SEATTLE WASHINGTON BUILDING EXPERT
DIRECTORY AND CAPABILITIES

The Construction Project is Late—Allocation of Delay

November 17, 2016 — David Adelstein – Florida Construction Legal Updates
The construction project is late. Very late. The owner is upset and notifies the contractor that it is assessing liquidated damages. The contractor, in turn, claims that the project is late because of excusable, compensable delays and, perhaps, excusable, noncompensable delays. This is a common and unfortunate story between an owner and contractor on any late construction project. Now the fun begins regarding the allocation of the delay! Through previous articles, I discussed that in this scenario the burden really falls on the contractor to establish that the liquidated damages were improperly assessed against it and, thus, it is entitled to additional time and/or extended general conditions as a result of excusable delays. Naturally, this requires the contractor to develop a critical path analysis (time impact analysis) allocating the impacts / delays (and the reasons for the impacts/ delays) to the project completion date. The reason the burden really falls on the contractor is because the owner’s burden is relatively easy – the project was not complete on time pursuant to the contract and any approved changed orders. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Katz, Barron, Squitero, Faust, Friedberg, English & Allen, P.A.
Mr. Adelstein may be contacted at dma@katzbarron.com

---

Intentional Mining Neighbor's Property is Not an Occurrence

October 30, 2018 — Tred R. Eyerly - Insurance Law Hawaii
The Kentucky Supreme Court determined there was no coverage when the insured was sued for mineral trespass. Am. Mining Ins. Co. v. Peters Farms, LLC, 2018 Ky. LEXIS 287 (Ky. Aug. 16, 2018). Beginning in 2007, Ikerd Mining. LLC removed 20,212 toms of coal from land belonging to Peters Farms, LLC. Of that amount, 10,012 tons were wrongfully mined under Ikerd's alleged mistaken belief as to the correct location of Peters' boundaries. The other 1,200 tons were mined by Ikerd knowing that the land thereunder belonged to Peters, but pursuant to a disputed oral lease agreement between the two. Peters claimed that the lease was an ongoing negotiation that was never finalized. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Covenant of Good Faith and Fair Dealing Applied to Pass-Through Agreements

June 19, 2023 — Scott D. Cessar - Construction Executive
Pass-through claims are claims by a party that has suffered damages but does not have a contractual relationship with the entity that caused the damages. In the construction industry, subcontractors commonly have claims for additional costs based on actions or inactions by the owner. However, since the subcontractor is not in privity of contract with the owner, it has no direct cause of action against the owner other than, perhaps, on a nongovernment project, a lien claim. In such cases, subcontractors may seek to pass the claim through the general contractor, who is in privity with the owner, to the owner. Indeed, many construction contracts require the subcontractor, in such cases of owner-caused damages, to pass the claim through the general contractor to the owner. And since the harm visited on a subcontractor by the owner usually also affected the general contractor, the subcontractor’s claim is packaged together with the general contractor’s claim, which is usually greater, for presentation to the owner and, if not resolved, litigation with the owner. Reprinted courtesy of Scott D. Cessar, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

---

Boston Water Main Break Floods Trench and Kills Two Workers

October 27, 2016 — Justin Rice – Engineering News-Record
Two workers died in Boston on Friday afternoon after a water main break flooded the trench where they were working, according to the Boston Fire Dept. Read the court decision
Read the full story...
Reprinted courtesy of Justin Rice, Engineering News-Record
Mr. Rice may be contacted at enrmidatlanticeditor@enr.com

---

Real Estate & Construction News Round-Up (11/03/21)

December 06, 2021 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
Amenity-rich buildings become a key focus in enticing employees back into the office, supply chain links are strained by a lack of storage capacity in warehouses and port areas, green lease signings are on the uptick, and more.

• In an effort to draw employees back into the office and retain talent in a tight labor market, businesses are spending more than ever on upscale workspaces, paying high rents for modern, amenity-rich buildings. (Peter Grant, The Wall Street Journal)
• As sustainability and ESG factors become increasingly important, net-zero carbon commitments are emerging as the next big “must-have” for commercial real estate owners, as more than 100 businesses and organizations have signed on to the World Green Building Council’s Net Zero Carbon Buildings Commitment, which seeks to decarbonize the buildings sector by 2050 and get halfway there by 2030. (Elsa Wenzel, GreenBiz)

Read the court decision
Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

---

Ohio Condo Owners Sue Builder, Alleging Construction Defects

September 10, 2014 — Beverley BevenFlorez-CDJ STAFF
Seventy-four condominium owners that reside in the Villas at Northstar in Westerville, Ohio, have sued Romanelli & Hughes, the builder, for alleged construction issues that led to water intrusion, according to The Columbus Dispatch. “There have been noted deficiencies at every building out there, with both the roofs and wall systems,” Kevin Fields, a partner at Kasman & Cusimano, the firm that is representing the condo owners, told The Columbus Dispatch. “There’s been severe water infiltration through the walls, which has caused underlying damage, and various roof leaks and roofs not properly secured — in essence, sliding off the buildings.” Counsel for the builder, Gabe Roehrenbeck, a partner with Thompson Hines law firm, stated that “he could not comment on the specifics of the case…because he has not had time to analyze it.” But he issued the statement, “Romanelli & Hughes is an award-winning builder that over the course of more than 40 years has built a reputation for client service and satisfaction.” Construction defects listed in the suit include “failure to install or improper installation of flashing, ice shields, roofing paper, shingles, control joints in stucco and weather-resistant barriers.” Read the court decision
Read the full story...
Reprinted courtesy of

---

The Power of Team Bonding: Transforming Workplaces for the Better

June 10, 2024 — Alexa Stephenson & Brittney Aquino - Kahana Feld
The number of civil Complaints filed in California has been steadily rising over the last few years. When employees struggle daily to make a dent in what seems as an insurmountable to-do list, taking time away from work to chat with coworkers about their weekends or the latest Netflix drop seems counterintuitive. Yet recent studies suggest that taking even 30 minutes away from your workday to engage in team bonding has lasting benefits. Investing in team bonding activities is not just about having fun; it is about creating a cohesive, motivated, and high-performing team that can drive organizational success. As the evidence suggests, the return on investment for team bonding activities is substantial, making it a vital component of any successful workplace strategy. Enhancing Communication and Collaboration One of the primary benefits of team bonding is improved communication among team members. Effective communication is the bedrock of any successful team, and activities designed to foster relationships can significantly enhance this aspect. A study conducted by MIT’s Human Dynamics Laboratory found that teams with higher levels of social interaction outside of formal meetings performed better than those with limited interaction. These teams were more cohesive, coordinated, and ultimately more productive. Bonding activities, as simple as group lunches or intensive as a weekend retreat, create opportunities for employees to interact in a relaxed setting. This helps break down barriers and encourages open communication, which translates into a more collaborative work environment. When employees feel comfortable sharing ideas and feedback, it leads to better problem-solving and innovation. Reprinted courtesy of Alexa Stephenson, Kahana Feld and Brittney Aquino, Kahana Feld Ms. Stephenson may be contacted at astephenson@kahanafeld.com Ms. Aquino may be contacted at baquino@kahanafeld.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Breaking News: Connecticut Supreme Court Decides Significant Coverage Issues in R.T. Vanderbilt

December 16, 2019 — Patricia B. Santelle & Ciaran B. Way - White and Williams LLP
On October 4, 2019 (almost two years after granting certification), the Connecticut Supreme Court affirmed the Appellate Court’s rulings on four key coverage issues in R.T. Vanderbilt Company v. Hartford Accident & Indemnity Company, et al. The coverage dispute in Vanderbilt concerns underlying actions alleging that talc and silica mined and sold by the insured contained asbestos and/or caused asbestos-related disease. The case has been proceeding in phases, two of which have been tried to date, resulting in the matter on appeal. (1) “Continuous Trigger” Theory of Coverage Applies: The Court affirmed and adopted the Appellate Court’s opinion applying a “continuous trigger” for the underlying claims at issue, and agreed that the trial court properly excluded testimony from medical experts the insurers had proffered to prove that the asbestos disease process did not support a continuous trigger. (2) The “Unavailability of Insurance” Exception to Time-on-Risk Pro Rata Allocation Applies: The Court affirmed and adopted the Appellate Court’s ruling that (a) damages and defense costs should not be allocated to any period in which insurance was “unavailable” in the market, (b) the insurers bear the burden of proving that coverage for asbestos liabilities was available to the policyholder after the date asbestos exclusions were added to the policies and (c) the insured bears the burden of proving that it was unable to obtain asbestos coverage prior to 1986 (when such insurance was generally available). The Appellate Court recognized that, in certain circumstances, there could be an “equitable exception” to the unavailability rule if the insured continued to manufacture products containing asbestos after 1986 with the knowledge that such products were hazardous and uninsurable (circumstances which the court found were not present in this case). Reprinted courtesy of Patricia B. Santelle, White and Williams LLP and Ciaran B. Way, White and Williams LLP Ms. Santelle may be contacted at santellep@whiteandwilliams.com Ms. Way may be contacted at wayc@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

---