Nine Gibbs Giden Partners Listed in Southern California Super Lawyers 2022
February 14, 2022 —
Gibbs Giden Locher Turner Senet & Wittbrodt, LLPPremiere law firm Gibbs Giden Locher Turner Senet & Wittbrodt, LLP announced that 9 of the firm's partners have been selected by their peers for inclusion in the 2022 Southern California Super Lawyers list.
The Super Lawyers lists are issued by Thomson Reuters. These lists honor no more than 5% of licensed attorneys in each state, based on peer recognition and professional achievements.
The following Gibbs Giden attorneys have been selected to the 2022 Southern California Super Lawyers list:
LOS ANGELES
Barbara Gadbois – Construction Law
Sara Kornblatt – Construction Law and Litigation
William (Bill) Locher - Real Estate and Business Law
Ted Senet – Insurance and Construction Law
Glenn Turner – Construction Law and Litigation
Richard Wittbrodt – Construction Law and Litigation, AAA Mediator/Arbitrator
IRVINE
Philip Zvonicek – Business, Corporate, Construction, Insurance Law
WESTLAKE
Jason Adams – Construction and Insurance Law
Christopher Ng – (Managing Partner) Construction and Business Law
Gibbs Giden understands the complex challenges companies face in today’s competitive business environment. From our roots in construction law to our evolution into a premier law firm serving the diverse needs of the business community, we provide the insight and advice our clients need to position themselves for the future.
www.gibbsgiden.com LOS ANGELES | IRVINE | SAN JOSE | WESTLAKE | LAS VEGAS
Read the court decisionRead the full story...Reprinted courtesy of
Pacing in Construction Scheduling Disputes
September 14, 2017 —
Luke Mecklenburg - Snell & Wilmer Real Estate Litigation BlogOn a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway.
However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48.
Read the court decisionRead the full story...Reprinted courtesy of
Luke Mecklenburg, Snell & WilmerMr. Mecklenburg may be contacted at
lmecklenburg@swlaw.com
GIS and BIM Integration Will Transform Infrastructure Design and Construction
October 09, 2018 —
Nicolas Mangon - Engineering News-RecordAn unfortunate fact of the architecture and engineering professions and the construction industry is that, between every stage of the process—from planning and design to construction and operations—critical data is lost.
Read the court decisionRead the full story...Reprinted courtesy of
Nicolas Mangon, ENRENR may be contacted at
ENR.com@bnpmedia.com
William Lyon to Acquire RSI Communities
February 22, 2018 —
Dave Suggs - CDJ STAFFAccording to the article “William Lyon Agrees to Buy RSI Communities $460 million deal plants Lyon in Texas and adds to Inland Empire land holdings” published on the website Builder, the Newport Beach home builder is purchasing the Southern California and Texas home builder. This will be Lyon Homes’ first venture in the state of Texas.
RSI Communities works within both San Antonio and Austin, Texas as well as Southern California and the Inland Empire. It was founded by Todd Palmaer, a home building expert and Ron Simon, a building products expert and Newport Beach businessman. First time home buyers have been RSI’s main target.
President and CEO of RSI, Tod Palmaer is optimistic about the acquisition “We are delighted to have our company join the William Lyon Homes organization. We have a great deal of confidence in the William Lyon Homes platform and its executive management team, and believe that its acquisition of RSI Communities will add to Lyon’s continued success in its current and new markets.”
Pat Donahue who has almost 30 years of experience in home building, will serve as President to the Inland Empire Division. John Bohnen, RSI’s present Chief Operating Officer, will be the regional president in Texas. Mr. Bohnen has previously held executive positions with numerous home builders. William Lyon’s president and CEO Mark R. Zaist is excited about adding RSI’s key players to their team, and had this to say about the purchase. “The acquisition of RSI represents our most significant acquisition since our entry into Portland and Seattle with the Polygon Northwest Homes acquisition in 2014 and furthers our strategy of building in the strongest markets in the Western U.S., while also strengthening our pipeline in Southern California, as we continue our mission of being the premier Western Regional home builder.”
Read the court decisionRead the full story...Reprinted courtesy of
French Laundry Spices Up COVID-19 Business Interruption Debate
April 20, 2020 —
Jeffrey J. Vita & Melanie A. McDonald - Saxe Doernberger & VitaOn March 26, 2020, Michelin-rated Napa Valley restaurants, French Laundry and Bouchon Bistro, and their celebrity chef, Thomas Keller, filed the second known
coronavirus-related declaratory judgment (DJ) lawsuit by a restaurant. The restaurants filed their DJ against Hartford Fire Insurance Company just seven days after Napa County issued a Shelter at Home Order.1 Chef Keller’s suit comes on the heels of the first such suit by a restaurant seeking to recover business income losses, filed by iconic New Orleans French Quarter restaurant Oceana Grill2 on March 17, just four days after the Louisiana governor issued an order prohibiting gatherings of more than 250 people.
As local governments seek to protect their citizens and prevent an onslaught of cases in area hospitals, they are issuing various “stay home,” “shelter at home,” and similar orders to force social distancing and to help flatten the curve of the growth in COVID-19 cases. Restaurants nationwide are especially hard hit by these orders, as many of these orders contain size limitations on gatherings, which have required that restaurants and bars limit capacity (as in the March 13th Louisiana order). Other such orders require non-essential businesses to “cease all activities in the County” (as in the Napa County Shelter at Home order). The Napa County order does not exempt restaurants as “essential businesses,” except when providing food for take-out or delivery. Other orders, still, directly address restaurants and require them to cease allowing public consumption of food and beverages (as in the subsequent, March 17th Louisiana order).
Reprinted courtesy of
Jeffrey J. Vita, Saxe Doernberger & Vita, P.C. and
Melanie A. McDonald, Saxe Doernberger & Vita, P.C.
Mr. Vita may be contacted at jjv@sdvlaw.com
Ms. McDonald may be contacted at mam@sdvlaw.com
Read the court decisionRead the full story...Reprinted courtesy of
Congratulations 2019 DE, NJ and PA Super Lawyers and Rising Stars
May 26, 2019 —
White and Williams LLPFifteen White and Williams lawyers have been named by Super Lawyers as a Delaware, New Jersey or Pennsylvania "Super Lawyer" while eight received "Rising Star" designations. Each lawyer who received the distinction competed in a rigorous selection process which took into consideration peer recognition and professional achievement. The lawyers named to this year's Super Lawyer list represent a multitude of practices throughout the firm.
Super Lawyers 2019 |
Attorney | Practice Area |
John Balaguer |
PI Defense: Med Mal |
Kevin Cottone |
PI Defense: Med Mal |
Thomas Goutman |
Class Action |
David Haase |
Business Litigation |
Christopher Leise |
Civil Litigation: Defense |
Randy Maniloff |
Insurance Coverage |
David Marion |
Business Litigation |
Peter Mooney |
Business Litigation |
Michael Olsan |
Insurance Coverage |
John Orlando |
General Litigation |
Wesley Payne |
Insurance Coverage |
Daryn Rush |
Insurance Coverage |
Anthony Salvino |
Workers’ Comp |
Patricia Santelle |
Insurance Coverage |
Andrew Susko |
Civil Litigation: Defense |
Read the court decisionRead the full story...Reprinted courtesy of
White and Williams LLP
WATCH: 2023 Construction Economic Update and Forecast
January 09, 2023 —
Construction ExecutiveConstruction Executive presented its "2023 Construction Economic Update and Forecast" webinar with
Associated Builders and Contractors Chief Economist Anirban Basu on Dec. 14, sponsored by
Aerotek,
Bluebeam,
CMiC and
Raken.
Basu started by announcing the Federal Reserve’s rate increase of 0.5%, the latest in a series of increases aimed at combating inflation. Calling 2022 a “year of tumult and a year of surprise,” Basu further noted that the Russian invasion of Ukraine surprised many, further disrupting global supply chains and causing a shockwave to ripple through global energy prices.
Citing the U.S. Consumer Price Index, with 7.1% year-over-year inflation in November, Basu believes we’ve “peaked in terms of inflation for this cycle”; while inflation hit higher-than-expected levels throughout 2022, it leveled off at lower-than-expected rates by the end of the year. Basu predicted inflation will continue to be problematic through 2023 as it has shifted from transitory inflation due to supply-chain disruptions in 2020 and 2022 to broader inflation due to the labor market, noting that the worst of the supply-chain issues seem to be over, reaching a high point in late 2021.
Blaming the injection of fiscal stimulus coming from the federal government, monetary stimulus from the Federal Reserve and the fact that inflation has now become ingrained in the economy and in people’s expectations, leading to wage and price increases, Basu calls the economy “overheated.”
Reprinted courtesy of
Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the court decisionRead the full story...Reprinted courtesy of
U.K. Broadens Crackdown on Archaic Property Leasehold System
October 23, 2018 —
Sree Vidya Bhaktavatsalam - BloombergThe U.K. government is cracking down on what it called “unfair” leasehold practices as part of sweeping reforms to its housing system, in a move that would modernize the property market to bring it more in line with nations such as the U.S.
Initially prompted by a malpractice scandal, the proposed scope of the focus by the Ministry of Housing, Communities & Local Government has become far broader. A consultation will seek views not only on the practice of charging buyers an annual fee for owning leasehold properties -- known as ground rents -- it will review the whole process of buying, selling and property management of leasehold homes.
Read the court decisionRead the full story...Reprinted courtesy of
Sree Vidya Bhaktavatsalam, Bloomberg