Cambridge Massachusetts Building Expert Directory

Construction Delays: Which Method Should Be Used to Calculate Delay?

July 25, 2021 — David Adelstein - Florida Construction Legal Updates
If you need to prove and allocate construction project delays, you should engage a scheduling consultant qualified with CPM (critical path method) analysis. You should also engage counsel to assist in preserving your rights, as well as presenting and maximing your arguments for delay. There are numerous methodologies used to quantify and allocate delay. You want to discuss the most effective analysis for your case and facts including whether you want/should use a forward-looking prospective analysis or a backward-looking retrospective analysis that factors in as-built data. In doing so, you want to make sure you understand the pros and cons of each methodology including the bases to attack the methodology that will be subject to cross-examination. The five primary CPM methodologies are as follows:

As-Planned Versus As-Built. This methodology compares the as-planned baseline schedule to an as-built schedule reflecting progress to assign delay. An as-built schedule that reflects progress includes actual start dates, finish dates, and durations. The actual dates and durations are compared with the as-planned dates and durations on the baseline schedule to determine delay. Under this methodology, the delay impact is determined retrospectively.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Construction Litigation Roundup: “It’s None of Your Business.”

May 22, 2023 — Daniel Lund III - Lexology
“It’s none of your business.” So said a construction surety resisting discovery of its underwriting file in the context of the surety’s affirmative $2 million indemnity claim (on a $25M bond), and a Missouri federal court agreed. In response to the surety’s indemnity suit, the defaulted principal contractor and additional corporate indemnitors offered up defenses of “lack of consideration and the doctrine of unclean hands, laches, waiver and/or estoppel, among others.” The indemnitors also issued written discovery to the surety seeking to obtain the surety’s underwriting file – which would reveal the underpinnings of the surety’s decision to issue the bond to the contractor – asserting “that the underwriting and due diligence documents are relevant to the[] lack of consideration defense. [Indemnitors] claim that ‘[t]his defense is based on Defendants' belief that Plaintiff did not conduct any reasonable inquiry into any Defendants' ability to pay or financial resources and therefore Plaintiff did not rely on the financial condition of each Defendant in determining whether to issue the bonds.’" Read the court decision
Read the full story...
Reprinted courtesy of Daniel Lund III, Phelps
Mr. Lund may be contacted at daniel.lund@phelps.com

Congratulations to Haight Attorneys Selected for the 2024 Edition of Best Lawyers and Best Lawyers: Ones to Watch

September 11, 2023 — Haight Brown & Bonesteel LLP
Best Lawyers and Best Lawyers: Ones to Watch – 2024 Edition Best Lawyers 2024 Edition

Bruce Cleeland
Peter Dubrawski
Denis Moriarty
Theodore Penny

Best Lawyers: Ones to Watch 2024 Edition

Frances Brower
Kyle DiNicola
Kristian Moriarty
Arezoo Jamshidi
Josh Maltzer
Philip McDermott
Patrick McIntyre
Annette Mijanovic
Kathleen Moriarty
Bethsaida Obra-White

Read the court decision
Read the full story...
Reprinted courtesy of Haight Brown & Bonesteel LLP

Evolving Climate Patterns and Extreme Weather Demand New Building Methods

May 22, 2023 — Annette Rubin - Construction Executive
Compared to the rest of the world, most buildings in the United States are relatively young. But most residential and commercial properties could use a makeover. Buildings constructed over twenty, fifty and one hundred years ago are, unsurprisingly, not as energy-efficient or as safe as new builds following modern methods—especially when considering the effects of climate change and more frequent extreme weather events on the integrity of that infrastructure. According to the National Association of Home Builders, over 90% of new homes built in the United States today are wood-framed. These homes are incapable of withstanding a tornado or hurricane, yet they are still being built directly in the path of storms. Even buildings constructed in some of the most earthquake-prone areas of the U.S. may contain design flaws that make them susceptible to damage because they are built using a non-ductile concrete method, which experts say has an inadequate configuration of steel reinforcing bars—making the building vulnerable when shaken. While this building method was banned for new construction, it is not yet required to retrofit older construction to improve safety and structural integrity. Reprinted courtesy of Annette Rubin, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

Bad News for Buyers: U.S. Mortgage Rates Hit Highest Since 2014

February 22, 2018 — Prashant Gopal – Bloomberg
Shanne Sleder, a San Diego mortgage banker, recently had to break the bad news to some would-be homebuyers: Borrowing costs jumped about 6 percent since he pre-approved them a couple months ago. Read the court decision
Read the full story...
Reprinted courtesy of Prashant Gopal, Bloomberg

Slump in U.S. Housing Starts Led by Multifamily: Economy

September 24, 2014 — Jeanna Smialek – Bloomberg
Housing starts slumped in August from the highest level in almost seven years, reflecting a setback in multifamily projects that are at the forefront of the rebound in U.S. real estate. Beginning home construction fell 14.4 percent, the most since April 2013, to a 956,000 annualized rate following July’s revised 1.12 million pace that was the strongest since November 2007, the Commerce Department said today in Washington. Work on apartments and condominiums, which tends to be volatile, dropped 31.7 percent after jumping 44.9 percent in July. As more Americans decide that homeownership isn’t for them because wage growth is slow and qualifying for mortgages remains difficult, builders have focused on putting up more rental units, which means the industry will see bigger swings month to month. The average number of multifamily units started over the past 12 months was the most since 2006. Read the court decision
Read the full story...
Reprinted courtesy of Jeanna Smialek, Bloomberg
Ms. Smialek may be contacted at jsmialek1@bloomberg.net

Recent Florida Legislative Changes Shorten Both Statute of Limitation ("SOL") and Statute of Repose ("SOR") for Construction Defect Claims

March 19, 2024 — Holly A. Rice - Saxe Doernberger & Vita, P.C.
The Florida Legislature and Governor DeSantis passed Senate Bill 360, effective April 13, 2023, which imposes significant changes to Florida’s statute of limitation (“SOL”) and statute of repose (“SOR”) periods prescribed in Florida Statute § 95.11. In short, the SOL and SOR periods will commence earlier and run earlier, which in effect shortens the time to bring a construction defect claim on both ends of the timeline.1 These changes will have positive impacts for general contractors who may save on insurance premiums with shorter completed operations tails. In other words, the timeframe within which contractors are at risk of being sued for construction-related errors is significantly reduced under the new version of the statute. Owners and developers, on the other hand, may feel that the increased pressure of uncovered construction defects necessitates the filing of lawsuits sooner than they might have otherwise filed. Collectively, all parties involved will certainly have to consider when and how to place their carriers on notice of claims or potential claims and, coupled with Florida’s sweeping changes to fee shifting statutes, insured parties may see more coverage denials which, in turn, could lead to more coverage actions.2 Read the court decision
Read the full story...
Reprinted courtesy of Holly A. Rice, Saxe Doernberger & Vita, P.C.
Ms. Rice may be contacted at HRice@sdvlaw.com

Home Prices in 20 U.S. Cities Rise Most Since February 2006

January 29, 2014 — Jeanna Smialek – Bloomberg
Home prices in 20 U.S. cities rose in November from a year ago by the most in almost eight years, providing a boost to household wealth. The S&P/Case-Shiller index of property prices in 20 cities climbed 13.7 percent from November 2012, the biggest 12-month gain since February 2006, after a 13.6 percent increase in the year ended in October, a report from the group showed today in New York. The median projection of 31 economists surveyed by Bloomberg called for a 13.8 percent advance. Read the court decision
Read the full story...
Reprinted courtesy of Jeanna Smialek, Bloomberg
Ms. Smialek may be contacted at jsmialek1@bloomberg.net

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES