Plaintiff’s Motion for Summary Judgment in the case of General Casualty Insurance v. Compton Construction Co., Inc. and Mary Ann Zubak stating that faulty workmanship can be an occurrence in CGL policies.



Judge Theresa L. Springmann cited Sheehan Construction Co., et al. v. Continental Casualty Co., et al. for her decision, ”The Indiana Supreme Court reversed summary judgment, which had been granted in favor of the insurer in Sheehan, holding that faulty workmanship can constitute an ‘accident’ under a CGL policy, which means any damage would have been caused by an ‘occurrence’ triggering the insurance policy’s coverage provisions. The Indiana Supreme Court also held that, under identically-worded policy exclusion terms that are at issue in this case, defective subcontractor work could provide the basis for a claim under a CGL policy.”



As we reported on April 1st, South Carolina’s legislature is currently working on bill S-431 that would change the wording of CGL policies in their state to include construction defects. Ray Farmer, Southwest region vice president of the American Insurance Association spoke out against the bill. “CGL policies were never meant to cover faulty workmanship by the contractor,” he said. “The bill’s supplementary and erroneous liability provisions will only serve to unnecessarily impact construction costs in South Carolina.”

 

Read the Opinion and order... 
Read the court’s ruling... 
Read the American Insurance Association statement...

Read the court decision
Read the full story...
Reprinted courtesy of

---

Federal Government Partial Shutdown – Picking Up the Pieces

February 27, 2019 — Jacob W. Scott -
Now that the partial shutdown has ended (though with the specter of another just around the corner), contractors are asking, “What now?” and “What did that cost me?” Although every case is fact-specific, following are some guidelines for moving forward after the shutdown. Following up on our previous guidance, contractors should make sure that any court, board, or agency filings made during the shutdown were received and properly docketed. If there is any question whether a filing was received, file it again as soon as possible with proof of the earlier attempt to file. The busiest tribunals, such as the federal courts, the Court of Federal Claims, the Boards of Contract Appeals, and the Government Accountability Office, remained open, or at least open to accept filings, and all indications are that filings made during the shutdown were received and acknowledged. But for some of the other tribunals or agencies, such as the Small Business Administration (“SBA”) Office of Hearings and Appeals and the SBA Office of Government Contracting and Business Development, prudence dictates double-checking that all filings were received. In many cases, non-statutory deadlines have been or will be adjusted by the court, board, or agency. Read the court decision
Read the full story...
Reprinted courtesy of Jacob W. Scott, Smith Currie
Mr. Scott may be contacted at jwscott@smithcurrie.com

---

San Francisco Office Secures Defense Verdict in Legal Malpractice Action

November 25, 2024 — Lewis Brisbois Newsroom
San Francisco, Calif. (October 31, 2024) - After a ten-day jury trial in San Francisco Superior Court, Partner Alex Graft recently secured a defense verdict in a legal malpractice action arising out of underlying litigation with the claimants’ homeowners association. The claimants alleged his client attorneys negligently advised them that the terms of the settlement agreement would result in the creation of a so-called independent board of directors for the homeowners association. It did not come to fruition. After the attorneys withdrew, they sued for their outstanding fees, which elicited a cross-complaint alleging malpractice, breach of fiduciary duty, breach of contract and negligent misrepresentation. Read the court decision
Read the full story...
Reprinted courtesy of Lewis Brisbois

---

Tips for Drafting Construction Contracts

May 04, 2020 — Stuart Rosen - Construction Executive
When negotiating a construction contract, a contractor and its advisers must first determine the areas of greatest concern. For example, if the contractor believes that the drawings that were prepared by the architect and other design professionals are deficient, the contractor may want to reference those deficiencies in the contract. The contractor should emphasize that it is not responsible for the drawings and to the extent the project schedule is extended to allow the parties to address such issues with the drawings, the contractor would be entitled to additional compensation. This article provides contractors with additional tips, with a broad focus on project delays, for their protection when negotiating and drafting construction contracts, and helps contractors understand the rationale for such tips to better prepare contractors in such negotiations. Contractor’s liability to the owner for delay damages It is imperative that the contract include a waiver of claims for consequential damages. AIA Document A201TM – 2017 includes such a waiver, which provides, in pertinent part, “The Contractor and Owner waive Claims against each other for consequential damages arising out of or relating to this Contract … This mutual waiver is applicable, without limitation, to all consequential damages due to either party’s termination in accordance with Article 14.” Reprinted courtesy of Stuart Rosen, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of
Mr. Rosen may be contacted at srosen@proskauer.com

---

BHA has a Nice Swing Donates to CDCCF

May 21, 2014 — Beverley BevenFlorez-CDJ STAFF
Bert L. Howe & Associates (BHA) would like to congratulate the winners of the BHA Has a Nice Swing golf game for charity. With the help of the participants, BHA was able to donate $1800 to the Construction Defect Community Charitable Foundation (CDCCF). CDCCF was established to provide financial assistance for active members of the construction defect community who have uninsured expenses because of a disability, sickness, and/or the death of a community member or their immediate family member. BHA would also like to congratulate their booth’s raffle winners. Prizes included an iPad Air, four sets of Dodger tickets, a Day at the Del Mar Races, and Best Buy gift cards. Read how the CDCCF assists the construction defect community... Read the court decision
Read the full story...
Reprinted courtesy of

---

Idaho Construction Executive Found Guilty of Fraud and Tax Evasion

October 01, 2013 — CDJ STAFF
A former president of the Associated General Contractors in Idaho has been found guilty of attempting to defraud the U.S. Government. Elaine Martin filed false income taxes, allowing her to participate in a program that helped economically and socially disadvantaged businesses. Ms. Martin has convicted on both the fraud tax evasion charges. Ms. Martin’s business partner, Darrell Swigert, has also been convicted. He was found guilty of obstruction of justice. Mr. Swigert helped Ms. Martin conceal the extent of her income. Read the court decision
Read the full story...
Reprinted courtesy of

---

New York Labor Laws and Action Over Exclusions

February 01, 2021 — Theresa A. Guertin & Ashley McWilliams - Saxe Doernberger & Vita, P.C.
One of the most important methods for shifting risk in the construction context is insurance coverage. Upstream parties such as owner/developers and general contractors typically require that their downstream subcontractors who perform work on their properties or projects bring specific insurance to the table. These insurance requirements have a twofold purpose: protect the upstream parties, through additional insured coverage, from liabilities caused by the subcontractor; and protect the downstream parties by ensuring that they have adequate insurance for their own potential liabilities. In New York, subcontractor insurance coverage can have some surprising terms which frustrate risk transfer. Numerous policies contain “Action Over” exclusions, which bar coverage for one of the most significant exposures faced by owner-developers and general contractors: bodily injury lawsuits brought by subcontractor employees. It is critical that upstream parties understand the unique impact of New York’s labor laws on the insurance market and be prepared to identify and request removal of Action Over exclusions on subcontractor insurance policies. Reprinted courtesy of Theresa A. Guertin, Saxe Doernberger & Vita, P.C. and Ashley McWilliams, Saxe Doernberger & Vita, P.C. Ms. Guertin may be contacted at TGuertin@sdvlaw.com Ms. McWilliams may be contacted at AMcWilliams@sdvlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---