FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Employee Exclusion Bars Coverage for Wrongful Death of Subcontractor's Employee

June 11, 2014 — Tred R. Eyerly – Insurance Law Hawaii
The Fifth Circuit determined the deceased was a statutory employee of the general contractor under Florida law, thereby barring coverage for the general contractor. Stephens v. Mid-Continent Casualty Co., 2014 WL 1623737 (11th Cir. April 24, 2014). The decedent fell from a ladder while working to install a modular home. Critically injured, he died on the way to the hospital. The decedent was an employee of Team Fritz, a subcontractor hired to set the modular home on its foundation. The general contractor, Anchorage Homes LLC, had a liability policy with Mid-Continent. Damages relating to injuries to any of Anchorage's employees were excluded under the policy. Mid-Continent denied coverage contending that under Florida law, Team Fritz's employees were "statutory employees" of Anchorage. The law provided that the employees of a subcontractor were deemed to be employees of the contractor. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Zero-Net Energy Homes Costly Everywhere but at the Electric Meter

August 27, 2013 — CDJ STAFF
On one hand, your walls are about nine inches thick. On the other hand, your heating and cooling costs are nonexistent. Greenhill Contracting is building “zero-net energy” homes in New Paltz, New York. The homes are designed to create more power than they consume. In addition to the walls, which WDTN News describes as “castle thick,” the homes include solar panels, triple-glazed windows, and geothermal heating and cooling systems. The cost for a three-bedroom home in this development starts at about $400,000. Meritage Homes is offering net-zero as an option on its homes. Based in Arizona, Meritage builds homes across the country. Another national builder, Shea Homes, calls its net-zero option “SheaXero,” and has built about a thousand in four western states and in Florida. One Arizona homeowner notes that she runs her air conditioner constantly, but “I still have never paid more than $18 and some change.” Sometimes she even gets a credit. Read the court decision
Read the full story...
Reprinted courtesy of

---

Making the World’s Longest Undersea Railway Tunnel Possible with BIM

December 11, 2018 — Aarni Heiskanen - AEC Business
Finland and Estonia are Baltic sea neighbors separated by the Gulf of Finland. Over eight million travelers and 1.2 million cars travel between Helsinki and Tallinn every year by boat. However, a consortium of companies is now planning to build the Finest railway tunnel between the two countries. The vision of such a tunnel has been around since the 1990s. In June 2016, Peter Vesterbacka, previously known as the marketer behind Rovio’s Angry Birds, made the latest endeavor public in his AEC Hackathon presentation. Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

---

California Condo Architects Not Liable for Construction Defects?

May 13, 2014 — Beverley BevenFlorez-CDJ STAFF
Law360 reported that attorneys for the architects of a San Francisco, California condominium complex told the California Supreme Court that the designers “can’t be held liable for construction defects that caused units to overheat” and urged “the panel to reverse a lower court's ruling that the architects owed a duty of care to the condos’ buyers.” The California appeals court ruling was based on California’s Right to Repair Act, however, “that law doesn’t apply to condo conversions.” The architects argued that since Beacon was “designed and originally rolled out as rental apartments before the units were sold as condos” the Right to Repair Act doesn’t apply. However, Beacon Residential Community Association’s attorney Robert Riggs of Katzoff & Riggs “argued that the architects had a ‘cradle to grave’ involvement in the development of the Beacon.” Riggs stated, “They designed a very large building with essentially no ventilation system, along with windows that don't open.” According to Law360, “[t]he justices took the arguments under submission and did not indicate which way they would rule.” Read the court decision
Read the full story...
Reprinted courtesy of

---

Construction Recovery Still Soft in New Hampshire

May 10, 2013 — CDJ STAFF
The latest building news out of New Hampshire is somewhat mixed. Yes, there has been an increase of seventeen percent in the value of future residential construction on the state. But that’s not enough to offset the general slide in the value of future construction overall. The New Hampshire Business Review reports that the state saw a four percent drop in the cost of planned construction, comparing March 2012 to March 2013. The total value of the drop was shared between the twelve percent drop in nonresidential construction and the fifty-two percent drop in infrastructure building, each of which were more than $4 million less than in the prior year. The rise in residential construction could not make up the loss in other areas. Read the court decision
Read the full story...
Reprinted courtesy of

---

Delays Caused When Government (Owner) Pushes Contractor’s Work Into Rainy / Adverse Weather Season

January 13, 2020 — David Adelstein - Florida Construction Legal Updates
There are a number of horizontal construction projects where a contractor’s sequence of work and schedule is predicated on avoiding the rainy season (or certain force majeure events). The reason is that the rainy season will result in delays due to the inability to work (and work efficiently) during the adverse weather (including flooding caused by the weather). If the work is pushed into the rainy season, is such delay compensable if the government (or owner) delayed the project that pushed work out into the rainy season? It very well can be. For example, in Meridian Engineering Co. v. U.S., 2019 WL 4594233 (Fed. Cl. 2019), a contractor was hired by the Army Corps of Engineers to construct a flood control project for a channel in Arizona. Due to delays, including those caused by the government, the project was pushed into the monsoon season, which caused additional delays largely due to flooding caused by the heavy rain. One issue was whether such delays were compensable to the contractor – the government raised the argument that the contractor assumed the risk of potential flooding from the rainy season. The Court found this argument unconvincing:

[The contractor’s] initial construction schedule planned for a completion of the channel invert work, a necessary step in protecting the site from flooding, to be completed by late June 2008…[M]any issues arose in the project’s early stages that led to cumulative substantial delay, including those caused by the government’s failure….The government cannot now claim that [the contractor] assumed the risk of flooding from monsoon season when the government was largely responsible for [the contractor’s] inability to complete the project prior to the beginning of the monsoon season. Simply put, the government cannot escape liability for flood damages when the government is responsible for causing the contractor to be working during the flood-prone season. Meridian Engineering, 2019 WL at *7 (internal citations omitted)

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

If Passed, New Bill AB 2320 Will Mandate Cyber Insurance For State Government Contractors

September 07, 2020 — Makenna Miller & Jeffrey Dennis - Newmeyer Dillion
Earlier this year, Assemblyman Edwin Chau (D-Monterey Park) introduced Assembly Bill 2320. AB 2320, if passed, would require any business that contracts with the state and has access to records containing personal information protected under the state’s Information Practices Act (IPA) to maintain cyber insurance coverage. Information covered under the IPA includes names, social security numbers, physical descriptions, home addresses, home telephone numbers, education, financial matters, and medical or employment history. Requiring contractors to maintain cyber insurance will likely both shift the costs of cyberattacks from taxpayers to the private sector, while also encouraging robust cyber security practices among businesses of all sizes. While the bill has not yet passed, businesses will be best served by implementing and improving cybersecurity practices now in order to attain lowest premium rates in the future. Incentivizing Best Practices With the adoption of AB 2320, businesses will be incentivized to increase their security posture in order to receive lower premiums from insurers. Simultaneously, insurers will be incentivized to mandate best practices from their insureds in order to mitigate their risk of having to pay out on cyber insurance policies. Thus, cyber insurance will work as a vehicle to increase best practices in businesses and subsequently decrease vulnerabilities to cyberattacks. Reprinted courtesy of Makenna Miller, Newmeyer Dillion and Jeffrey Dennis, Newmeyer Dillion Ms. Miller may be contacted at makenna.miller@ndlf.com Mr. Dennis may be contacted at jeff.dennis@ndlf.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Differing Site Conditions Produce Differing Challenges

February 18, 2019 — Sarah E. Carson - Smith Currie
The saying “The best laid plans of mice and men often go awry” can too often apply in the construction industry. A contractor may receive a description of site conditions that is ultimately found flawed or misleading. The costs associated with addressing these surprise conditions often fall on the contractor to pay. The following article details proactive steps to avoid costly obstacles that may cause a project’s success to go awry. What are Differing Site Conditions? There are generally two recognized types of differing site conditions. The first, often referred to as a “Type I Changed Condition,” exists when a specification in the conditions indicated in the contract documents varies from what is represented. The second category, generally referred to as a “Type II Changed Condition,” is a variance so unusual in its nature that it materially differs from conditions ordinarily encountered in performing the type of work called for in the geographic area where the project is located. Read the court decision
Read the full story...
Reprinted courtesy of Sarah E. Carson, Smith Currie
Ms. Carson may be contacted at secarson@smithcurrie.com

---