SEATTLE WASHINGTON BUILDING EXPERT
DIRECTORY AND CAPABILITIES

California Appeals Court Remands Fine in Late Completion Case

November 18, 2011 — CDJ STAFF

The California Court of Appeals in Stanislaus County has reversed the decision of the lower court in Greg Opinski Construction Inc. v. City of Oakdale. The earlier court had awarded the city of judgment of $54,000 for late completion, $3,266 for repair of construction defects and interest, and $97,775 in attorneys’ fees. The late completion of the project was due to actions by the City of Oakdale, however, the court rejected Opinski’s argument that the California Supreme Court decision in Kiewit did not allow this, as his contract with the city established a procedure for claiming extensions.

The appeals court noted that the Kiewit decision has been “criticized as an unwarranted interference in the power of contracting parties to shift the risk of delays caused by one party onto the other party by forcing the second party to give the first notice of any intention to claim an extension of time based on delays caused by first.” They cited Sweet, a professor at Boalt Hall, UC Berkeley’s law school, that Kiewit “gutted” the “provision that conditions the contractor’s right to claim an extension of time for delays beyond his control.”

Further changes in California law in response to the Kiewit decision lead to the current situation which the court characterized as “if the contractor wished to claim it needed an extension of time because of delays caused by the city, the contractor was required to obtain a written change order by mutual consent or submit a claim in writing requesting a formal decision by the engineer.”

Opinski also argued that the lower court misinterpreted the contract. The Appeals court replied that “Opinski is mistaken.” He cited parts of the contract regarding the increase of time, but the court rejected these, noting that “an inability to agree is not the same as an express rejection.”

The court also rejects Opinski’s appeal that “the evidence the project was complete earlier than September 30, 2005, is weightier than the evidence to the contrary,” which they describe as “not a winning appellate argument.” The court points out that the role of an appeals court is not to reweigh the evidence, but to determine “whether the record contains substantial evidence in support of the judgment.”

The court did side with Opinski on one question of the escrow account. They rejected most of his arguments, repeating the line “Opinski is mistaken” several times. They decided that he was mistaken on the timing of the setoff decision and on whether the city was the prevailing party. However, the appeals court did find that Opinski was not liable for interest on the judgment.

The appeals court rejected the awarding of prejudgment interest to the city as the funds from which the judgment was drawn was held in an escrow account. The court noted that the city had access to the funds and could “access the funds when it determined that Opinski had breached the contract.” The appeals court noted that the judgment exhausted the escrow balance and remanded the case to the lower court to determine the amount own to Opinski.

Read the court’s decision…

Read the court decision
Read the full story...
Reprinted courtesy of

---

California Superior Court Overrules Insurer's Demurrer on COVID-19 Claim

February 15, 2021 — Tred R. Eyerly - Insurance Law Hawaii
A Superior Court in California overruled the insurer's demurrer to the policy holder's complaint seeking business interruption coverage after government shutdown orders were issued because of the coronavirus pandemic. Goodwill Industries of Orange County, California v. Philadelphia Indemnity Ins. Co., Cal. Superior Ct., Civil No. 30-2020-01169032-CU-IC-CXC (Minute Order Jan. 28,, 2021). The minute order is here [Goodwill Decision]. The insurer demurred on the ground that the insured had not alleged sufficient facts to show "direct physical loss" under the business income, extra expenses and civil authority provisions in the policy because coronavirus and COVID-19 did not physically alter the structure. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Viva La France! 2024 Summer Olympics Construction Features Sustainable Design, Including, Simply Not Building at All

August 26, 2024 — Garret Murai - California Construction Law Blog
If you’re like me and many others you’ve probably been watching the 2024 Summer Olympics in Paris, France. We were in Paris last year and we passed the construction site of the Aquatics Centre, one of only three new permanent facilities that was constructed for this year’s Olympics. On a side note, Parisian Uber drivers are some of the most aggressive drivers I’ve seen, replete with honking, hand gestures, and cursing at other drivers and pedestrians in, of course, French. Putain! In recent history, Olympic construction costs have skyrocketed, often vastly exceeding the planned budgets of the host cities, and, in recent years, has caused even some host city hopefuls to reconsider whether to even throwing their hats in the ring. The 2020/2021Summer Olympics in Tokyo, for example, had an original budget of $7.5 billion. The actual cost was over $13 billion and, depending on what beans you count, may have been over twice that! Paris seeks to change all of this. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

---

First-Time Homebuyers Make Biggest Share of Deals in 17 Years

February 22, 2018 — Prashant Gopal – Bloomberg
Millennials are playing homeownership catch-up. First-time buyers rushed into the market last year, making 38 percent of all U.S. single-family home purchases, the biggest share since 2000, data released Thursday by Genworth Mortgage Insurance show. The 2.07 million new or existing homes bought by first-timers was 7 percent more than in 2016, according to the insurer, part of Genworth Financial Inc. Read the court decision
Read the full story...
Reprinted courtesy of Prashant Gopal, Bloomberg

---

Georgia Supreme Court Limits Damages Under Georgia Computer Systems Protection Act

March 01, 2017 — Chadd Reynolds – Autry, Hanrahan, Hall & Cook, LLP
On January 27, 2017, the Supreme Court of Georgia issued a decision determining whether the Georgia Computer Systems Protection Act (“GCSPA”) provides for punitive damages. While not directly related to construction, the GCSPA can be a potential mechanism for asserting claims against former employees that use company information stored in computers. Read the court decision
Read the full story...
Reprinted courtesy of Chadd Reynolds, Autry, Hanrahan, Hall & Cook, LLP
Mr. Reynolds may be contacted at reynolds@ahclaw.com

---

N.J. Governor Fires Staff at Authority Roiled by Patronage Hires

August 20, 2019 — Elise Young, Bloomberg
New Jersey Governor Phil Murphy’s administration fired 30 employees of a state authority that finances local school construction after an independent review found that his former appointee stacked it with friends, family and political contacts who were unqualified for their jobs. All but three of those dismissed Tuesday from the Schools Development Authority had been hired by Lizette Delgado-Polanco, the former chief executive officer who resigned in April amid media scrutiny of her oversight. A review by an outside law firm faulted the agency for “patronage-type hires” that undermined its work. Read the court decision
Read the full story...
Reprinted courtesy of Elise Young - Bloomberg

---

Evolving Climate Patterns and Extreme Weather Demand New Building Methods

May 22, 2023 — Annette Rubin - Construction Executive
Compared to the rest of the world, most buildings in the United States are relatively young. But most residential and commercial properties could use a makeover. Buildings constructed over twenty, fifty and one hundred years ago are, unsurprisingly, not as energy-efficient or as safe as new builds following modern methods—especially when considering the effects of climate change and more frequent extreme weather events on the integrity of that infrastructure. According to the National Association of Home Builders, over 90% of new homes built in the United States today are wood-framed. These homes are incapable of withstanding a tornado or hurricane, yet they are still being built directly in the path of storms. Even buildings constructed in some of the most earthquake-prone areas of the U.S. may contain design flaws that make them susceptible to damage because they are built using a non-ductile concrete method, which experts say has an inadequate configuration of steel reinforcing bars—making the building vulnerable when shaken. While this building method was banned for new construction, it is not yet required to retrofit older construction to improve safety and structural integrity. Reprinted courtesy of Annette Rubin, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

---

Definitions Matter in Illinois: Tenant Held Liable Only for Damage to Apartment Unit

September 09, 2024 — Gus Sara - The Subrogation Strategist
In Phila. Indem. Ins. Co. v. Gonzalez, No. 1-23-0833, 2024 Ill. App. Unpub. LEXIS 1372, the Appellate Court of Illinois considered whether the terms of a lease agreement limited a tenant’s liability for fire damages, a fire caused by her negligence, to her apartment unit only. The plaintiff insured the subject apartment building, which incurred damage to several units as result of a fire in the tenant’s unit. The lease defined “Premises” as the specific apartment unit occupied by the tenant and held the tenant responsible for damage caused to the Premises. While the court found that the lease permitted the plaintiff to subrogate against the tenant, it held that the lease terms limited the damages to the tenant’s apartment unit only. In Gonzalez, the plaintiff’s insured owned a multi-unit apartment building in Chicago. In September 2019, the building owner entered into a lease agreement with the defendant for apartment Unit 601. The lease stated that Unit 601 was the “Leased Address (Premises).” Another provision stated that building owner “hereby leases to Tenant(s) and Tenant(s) hereby leases from Landlord(s) for use as a private dwelling only, the Premises, together with the fixtures and appliances (if any) in the premises…” The lease also stated that “Tenant shall be liable for any damage done to the premises as a result of Tenant’s or Tenant’s invitees, guests or others authorized to reside in the Premises [sic] direct action, negligence, or failure to inform Landlord of repairs necessary to prevent damage to the Premises.” Read the court decision
Read the full story...
Reprinted courtesy of Gus Sara, White and Williams
Mr. Sara may be contacted at sarag@whiteandwilliams.com

---