Fairfield Connecticut Building Expert Directory

Cliffhanger: $451M Upgrade for Treacherous Stretch of Highway 1 in British Columbia

July 31, 2023 — Aileen Cho - Engineering News-Record
Rugged Construction | Part Three of an ENR Series Winding along the edges of steep slopes deep in the eastern forests of British Columbia, a stretch of Highway 1 offers stunning vistas for commuters and visitors as they traverse Kicking Horse Canyon. But the 70-plus-year-old two-lane highway also has been susceptible to rockfalls, avalanches and traffic accidents involving both humans and wildlife. Reprinted courtesy of Aileen Cho, Engineering News-Record Ms. Cho may be contacted at choa@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

LAX Runway Lawsuit a Year Too Late?

January 17, 2014 — Beverley BevenFlorez-CDJ STAFF
The City of Los Angeles filed a lawsuit against Tutor-Saliba Corp. and O&G Industries Inc., which had created a joint venture to rebuild Runway 25L at Los Angeles International Airport (LAX), according to Brian Sumers writing for the Daily Breeze. However, lawyers for the construction companies are alleging that the lawsuit was filed a year too late: “…the complaint’s first four causes of action against Joint Venture are indisputably barred under California Law,” lawyers from Castle & Associates claimed. This news came soon after a plane blew a tire on the same runway involved in the lawsuit, as reported by the Los Angeles Times. The blown out tire may not be related to the alleged construction defects: “The runway is usable,” Nancy Castles, spokeswoman for Los Angeles World airports told the Los Angeles Times. Castles explained that “the lawsuit is about ‘deterioration’ and that at some point the runway will need to be rebuilt, but that time is not now.” Read the full story at the Daily Breeze... Read the full story at the Los Angeles Times... Read the court decision
Read the full story...
Reprinted courtesy of

Federal Court Rejects Insurer's Argument that Wisconsin Has Adopted the Manifestation Trigger for Property Policy

April 03, 2013 — Tred Eyerly - Insurance Law Hawaii
The federal district court disagreed with the insurer's strident claim that Wisconsin followed the manifestation trigger for deciding coverage under a homeowner's policy. Strauss v. Chubb Indem. Ins. Co., 2013 U.S. Dist. LEXIS 224 (E.D. Wis. Jan. 2, 2013). Several years after their house was constructed, the insureds discovered water damage. Chubb denied the claim. The insureds sued. Chubb moved for summary judgment and argued that the loss first manifested many years after its policy expired. Further, Chubb argued that Wisconsin followed the manifestation trigger for first-party property insurance, meaning that only the insurance policy in effect when the loss manifested was required to respond. Read the court decision
Read the full story...
Reprinted courtesy of Tred Eyerly
Tred Eyerly can be contacted at te@hawaiilawyer.com

Texas Supreme Court Cements Exception to “Eight-Corners” Rule Through Two Recent Rulings

March 06, 2022 — Jeremy S. Macklin - Traub Lieberman Insurance Law Blog
The Texas “eight corners” rule precludes insurers from disclaiming a defense obligation based on facts not alleged in the underlying pleadings. Texas federal and appellate courts have been issuing rulings addressing exceptions to the eight corners rule and recently sought guidance from the Texas Supreme Court on whether Texas law recognizes such exceptions to the “eight corners” rule. The Texas Supreme Court has now spoken on the issue. Monroe Guar. Ins. Co. v. BITCO Gen. Ins. Corp., 65 Tex. Sup. Ct. J. 440 (2022). In Monroe, David Jones contracted with 5D Drilling & Pump Services in the summer of 2014 to drill a 3,600-foot commercial irrigation well on his farmland. In 2016, Jones sued 5D for breach of contract and negligence relating to 5D’s drilling operations on Jones’s property. Jones’s pleading was silent as to when the damage flowing from 5D’s alleged acts of misconduct occurred. BITCO and Monroe stipulated that 5D’s drill struck a bore hole during 5D’s drilling operations in or around November 2014. Read the court decision
Read the full story...
Reprinted courtesy of Jeremy S. Macklin, Traub Lieberman
Mr. Macklin may be contacted at jmacklin@tlsslaw.com

A Few Things You Might Consider Doing Instead of Binging on Netflix

April 13, 2020 — Garret Murai - California Construction Law Blog
Governments throughout the world have issued “shelter in place” orders requiring that residents stay at home except for “essential” purposes. As a result, in the United States, more than a third of Americans have been ordered to stay at home. This, in turn, has had a direct impact on construction projects which have slowed or have been temporarily shuttered altogether, and it will (not may) have an impact on the flow of project funds. So what can project owners and contractors do? We’ve got a few tips. 1. Read Your Contract, Paying Particular Attention to Force Majeure, No Damages for Delay and Notice Provisions For the most part, with the exception of statutory rights and remedies which we will discuss below, your contract spells out your rights and remedies should the proverbial “S” hit the fan. It is, in other words, the rules you agreed to, and you should know what those rules provide. Three provisions you should look for, and if they’re in your contract, you should review carefully are: (1) Force majeure provisions; (2) No damages for delay provisions; and (3) notice provisions. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

Chinese Lead $92 Billion of U.S. Home Sales to Foreigners

July 09, 2014 — John Gittelsohn – Bloomberg
Foreigners purchased $92.2 billion of U.S. homes in the 12 months through March, led by buyers from China, according to the National Association of Realtors. Spending by Chinese buyers soared 72 percent from a year earlier to $22 billion, with their purchases accounting for 24 percent of spending by international buyers, the trade association said today from Washington. Total investments by foreigners jumped 35 percent. Chinese buyers acquired 16 percent of houses sold to foreigners, up 4 percentage points, spurred by currency appreciation, rising affluence and concerns about an economic slowdown in the world’s most-populous country, the group said. Read the court decision
Read the full story...
Reprinted courtesy of John Gittelsohn, Bloomberg
Mr. Gittelsohn may be contacted at johngitt@bloomberg.net

Defining Constructive Acceleration

March 22, 2021 — David Adelstein - Florida Construction Legal Updates
When it comes to the definition of “constructive acceleration,” the case of Fraser Const. Co. v. U.S., 384 F.3d 1354 (Fed.Cir. 2004) is a cited case and contains an instructive definition, quoted below, for proving a constructive acceleration claim. In a nutshell, a constructive acceleration claim is when the contractor incurs added costs for trying to complete the contract on time when it should be provided extensions of time to perform based on excusable delay (i.e., delay not caused by the contractor). These added costs could be bringing in additional supervision to manage the work, adding manpower to perform the work, working overtime, working weekends, adding more shift work, stacking trades, etc. However, just because a contractor claims they have been constructively accelerated does not make it so. The contractor has to actually ask for an extension of time based on an excusable delay and the owner either denied the extension or unreasonably sat on the request for an extension of time; thus, the contractor incurred significant costs to accelerate in order to finish the project on time because it was deprived of a requested time extension for excusable delay. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Fix for Settling Millennium Tower May Start This Fall

August 17, 2020 — Nadine M. Post - Engineering News-Record
With the lengthy and complex permitting and approval process complete and almost all the other details worked out, construction could begin in mid-November on the estimated $100-million shoring fix for the 645-ft-tall Millennium Tower in San Francisco. The perimeter pile upgrade for the 58-story residential condominium building, which has settled more than 17 in. toward the northwest since its completion in 2009, was originally expected to begin earlier this year. Nadine M. Post, Engineering News-Record Ms. Post may be contacted at postn@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES