Seattle Washington Building Expert Directory

Code Changes Pave Way for CLT in Tall Buildings and Spark Flammability Debate

May 13, 2019 — Sam Barnes - Construction Executive
Although nothing new, the debate over which is better as a building material—wood or concrete—intensified in December following the preliminary approval of new codes for cross-laminated timber and mass timber in tall structures. The discussion among industry professionals has been less about CLT’s structural capabilities and more about its perceived flammability, with either side offering decidedly different perspectives. Comparatively new to the United States, CLT and mass timber products are constructed of several layers of pressed lumber board stacked in alternating directions. In December, the International Code Council released the unofficial voting results on several code change proposals, including passage of the entire package of 14 tall mass timber codes. The proposals were presented by the ICC’s Ad Hoc Committee on Tall Wood Buildings, comprised mostly of engineers, architects, building and fire code officials, fire service, materials and testing lab representatives. Reprinted courtesy of Sam Barnes, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

6,500 Bridges in Ohio Allegedly Functionally Obsolete or Structurally Deficient

June 17, 2015 — Beverley BevenFlorez-CDJ STAFF
The Portsmouth Daily Times reported that U.S. Senator Sherrod Brown (D-OH) released a report that declared “6,500 bridges in Ohio are either functionally obsolete or structurally deficient as defined by the Federal Highway Administration (FHWA).” According to the Portsmouth Daily Times, the “FHWA defines Functionally Obsolete as a bridge that is no longer by design functionally adequate for its task” and “Structurally Deficient as a bridge that has one or more structural defects that require attention.” Brown’s solution to the issue is to pass a long-term transportation bill. Read the court decision
Read the full story...
Reprinted courtesy of

Does a No-Damage-for-Delay Clause Also Preclude Acceleration Damages?

January 27, 2020 — Ted R. Gropman & Christine Z. Fan - ConsensusDocs
Construction contracts often include a “no damage for delay” clause that denies a contractor the right to recover delay-related costs and limits the contractor’s remedy to an extension of time for noncontractor-caused delays to a project’s completion date. Depending on the nature of the delay and the jurisdiction where the project is located, the contractual prohibition against delay damages may well be enforceable. This article will explore whether an enforceable no-damage-for-delay clause is also a bar to recovery of “acceleration” damages, i.e., the costs incurred by the contractor in its attempt to overcome delays to the project’s completion date. Courts are split as to whether damages for a contractor’s “acceleration” efforts are distinguishable from “delay” damages such that they may be recovered under an enforceable no-damage-for-delay clause. See, e.g., Siefford v. Hous. Auth. of Humboldt, 223 N.W.2d 816 (Neb. 1974) (disallowing the recovery of acceleration damages under a no-damage-for-delay clause); but see Watson Elec. Constr. Co. v. Winston-Salem, 109 N.C. App. 194 (1993) (allowing the recovery of acceleration damages despite a no-damage-for-delay clause). The scope and effect of a no-damage-for-delay clause depend on the specific laws of the jurisdiction and the factual circumstances involved. There are a few ways for a contractor to circumvent an enforceable no-damage-for-delay clause to recover acceleration damages. First, the contractor may invoke one of the state’s enumerated exceptions to the enforceability of the clause. It is helpful to keep in mind that most jurisdictions strictly construe a no-damage-for-delay clause to limit its application. This means that, regardless of delay or acceleration, courts will nonetheless permit the contractor to recover damages if the delay is, for example, of a kind not contemplated by the parties, due to an unreasonable delay, or a result of the owner’s fraud, bad faith, gross negligence, active interference or abandonment of the contract. See Tricon Kent Co. v. Lafarge N. Am., Inc., 186 P.3d 155, 160 (Colo. App. 2008); United States Steel Corp. v. Mo. P. R. Co., 668 F.2d 435, 438 (8th Cir. 1982); Peter Kiewit Sons’ Co. v. Iowa S. Utils. Co., 355 F. Supp. 376, 396 (S.D. Iowa 1973). Reprinted courtesy of Ted R. Gropman, Pepper Hamilton LLP and Christine Z. Fan, Pepper Hamilton LLP Mr. Gropman may be contacted at gropmant@pepperlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Haight has been named a Metropolitan Los Angeles Tier 1 “Best Law Firm” and Tier 2 for Los Angeles and Orange County by U.S. News – Best Lawyers® “Best Law Firms” in 2022

November 08, 2021 — Haight Brown & Bonesteel LLP
Haight Brown & Bonesteel LLP is listed in the U.S. News – Best Lawyers® (2022 Edition) “Best Law Firms” list with six metro rankings in the following areas: Los Angeles

Tier 1

Insurance Law
Personal Injury Litigation – Defendants
Product Liability Litigation – Defendants
Product Liability Litigation – Plaintiffs

Tier 2

Personal Injury Litigation – Plaintiffs

Orange County

Tier 2

Product Liability Litigation – Defendants

Read the court decision
Read the full story...
Reprinted courtesy of Haight Brown & Bonesteel LLP

Be Careful With Construction Fraud Allegations

April 06, 2016 — Christopher G. Hill – Construction Law Musings
Here at Construction Law Musings we have discussed the intersection of contracts, construction and fraud on several occasions. We’ve even discussed how such fraud can bleed over from the civil to the criminal. Recently, the Virginia Supreme Court weighed in again on the question of construction fraud and criminal allegations. In O’Connor v. Tice, the Court discussed a malicious prosecution action brought by a contractor against owners of a commercial building. In O’Connor, the owners and the contractor got into a disagreement over alleged damage to the roof of the owners’ building and who was responsible. In response to this disagreement, the owners contacted the local sheriff’s office, accusing the contractor of construction fraud, and then wrote a “15 day letter” to the contractor outlining the criminal consequences should he fail to pay the damages sought in the owners civil lawsuit. Subsequently, a criminal warrant was issued against the contractor based solely upon the word of the owners. This last occurred at the insistence of the owners (who did not inform the sheriff’s deputy or the Commonwealth Attorney that they’d had this conversation or that the contractor had partially performed) after they discussed the matter with the contractor’s attorney and were informed that any claim that they may have had was civil in nature. Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, Construction Law Musings
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Joint Venture Dispute Over Profits

January 28, 2019 — David R. Cook, Jr. - Autry, Hall, & Cook, LLP
A recent Georgia Court of Appeals case demonstrates the risk of joint ventures failing to carefully define accounting rules in their joint venture agreement. Two trade contractors teamed up to accomplish certain tasks on a job at a wastewater lift station at Fort Gordon. A joint venture agreement provided for an equal split of the profits and losses. Unfortunately, the parties did not define “profit,” and particularly did not define what cost would be deducted in calculating profit. They disputed in particular whether certain large payments to individuals and 15% overhead charges should be deducted in calculating profits. One party presented the expert testimony of an accountant while the other did not. The party presenting expert testimony asked the court to dismiss the other party’s claim because it was not supported by expert testimony of an accountant. The trial court granted the motion and dismissed the claim. Read the court decision
Read the full story...
Reprinted courtesy of David R. Cook, Jr., Autry, Hall, & Cook, LLP
Mr. Cook may be contacted at cook@ahclaw.com

Nine Haight Attorneys Selected for Best Lawyers®: Ones to Watch 2021

September 14, 2020 — Haight Brown & Bonesteel LLP
Nine Haight Brown & Bonesteel LLP attorneys were selected for Best Lawyers®: Ones to Watch 2021. Congratulations to Courtney Arbucci, Frances Brower, James de los Reyes, Kyle DiNicola, Arezoo Jamshidi, Kristian Moriarty, Beth Obra-White, Casey Otis and Kaitlin Preston! Since it was first published in 1983, Best Lawyers® has become universally regarded as the definitive guide to legal excellence. Best Lawyers lists are compiled based on an exhaustive peer-review evaluation. Almost 94,000 industry leading lawyers are eligible to vote (from around the world), and Best Lawyers has received over 11 million evaluations on the legal abilities of other lawyers based on their specific practice areas around the world. Lawyers are not required or allowed to pay a fee to be listed; therefore inclusion in Best Lawyers is considered a singular honor. Corporate Counsel magazine has called Best Lawyers “the most respected referral list of attorneys in practice.” Read the court decision
Read the full story...
Reprinted courtesy of Haight Brown & Bonesteel LLP

Indiana Court Enforces Contract Provisions rather than Construction Drawing Markings

January 14, 2015 — Beverley BevenFlorez-CDJ STAFF
Timothy J. Abeska, a vice-chair of Barnes & Thornburg LLP’s Construction Law Practice Group, analyzed Goodrich Quality Theaters, Inc. v. Fostcorp Heating and Cooling, Inc., 16 N.E.3d 426 (Ind. Ct. App. 2014), which “provides an example of a court enforcing contract provisions rather than markings on construction drawings that are inconsistent with contract requirements.” The case evolved from a dispute on a construction of an IMAX theater, when the general contractor did not understand the architect’s markings for non-standard joist girders, and ordered standard joist girders, per the contract. The error created delays and other problems, which led to payment disputes and mechanic’s liens against the project. Abeska stated that “[t]his case shows the importance of making sure all documents which comprise a construction contract are consistent with each other, as courts will enforce contracts negotiated by the parties. The case also demonstrates that litigation is not a quick process, as the Court of Appeals Opinion was issued more than seven years after the project was completed.” Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES