Fairfield Connecticut Building Expert Directory

“For What It’s Worth”

October 21, 2024 — Daniel Lund III - Lexology
The legal doctrine of quantum meruit is essentially referring to recovering “for what it’s worth,” incorporating the Latin phrase for “as much as one has deserved.” Quantum meruit recovery occurs when there is no contract between parties for the particular item for which recovery is sought. Hence, quantum meruit recovery is generally a means of last resort to endeavor to make oneself whole. So, it was for a subcontractor seeking nearly $14,000,000 for work it performed on a construction project in Portsmouth, New Hampshire. The subcontractor sued on contract as well as quantum meruit/unjust enrichment. The court initially dismissed the quantum meruit/unjust enrichment claims – because there was a contract claim – whereupon the contract claim was dismissed on summary judgment: the subcontractor failed to timely submit change proposals and, consequently, “lost contract remedies available to recover amounts it sought in the change proposals.” Read the court decision
Read the full story...
Reprinted courtesy of Daniel Lund III, Phelps
Mr. Lund may be contacted at daniel.lund@phelps.com

Who Would Face Liability For Oroville Dam Management: Brett Moore Authors Law360 Article

February 23, 2017 — Brett G. Moore - Haight Brown & Bonesteel LLP
On February 12, 2017, the Butte County Sheriff ordered the evacuation of more than 180,000 people in the communities surrounding California’s Oroville Dam after officials spotted severe erosion in the dam’s emergency spillway. The Oroville Dam facilities are managed on by the Federal Energy Regulatory Commission, which licenses the project to California’s Department of Water Resources (DWR). In his Law360 article “Who Would Face Liability For Oroville Dam Management,” Attorney Brett Moore discusses the liability of the agencies involved in managing the Oroville facilities should the dam fail again. Read the court decision
Read the full story...
Reprinted courtesy of Brett G. Moore, Haight Brown & Bonesteel LLP
Mr. Moore may be contacted at bmoore@hbblaw.com

Code Changes Pave Way for CLT in Tall Buildings and Spark Flammability Debate

May 13, 2019 — Sam Barnes - Construction Executive
Although nothing new, the debate over which is better as a building material—wood or concrete—intensified in December following the preliminary approval of new codes for cross-laminated timber and mass timber in tall structures. The discussion among industry professionals has been less about CLT’s structural capabilities and more about its perceived flammability, with either side offering decidedly different perspectives. Comparatively new to the United States, CLT and mass timber products are constructed of several layers of pressed lumber board stacked in alternating directions. In December, the International Code Council released the unofficial voting results on several code change proposals, including passage of the entire package of 14 tall mass timber codes. The proposals were presented by the ICC’s Ad Hoc Committee on Tall Wood Buildings, comprised mostly of engineers, architects, building and fire code officials, fire service, materials and testing lab representatives. Reprinted courtesy of Sam Barnes, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

Not so Fast! How Does Revoking Acceleration of a Note Impact the Statute of Limitations?

July 30, 2018 — Ben Reeves - Snell & Wilmer Real Estate Litigation Blog
Introduction Lenders routinely accelerate notes after a default occurs, calling the entire loan due immediately. Less regularly, a lender may change its mind and unilaterally revoke the acceleration. Rarely, however, does a lender fail to foreclose on its real property collateral before the statute of limitations expires. In Andra R. Miller Designs, LLC v. U.S. Bank, N.A., 244 Ariz. 265, 418 P.3d 1038 (Ct. App. 2018), a unique set of facts involving these issues led the Arizona Court of Appeals to hold that proper revocation of acceleration resets the statute of limitations. The Facts In Miller, a lender made a $1,940,000 loan evidenced by a promissory note and secured by a deed of trust against a home in Paradise Valley, Arizona. The borrower defaulted in September 2008. The default prompted the lender to notice a default, accelerate the note, and initiate a trustee’s sale of the home in 2009. After the lender accelerated the note, the six year statute of limitations began to run. See A.R.S. § 12-548(A)(1) and A.R.S. § 33-816. Pretty standard facts so far, right? Don’t worry, it gets a bit more convoluted. Read the court decision
Read the full story...
Reprinted courtesy of Ben Reeves, Snell & Wilmer
Mr. Reeves may be contacted at breeves@swlaw.com

Corps Spells Out Billions in Infrastructure Act Allocations

February 14, 2022 — Tom Ichniowski - Engineering News-Record
The Army Corps of Engineers has released a detailed project-by-project breakdown outlining how it plans to spend the 2022 portion of the $17.1-billion infusion provided for its civil works program in the Infrastructure Investment and Jobs Act (IIJA). Reprinted courtesy of Tom Ichniowski, Engineering News-Record Mr. Ichniowski may be contacted at ichniowskit@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

In Pricey California, Renters Near Respite From Landlord Gouging

September 16, 2019 — Noah Buhayar - Bloomberg
The housing crisis engulfing California has state lawmakers racing to pass bills that would boost construction and stop corporate landlords from egregiously jacking up rents. The bills overcame key hurdles last week and are due for final votes before the legislature adjourns on Sept. 13. The hardest-fought measure would set a higher standard for evictions and cap annual rent increases at 5% plus the rate of inflation. While that’s below the typical pace of lease hikes -- and the bill has many caveats for landlords -- it would still mark the state’s most significant new protection for tenants in decades. Read the court decision
Read the full story...
Reprinted courtesy of Noah Buhayar, Bloomberg

A Court-Side Seat: Environmental Developments on the Ninth Circuit

July 13, 2020 — Anthony B. Cavender - Gravel2Gavel
On May 26, 2020, the U.S. Court of Appeals for the Ninth Circuit decided three significant environmental law cases. Two of these cases involved whether global warming tort cases could be brought in California state courts on, for example, a public nuisance claim, and whether the defendant energy companies had the right to have them removed to the federal courts. County of San Mateo, et al. v. Chevron Corp., et al. and City of Oakland v. BP PLC, et al. While acknowledging the immensity of the legal issues, the Ninth Circuit held that the federal removal statutes did not permit these cases to be removed to the federal courts. For one thing, state court jurisdiction was not preempted by the Clean Air Act. Accordingly, the court affirmed the ruling of Federal Judge Chhabria in the Chevron case, and vacated Judge Alsup’s ruling in the BP case that he had jurisdiction to hear this case pursuant to federal common law, and then to dismiss it. The court also remanded the case to Judge Alsup, and directed him to determine if there was an “alternate basis” for federal court jurisdiction based on the pleadings that an issue of ”navigable waters” was a concern. Read the court decision
Read the full story...
Reprinted courtesy of Anthony B. Cavender, Pillsbury
Mr. Cavender may be contacted at anthony.cavender@pillsburylaw.com

Recovering Unabsorbed Home Office Overhead Due to Delay

May 30, 2022 — David Adelstein - Florida Construction Legal Updates
In the preceding article, I discussed the use of a retrospective as-built delay analysis in a case before the Civilian Board of Contract Appeals (CBCA). This case also discussed a damages component in certain delay claims known as unabsorbed home office overhead—a challenging damages component to recover because this deals with indirect costs as opposed to direct costs. Unabsorbed home office overhead is a damages component when the contractor is on standby, but this is NOT as easy as just claiming standby thereby you are automatically entitled to unabsorbed home office overhead. There are requirements that MUST be met.

To obtain an equitable adjustment for unabsorbed home office overhead as compensation for being on standby, [the contractor] must initially show “[1] a government-caused delay of uncertain duration,” that “[2] the delay extended the original time for performance” or precluded the contractor from finishing earlier than scheduled, and that “[3] the contractor [was] on standby and unable to take on other work during the delay period. CTA I, LLC v. Department of Veteran Affairs, CBCA 5826, 2022 WL 884710 (CBCA 2022) quoting Nicon, Inc. v. U.S., 331 F.3d 878, 883 (Fed. Cir. 2003).

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES