Fairfield Connecticut Building Expert Directory

Just When You Thought General Contractors Were Necessary Parties. . .

November 30, 2020 — Christopher G. Hill - Construction Law Musings
Did you think that a subcontractor had to name a general contractor in a mechanic’s lien suit? I did. Did you think that nothing about this changed in the case where a Virginia mechanic’s lien was “bonded off” pursuant to Va. Code Section 43-71? I did. Well, a recent Virginia Supreme Court case, Synchronized Construction Services Inc. v. Prav Lodging LLC, seems to at least create some doubt as to whether the a general contractor is a “necessary” party to a lawsuit by a subcontractor in the case where a bond is posted for release of a mechanic’s lien. In Prav Lodging, the facts were a bit unusual. The day after the mechanic’s lien was recorded by Synchronized Construction Services, Inc. (“Synchronized”) the construction manager, Paris Development Group, the construction manager and de facto general contractor, went out of business. Despite this fact, and after the lien was bonded off, Synchronized sued to enforce the lien and for breach of contract against Paris. The wrinkle here is that Synchronized was unable to serve several defendants, among them Paris, within one year of filing suit as required by Virginia statute. In the Circuit Court, the financing bank moved to dismiss the suit for failure to serve necessary parties. The Circuit Court dismissed the breach of contract count but refused to dismiss the mechanic’s lien count on this basis. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Does a No-Damage-for-Delay Clause Also Preclude Acceleration Damages?

January 27, 2020 — Ted R. Gropman & Christine Z. Fan - ConsensusDocs
Construction contracts often include a “no damage for delay” clause that denies a contractor the right to recover delay-related costs and limits the contractor’s remedy to an extension of time for noncontractor-caused delays to a project’s completion date. Depending on the nature of the delay and the jurisdiction where the project is located, the contractual prohibition against delay damages may well be enforceable. This article will explore whether an enforceable no-damage-for-delay clause is also a bar to recovery of “acceleration” damages, i.e., the costs incurred by the contractor in its attempt to overcome delays to the project’s completion date. Courts are split as to whether damages for a contractor’s “acceleration” efforts are distinguishable from “delay” damages such that they may be recovered under an enforceable no-damage-for-delay clause. See, e.g., Siefford v. Hous. Auth. of Humboldt, 223 N.W.2d 816 (Neb. 1974) (disallowing the recovery of acceleration damages under a no-damage-for-delay clause); but see Watson Elec. Constr. Co. v. Winston-Salem, 109 N.C. App. 194 (1993) (allowing the recovery of acceleration damages despite a no-damage-for-delay clause). The scope and effect of a no-damage-for-delay clause depend on the specific laws of the jurisdiction and the factual circumstances involved. There are a few ways for a contractor to circumvent an enforceable no-damage-for-delay clause to recover acceleration damages. First, the contractor may invoke one of the state’s enumerated exceptions to the enforceability of the clause. It is helpful to keep in mind that most jurisdictions strictly construe a no-damage-for-delay clause to limit its application. This means that, regardless of delay or acceleration, courts will nonetheless permit the contractor to recover damages if the delay is, for example, of a kind not contemplated by the parties, due to an unreasonable delay, or a result of the owner’s fraud, bad faith, gross negligence, active interference or abandonment of the contract. See Tricon Kent Co. v. Lafarge N. Am., Inc., 186 P.3d 155, 160 (Colo. App. 2008); United States Steel Corp. v. Mo. P. R. Co., 668 F.2d 435, 438 (8th Cir. 1982); Peter Kiewit Sons’ Co. v. Iowa S. Utils. Co., 355 F. Supp. 376, 396 (S.D. Iowa 1973). Reprinted courtesy of Ted R. Gropman, Pepper Hamilton LLP and Christine Z. Fan, Pepper Hamilton LLP Mr. Gropman may be contacted at gropmant@pepperlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Insurer Must Indemnify Additional Insured After Settlement

October 21, 2015 — Tred R. Eyerly – Insurance Law Hawaii
The court determined that Target was an additional insured under its supplier's policy and the insurer had a duty to indemnify Target after it settled the underlying suit. Selective Ins. Co. v. Target Corp., 2015 U.S. Dist. LEXIS 123230 (E.D. Ill. Sept. 15, 2015). Angela Brown sued Target when she was allegedly injured by a door to a fitting room that came unhinged and fell on her head. Harbor Industries, Inc. supplied Target with its fitting rooms. Pursuant to the "Supplier Qualification Agreement" (SQA), Harbor named Target as an additional insured under its policy with Selective Insurance Company. The SQA became effective and was to remain in effect until terminated by either party. A second agreement, the "Program Agreement," set forth the terms under which Harbor sold the fitting rooms to Target. The Program Agreement went into effect on April 23, 2009, and expired on July 1, 2010. Brown's injury occurred on December 17, 2011, while the SQA and the policy were in effect, but after the Program Agreement expired. After Brown's injury, Target tendered to Selective, who denied coverage, contending Target was not an additional insured. The policy's endorsement expanded insureds to any additional insured whom Harbor agreed in a written contract to add as an additional insured. Selective filed suit and the parties filed cross-motions for summary judgment. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Coverage Denied for Insured's Defective Product

October 15, 2014 — Tred R. Eyerly – Insurance Law Hawaii
The court found there was no coverage obligations for the insured's defective product. Titanium Indus., Inc. v. Federal. Ins. Co., 2014 WL 4428324 (N.J. Super. Ct. App. Div. Sept. 10, 2014). The insured, Titanium Industries, supplied titanium bar materials to Biomet Manufacturing Corporation. Biomet manufactured orthopedic implants and devises. The titanium was used to manufacture screws to incorporate into Biomet's products. Biomet notified the insured of a potential defect in some of the titanium material, described as "alloy segregation," i.e., the failure of alloys in a metal to completely melt, causing the alloy to separate and undermine the strength of the finished product. The insured and Biomet negotiated a settlement, which included lost profits and the cost of returning the titanium. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Matthew Graham Named to Best Lawyers in America

September 10, 2018 — Garret Murai - California Construction Law Blog
Wendel Rosen’s very own Matt Graham has been selected for inclusion in The Best Lawyers in America© 2019 in the area of Construction Law. First published in 1983, Best Lawyers is the oldest and most respected peer-review publication in the legal profession. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel, Rosen, Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

Appraisal Panel Can Determine Causation of Loss under Ohio Law

February 19, 2024 — Tred R. Eyerly - Insurance Law Hawaii
The federal district court granted the insured's motion to compel an appraisal that would include a determination of causation of the loss. Eagle Highland Owners Association v. State Farm Fire and Casualty Co., 2023 U.S. Dist. LEXIS 220937 (S.D. Ohio Dec. 12, 2023). Plaintiff argued its property suffered wind and hail damage from a storm on June 18, 2021. A claim was submitted to State Farm. State Farm's investigation determined the loss to be $0.00. Plaintiff's investigator determined the loss to be $586,647.08 in repair costs. State Farm opposed appraisal because, in its view, the damage arose from a loss in 2019, not from the June 18, 2021 storm. Plaintiff submitted a loss claim in 2019 for damage that State Farm alleged was exactly the same as the damage alleged in the loss claim for the June 18, 2021 storm. Therefore, State Farm did not view the matter as a dispute over an amount of loss, but rather over whether a loss even occurred on June 18, 2021. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Women Make Slow Entry into Building Trades

December 04, 2013 — CDJ STAFF
In the next seven years, about 200,000 carpenters will be added to workforce, but few of those are likely to be women. Sylas Demello, an electrical apprentice noted that it isn’t “made clear for women in high school to say, ‘hey, this is an option for you.’” Tiffany Bluemle is trying to do something about that. She runs Vermont Works for Women, which trains women for jobs in which there are few women, including the building trades. She notes that “seventy-five percent of owners say they face labor shortages.” Amy Judd is now one of those owners. Fifteen years ago, failing to find a teaching job, she started working as a carpenter. “It had never occurred to me that I would want to be a carpenter,” she said. Her firm employs eight people, half of whom are women. Read the court decision
Read the full story...
Reprinted courtesy of

Roots of Las Vegas Construction Defect Scam Reach Back a Decade

August 05, 2013 — CDJ STAFF
Recent court documents in the Las Vegas HOA scandal reveal that the late Nancy Quon, thought to be a mastermind in the scam was involved with a similar case before 2001. The Las Vegas Review-Journal reports that the Nevada attorney general’s office launched an investigation of the Starfire condominium complex. Claims were made that an architect and a construction company attempted to fill the Starfire board with straw buyers. Quon represented a resident to filed a claim over defective windows. Chris Rasmussen, the attorney for Edith Gillespie, Leon Benzer’s half sister, has noted that his client was not charged in the Starfire case, but the Review-Journal notes that no one was, as the insurance company settled quickly, which ended the chances for a criminal investigation. The Starfire case is described as “a $6 million lawsuit based on fraudulent construction defect claims.” Quon, Benzer, and their co-conspirators are alleged to have modeled their subsequent actions after Starfire. Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES