FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

OSHA Issues New Rules on Injury Record Keeping

August 19, 2015 — Craig Martin – Construction Contractor Advisor
On July 28, 2015, OSHA issued proposed rules seeking to clarify an employer’s ongoing obligation to make and maintain accurate records of work-related injuries and illness. The new rules were drafted in response to the U.S. Court of Appeals decision in AKM LLC, d/b/a Volks Constructors v. Secretary of Labor, in which a contractor successfully argued that OSHA’s citation was issued well beyond the six month limitation period. OSHA’s Injury Record Keeping Obligations The Occupational Safety and Health Act requires each employer to make, keep and preserve records of workplace injuries and illnesses. 29 U.S.C. § 658(c). OSHA has promulgated a set of regulations which require employers to record information about work-related injuries and illnesses in three ways. Employers must prepare an incident report and a separate injury log “within seven (7) calendar days of receiving information that a recordable injury or illness has occurred,” 29 C.F.R. § 1904.29(b)(3), and must also prepare a year-end summary report of all recordable injuries during the calendar year, id. § 1904.32(a)(2). An employer “must save” all of these documents for five years from the end of the calendar year those records cover. 29 C.F.R. § 1904.33(a). Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

---

Shifting the Risk of Delay by Having Float Go Your Way

July 05, 2021 — Christopher J. Brasco & Matthew D. Baker - ConsensusDocs
Critical path delay plays a central role in allocating responsibility for project delay. The interrelated concept of concurrency is also frequently determinative of entitlement on a range of claims including by owners for liquidated damages and by contractors for delay damages. What constitutes critical/concurrent delay, however, is hotly debated by scheduling experts. The lack of real consensus regarding how critical/concurrent delay should be determined and analyzed has created significant uncertainty in scheduling disputes. Indeed, courts have adopted differing and at times conflicting theories of concurrency that can produce divergent outcomes for the parties. In an effort to reduce uncertainty, stakeholders have increasingly adopted specialized contractual provisions and scheduling techniques which have significant implications for the evaluation of the companion concepts of criticality and concurrency. One such mechanism is float sequestration. Regardless of whether float sequestration is ultimately in the construction industry’s broader interest, stakeholders must be able to recognize its use and appreciate the implications for delay disputes on their projects. Simply defined, float is the number of days an activity can be delayed before affecting the project’s critical path (i.e., the longest chain of activities which determines the project’s minimal duration). Typically, only delays affecting the critical path can produce concurrent delay. Consequently, the concept of float is integral to understanding and resolving issues of both criticality and concurrency. Reprinted courtesy of Christopher J. Brasco, Watt, Tieder, Hoffar & Fitzgerald, LLP and Matthew D. Baker, Watt, Tieder, Hoffar & Fitzgerald, LLP Mr. Brasco may be contacted at cbrasco@watttieder.com Mr. Baker may be contacted at mbaker@watttieder.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Attorneys' Fees Awarded as Part of "Damages Because of Property Damage"

October 07, 2016 — Tred R. Eyerly – Insurance Law Hawaii
The federal district court for the district of Hawaii found that an arbitrator's award of attorneys' fees was part of the "damages because of property damage" and covered under a CGL policy. Ass'n of Apt. Owners of the Moorings v. Dongbu Ins. Co., 2016 U.S. Dist. LEXIS 110283 (Aug. 18, 2016 D. Haw). The Moorings AOAO was the named insured under the policy issued by Dongbu. Jo-Anne and Brent Braden, owners of a residential unit at the Moorings, filed a demand for arbitration against the AOAO. The Bradens alleged that the AOAO had failed to repair and maintain their lanai roof, which caused water damage to their unit. The arbitrator awarded the Bradens $6,103.49 in special damages, which was the amount they paid to repair their roof and interior damage. The arbitrator also awarded $85,644.30 in attorneys' fees and $8,515.91 in costs to the Bradens. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Denver Parking Garage Roof Collapses Crushing Vehicles

February 12, 2014 — Beverley BevenFlorez-CDJ STAFF
On Monday night, a parking garage ceiling collapsed at the Park Mayfair Condos in Denver, Colorado, according to KKTV News. Residents claim that “between five and ten vehicles were completely destroyed after the ceiling of the underground garage caved in.” No one was injured from the incident. Structural engineers have not commented “yet on how the collapse occurred, but residents told sister station KCNC that the ceiling fell after a cement beam holding up one side of the roof collapsed.” According to KWGN News, FOX31 interviewed a “passerby” who alleged that he lived in the condominium five years ago, but moved out “because inspectors repeatedly sent notices to fix problems with the garage, but, to his knowledge, no action was taken by the condo complex.” Read the full story at KKTV News... Read the full story at KWGN News... Read the court decision
Read the full story...
Reprinted courtesy of

---

Compliance with Contractual and Jurisdictional Pre-Suit Requirements is Essential to Maximizing Recovery

November 27, 2023 — Michael S. Levine, Geoffrey B. Fehling & Charlotte Leszinske - Hunton Insurance Recovery Blog
Timely notice is an important first step in a successful insurance recovery. But insurance policies are not always straightforward in identifying how, when, and to whom notice must be provided. Some states may also impose additional procedural hurdles, including requiring policyholders to contact their insurers before filing suit (the idea behind this requirement is that it may avoid litigation). Failing to comply with pre-suit requirements can hurt the policyholder’s recovery, as illustrated in a recent decision from the Northern District of Texas. In NewcrestImage Holdings, LLC v. The Travelers Lloyds Insurance Company, No. 2:23-cv-039-BR (N.D. Tex. Oct. 17, 2023), the court considered whether NewcrestImage had forfeited its right to recover attorneys’ fees by failing to give Travelers pre-suit notice. NewcrestImage had filed suit against Travelers to obtain coverage for damage to its hotel property arising out of Winter Storm Uri. In its answer, Travelers asserted that NewcrestImage failed to provide the insurer with pre-suit notice as required under the Texas Insurance Code, and that if NewcrestImage successfully proved it was entitled to coverage, NewcrestImage’s failure to provide pre-suit notice precluded it from recovering attorneys’ fees. Travelers later moved to strike the claim for attorneys’ fees on that basis. Reprinted courtesy of Michael S. Levine, Hunton Andrews Kurth, Geoffrey B. Fehling, Hunton Andrews Kurth and Charlotte Leszinske, Hunton Andrews Kurth Mr. Levine may be contacted at mlevine@HuntonAK.com Mr. Fehling may be contacted at gfehling@HuntonAK.com Ms. Leszinske may be contacted at cleszinske@HuntonAK.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Federal Judge Rips Shady Procurement Practices at DRPA

October 07, 2016 — Wally Zimolong – Supplemental Conditions
In an opinion overturning a $17,000,000 bridge painting contract for the Commodore Barry Bridge, a United States Federal Judge called the procurement practices of the Delaware River Port Authority “a black box . . . obscure and unexplained, and lacking any indicia of transparency or the hallmarks of a deliberative process.” The case involved lead paint remediation and repainting of the Pennsylvania span of the Commodore Barry. Seven contractors submitted bids. Alpha Painting was the apparent low bidder. Corcon was the second low bidder. Corcon was also the contractor that was perform the painting work on the New Jersey span of the bridge. Like most agencies engaged in public bidding, the DRPA requires contracts to be awarded to the lowest responsible and responsive bidder. Read the court decision
Read the full story...
Reprinted courtesy of Wally Zimolong, Zimolong LLC
Mr. Zimolong may be contacted at wally@zimolonglaw.com

---

Smart Cities Offer New Ideas for Connectivity

April 05, 2017 — Jennifer Seward - Engineering News-Record
Innovative, technology-driven communities are being designed and constructed for the next generation—and beyond. Although each of them is uniquely planned, experts say the central theme of connectivity is the key to turning concepts into reality. Read the court decision
Read the full story...
Reprinted courtesy of Jennifer Seward, ENR
ENR may be contacted at ENR.com@bnpmedia.com

---

How the Election Could Affect the Housing Industry: Steven Cvitanovic Authors Construction Today Article

October 07, 2016 — Steven M. Cvitanovic – Haight Brown & Bonesteel LLP
Though non-policy issues dominating the news cycle have set this presidential election apart, both Hillary Clinton and Donald Trump have recognized the importance of housing and infrastructure investment. In an article for Construction Today, Partner Steven Cvitanovic outlines several challenges facing the real estate development industry, and analyzes how Clinton and Trump might benefit or harm the industry. Read the court decision
Read the full story...
Reprinted courtesy of Steven M. Cvitanovic, Haight Brown & Bonesteel LLP
Mr. Cvitanovic may be contacted at scvitanovic@hbblaw.com

---