Fairfield Connecticut Building Expert Directory

Delays Caused When Government (Owner) Pushes Contractor’s Work Into Rainy / Adverse Weather Season

January 13, 2020 — David Adelstein - Florida Construction Legal Updates
There are a number of horizontal construction projects where a contractor’s sequence of work and schedule is predicated on avoiding the rainy season (or certain force majeure events). The reason is that the rainy season will result in delays due to the inability to work (and work efficiently) during the adverse weather (including flooding caused by the weather). If the work is pushed into the rainy season, is such delay compensable if the government (or owner) delayed the project that pushed work out into the rainy season? It very well can be. For example, in Meridian Engineering Co. v. U.S., 2019 WL 4594233 (Fed. Cl. 2019), a contractor was hired by the Army Corps of Engineers to construct a flood control project for a channel in Arizona. Due to delays, including those caused by the government, the project was pushed into the monsoon season, which caused additional delays largely due to flooding caused by the heavy rain. One issue was whether such delays were compensable to the contractor – the government raised the argument that the contractor assumed the risk of potential flooding from the rainy season. The Court found this argument unconvincing:

[The contractor’s] initial construction schedule planned for a completion of the channel invert work, a necessary step in protecting the site from flooding, to be completed by late June 2008…[M]any issues arose in the project’s early stages that led to cumulative substantial delay, including those caused by the government’s failure….The government cannot now claim that [the contractor] assumed the risk of flooding from monsoon season when the government was largely responsible for [the contractor’s] inability to complete the project prior to the beginning of the monsoon season. Simply put, the government cannot escape liability for flood damages when the government is responsible for causing the contractor to be working during the flood-prone season. Meridian Engineering, 2019 WL at *7 (internal citations omitted)

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Three Kahana Feld Attorneys Selected to 2024 NY Metro Super Lawyers Lists

October 28, 2024 — Linda Carter - Kahana Feld
Kahana Feld is pleased to announce that Tim Capowski was selected to the 2024 NY Metro Super Lawyers list, and Christopher Theobalt and Sofya Uvaydov were selected to the 2024 NY Metro Rising Stars list. All three attorneys were recognized in the Appellate practice area. Tim Capowski is a partner at Kahana Feld and chair of the firm’s National Appellate Litigation & Consulting Group. He has spent the better part of three decades at the forefront of the insurance defense bar. Tim has litigated hundreds of appeals and thousands of motions in state and federal and appellate courts throughout New York and around the country. He handles a variety of complex litigation including catastrophic property and casualty claims, construction defect, professional liability, labor and employment law, mass torts, insurance coverage, and more. Read the court decision
Read the full story...
Reprinted courtesy of Linda Carter, Kahana Feld
Ms. Carter may be contacted at lcarter@kahanafeld.com

When a Construction Lender Steps into the Shoes of the Developer, the Door is Open for Claims by the General Contractor

February 18, 2015 — Kevin Brodehl – California Construction Law Blog
Thank you to my partner Garret Murai for giving me the opportunity to post again on his excellent California Construction Law Blog. I am the author/editor of the Money and Dirt Blog, where I focus on issues relating to real estate investment, development, and secured lending. On the Money and Dirt Blog, I recently posted an article on an interesting new secured lending opinion from the California Court of Appeal (Fourth District in Riverside), California Bank & Trust v. Del Ponti. That blog post focused on guaranty liability, and the court’s holding that there are limits to the defenses that a guarantor can lawfully waive. But that same decision also highlights valuable lessons regarding the relationship between construction lenders and general contractors in distressed projects, which I’ll cover here. In short, the court held that when a construction lender “steps into the shoes” of the developer to manage a distressed project, the lender might open the door to liability to the general contractor under theories of breach of contract and promissory estoppel. Read the court decision
Read the full story...
Reprinted courtesy of Kevin Brodehl, Wendel Rosen Black & Dean LLP
Mr. Bordehl may be contacted at kbrodehl@wendel.com

California Rejects Judgments By Confession Pursuant to Civil Code Section 1132

May 08, 2023 — Drew M. Jorgenson & Louis "Dutch" Schotemeyer - Newmeyer Dillion
The Elimination of Judgment by Confession Following in the footsteps of Massachusetts and Florida, California recently updated California Code of Civil Procedure section 1132 which renders judgments by confession unenforceable and inadmissible in any superior court, effective January 1, 2023. The bar is not retroactive, so judgments by confession obtained or entered before January 1, 2023 are still valid. Moving forward, consider the following. What is a Judgment By Confession? A judgment by confession, also known as a confession of judgment or "cognovit" clause, is a mechanism by which a debtor agrees that a creditor may summarily obtain a legal judgment against that debtor and enforce it in the event of the debtor's breach of contract or default. In other words, it is a private admission by a debtor that they are liable for a debt without the need for a trial, and consequently, agree to forfeit very important rights. Most importantly, parties agreeing to such clauses are waiving rights such as the right to notice of the judgment and the right to assert defenses against the creditor or third party's claims. Historically, without any judicial involvement, these types of out-of-court judgments would be enforceable. Reprinted courtesy of Drew M. Jorgenson, Newmeyer Dillion and Louis "Dutch" Schotemeyer, Newmeyer Dillion Mr. Jorgenson may be contacted at drew.jorgenson@ndlf.com Mr. Schotemeyer may be contacted at dutch.schotemeyer@ndlf.com Read the court decision
Read the full story...
Reprinted courtesy of

Bremer Whyte’s Newport Beach Team Prevails on a Motion for Summary Judgment in a Wrongful Death Case!

September 02, 2024 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
Congratulations on another win to Orange County Partners Jonathan Cothran and Rachel Mihai for prevailing on a Motion for Summary Judgment in a wrongful death case! Plaintiffs filed a wrongful death lawsuit alleging negligence and vicarious liability against BWB&O’s client, a licensed electrical contractor. BWB&O’s client installed a solar system at the Plaintiffs’ home in January 2018. In October 2018, an electrical fire broke out at the home in an upstairs bedroom. Tragically, the family’s father perished in the fire when he entered the home after the fire started. Plaintiffs alleged that BWB&O’s client was liable for the fire and Plaintiffs’ resulting injuries due to its electrical work on the solar system at the home. Read the court decision
Read the full story...
Reprinted courtesy of Dolores Montoya, Bremer Whyte Brown & O'Meara LLP

OSHA ETS Heads to Sixth Circuit

December 13, 2021 — George Morrison - White and Williams LLP
On November 16, 2021, the U.S. Court of Appeals for the Sixth Circuit was selected during the Judicial Panel on Multidistrict Litigation’s lottery to hear the multiple consolidated challenges to the recent COVID-19 Emergency Temporary Standard (ETS) issued by the Occupational Safety and Health Administration (OSHA). OSHA is permitted to issue an ETS if the agency arrives at the conclusion that a “grave danger” to worker safety exists. An ETS does not go through the typical notice-and-comment period that federal regulations usually follow. Inheriting the Fifth Circuit’s recent nationwide stay on implementation and enforcement of the ETS, the Sixth Circuit will decide whether the stay should be “modified, revoked, or extended” in the short term. Early this morning, OSHA filed an emergency motion to dissolve the Fifth Circuit’s stay of the vaccine mandate with the Sixth Circuit. OSHA argued, among other things:

The Fifth Circuit erred in holding “that OSHA lacked statutory authority to address the grave danger of COVID-19 in the place on the ground that COVID-19 is caused by a virus and also exists outside of the workplace” because “[t]hat rationale has no basis in the statutory text.”
The Fifth Circuit erred in finding the ETS both over- and underinclusive because “OSHA recounted extensive empirical data showing that all employees can transmit COVID-19 in the workplace and that COVID-19 has spread in a vast variety of workplace.”
The “petitioners have not shown that their claimed injuries outweigh the interests in protecting employees from a dangerous virus while this litigation proceeds . . . . These claimed injuries do not justify delaying the [ETS] that will save thousands of lives and prevent hundreds of thousands of hospitalizations.”

Read the court decision
Read the full story...
Reprinted courtesy of George Morrison, White and Williams LLP
Mr. Morrison may be contacted at morrisong@whiteandwilliams.com

Insurer's Appeal of Jury Verdict Rejected by Tenth Circuit

March 06, 2023 — Tred R. Eyerly - Insurance Law Hawaii
After a jury awarded damages related to the insurer's delayed payment under the claim and the insurer's post trial motions to set aside the verdict were denied, the Tenth Circuit affirmed. US General, LLC v. GuideOne Mut. Ins. Co., 2022 U.S. App. LEXIS 34066 (10th Cir. Dec. 12, 2022). Crossroads American Baptist Church submitted a claim to GuideOne for hailstorm damage. Crossroads hired US General as the general contractor to perform the repairs and later assigned its interest in the insurance policy to US General. Numerous disputes arose between Crossroads and GuideOne regarding the cost of the repairs. There were delayed payments and portions of the repairs were never paid for. The delayed payments meant GuideOne's ability to begin making the repairs was hindered because it was more expensive to start and stop a project. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Netflix Plans $900M Facility At Former New Jersey Army Base

January 23, 2023 — The Associated Press (Wayne Parry) - Bloomberg
(AP) -- Netflix said Wednesday it plans to build a state-of-the-art production facility at a former Army base at the Jersey Shore that will cost more than $900 million, and create thousands of jobs. The subscription video streaming company will pay $55 million for a 292-acre site on the former Fort Monmouth military base in Eatontown and Oceanport. The California-based company plans an additional $848 million worth of investments in 12 sound stages and for other uses related to the film industry. “We’re thrilled to continue and expand our significant investment in New Jersey and North America,” said Ted Sarandos, the company's co-CEO and chief content officer. “We believe a Netflix studio can boost the local and state economy with thousands of new jobs and billions in economic output, while sparking a vibrant production ecosystem in New Jersey.” Read the court decision
Read the full story...
Reprinted courtesy of Bloomberg

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES