Cambridge Massachusetts Building Expert Directory

A Classic Blunder: Practical Advice for Avoiding Two-Front Wars

August 23, 2021 — William Underwood - ConsensusDocs
“Ha ha! You fool! You fell victim to one of the classic blunders – the most famous of which is ‘never get involved in a land war in Asia’ – but only slightly less well-known is this: ‘Never go in against a Sicilian when death is on the line.’”[1] Vizzini forgot to include “never fight a two-front war with your owner and a subcontractor” on his list of classic blunders, but it certainly belongs there. This article examines practical tips and tricks for general contractors to avoid the classic blunder of a two-front war, including recommended contract provisions and sound project documentation practices. Admittedly, general contractors face a wide array of obligations on a project. And perhaps one of the most delicate balancing acts is managing relationships with the owner and your subcontractors. But far too often general contractors find themselves in the difficult position of fighting a two-front war against one (or more) of their subcontractors and the project owner. But this does not always have to be the case—there are ways for general contractors to reduce the risk of finding themselves in a two-front war. And every project does not have to devolve in a circular firing squad with you in the middle. That said, this article comes with the caveat that a general contractor cannot avoid a two-front war in every instance, nor does this article examine every imaginable way to reduce the risk of a two-front war (see e.g. https://www.consensusdocs.org/pass-through-subcontractor-claims-liquidating-agreements-and-avoiding-a-two-front-war/). But this article will provide an overview of several key tools that can be used to minimize the risk of falling into a classic blunder. Read the court decision
Read the full story...
Reprinted courtesy of William Underwood, Jones Walker LLP
Mr. Underwood may be contacted at wunderwood@joneswalker.com

Newark Trial Team Obtains Affirmance of Summary Judgment for General Contractor Client

January 21, 2025 — Lewis Brisbois Newsroom
Newark, N.J. (December 31, 2024) - Days after obtaining an Appellate Division victory affirming a “no cause” jury verdict, Newark Partner Afsha Noran and Managing Partner Colin Hackett obtained a second appellate court victory affirming a trial court's dismissal of a complaint against another firm client, a general contractor. The team had previously obtained summary judgment at the trial level on the grounds plaintiff could not establish a prima facie case against the client. The plaintiff appealed the grant of summary judgment and dismissal of her claim to the Appellate Division. Read the court decision
Read the full story...
Reprinted courtesy of Lewis Brisbois

Does a No-Damage-for-Delay Clause Also Preclude Acceleration Damages?

January 27, 2020 — Ted R. Gropman & Christine Z. Fan - ConsensusDocs
Construction contracts often include a “no damage for delay” clause that denies a contractor the right to recover delay-related costs and limits the contractor’s remedy to an extension of time for noncontractor-caused delays to a project’s completion date. Depending on the nature of the delay and the jurisdiction where the project is located, the contractual prohibition against delay damages may well be enforceable. This article will explore whether an enforceable no-damage-for-delay clause is also a bar to recovery of “acceleration” damages, i.e., the costs incurred by the contractor in its attempt to overcome delays to the project’s completion date. Courts are split as to whether damages for a contractor’s “acceleration” efforts are distinguishable from “delay” damages such that they may be recovered under an enforceable no-damage-for-delay clause. See, e.g., Siefford v. Hous. Auth. of Humboldt, 223 N.W.2d 816 (Neb. 1974) (disallowing the recovery of acceleration damages under a no-damage-for-delay clause); but see Watson Elec. Constr. Co. v. Winston-Salem, 109 N.C. App. 194 (1993) (allowing the recovery of acceleration damages despite a no-damage-for-delay clause). The scope and effect of a no-damage-for-delay clause depend on the specific laws of the jurisdiction and the factual circumstances involved. There are a few ways for a contractor to circumvent an enforceable no-damage-for-delay clause to recover acceleration damages. First, the contractor may invoke one of the state’s enumerated exceptions to the enforceability of the clause. It is helpful to keep in mind that most jurisdictions strictly construe a no-damage-for-delay clause to limit its application. This means that, regardless of delay or acceleration, courts will nonetheless permit the contractor to recover damages if the delay is, for example, of a kind not contemplated by the parties, due to an unreasonable delay, or a result of the owner’s fraud, bad faith, gross negligence, active interference or abandonment of the contract. See Tricon Kent Co. v. Lafarge N. Am., Inc., 186 P.3d 155, 160 (Colo. App. 2008); United States Steel Corp. v. Mo. P. R. Co., 668 F.2d 435, 438 (8th Cir. 1982); Peter Kiewit Sons’ Co. v. Iowa S. Utils. Co., 355 F. Supp. 376, 396 (S.D. Iowa 1973). Reprinted courtesy of Ted R. Gropman, Pepper Hamilton LLP and Christine Z. Fan, Pepper Hamilton LLP Mr. Gropman may be contacted at gropmant@pepperlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Florida Contractor on Trial for Bribing School Official

October 28, 2011 — CDJ STAFF

Lloyd Whann, an executive in M. M. Parrish Construction, a Gainesville, Florida firm, is going to trial over claims that he bribed a school district official with more than $50,000 in gifts. The trial has been pushed to March of 2012, in order for his defense to review documents.

Bob Williams, the former school official, plead guilty to conspiracy to commit bribery. He agreed to testify against Whann and M.M. Parrish Construction.

Read the full story...

Read the court decision
Read the full story...
Reprinted courtesy of

Fifth Circuit Decision on Number of Occurrences Underscores Need to Carefully Tailor Your Insurance Program

December 19, 2018 — Michael S. Levine & Daniel Hentschel - Hunton Insurance Recovery Blog
The Fifth Circuit in Evanston Insurance Co. v. Mid-Continent Casualty Co. recently held that multiple collisions caused by the same insured driver over a span of 10 minutes constitute a single occurrence subject to a $1 million limit in the insured’s primary policy with Mid-Continent. The holding reversed a lower court’s ruling that Mid-Continent is liable for an additional sum the excess insurer, Evanston, paid to resolve all of the claims arising from the collisions. At issue, a fundamental question about causation and coverage under commercial liability insurance. Reprinted courtesy of Michael S. Levine, Hunton Andrews Kurth and Daniel Hentschel, Hunton Andrews Kurth Mr. Levine may be contacted at mlevine@HuntonAK.com Mr. Hentschel may be contacted at dhentschel@HuntonAK.com Read the court decision
Read the full story...
Reprinted courtesy of

Mortgage Battle Flares as U.K. Homebuying Loses Allure

January 28, 2015 — Neil Callanan and Richard Partington – Bloomberg
U.K. banks, which spent six years repairing their balance sheets after the 2008 property crash, want to advance more credit to homebuyers. Borrowers aren’t as enthusiastic. Cheap funding costs and low default rates have made homebuyers attractive to lenders in recent years, boosting returns for companies such as Nationwide Building Society and Lloyds Banking Group Plc. (LLOY) Now, with demand for property cooling, they’re having to fight harder for business. Interest rates on the most popular mortgages fell to record lows in December, according to the Bank of England. Mr. Callanan may be contacted at ncallanan@bloomberg.net; Mr. Partington may be contacted at rpartington@bloomberg.net Read the court decision
Read the full story...
Reprinted courtesy of Neil Callanan and Richard Partington, Bloomberg

EEOC Focuses on Eliminating Harassment, Recruitment and Hiring Barriers in the Construction Industry

September 09, 2024 — Aaron C. Schlesinger & Stephen E. Irving - Peckar & Abramson, P.C.
The Equal Employment Opportunity Commission (EEOC), whose mission is to enforce the nation’s anti-discrimination laws, released new guidelines on June 18, 2024, entitled Promising Practices for Preventing Harassment in the Construction Industry. The guidelines are in support of its Strategic Enforcement Plan for the fiscal years 2024-2028 for combatting systemic harassment and eliminating barriers in recruitment and hiring in the construction industry. With these guidelines, the EEOC has identified harassment as an ongoing issue in the construction industry, and that immediate attention and resolution is required. The EEOC specifically recommends that the following five core principles that it has found effective in preventing and addressing harassment be implemented by construction industry employers:

Committed and engaged leadership;
Consistent and demonstrated accountability;
Strong and comprehensive harassment policies;
Trusted and accessible complaint procedures; and
Regular, interactive training tailored to the audience and the organization.

Reprinted courtesy of Aaron C. Schlesinger, Peckar & Abramson, P.C. and Stephen E. Irving, Peckar & Abramson, P.C. Mr. Schlesinger may be contacted at aschlesinger@pecklaw.com Mr. Irving may be contacted at sirving@pecklaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Kentucky Court Upholds Arbitration Award, Denies Appeal

June 15, 2011 — CDJ STAFF

The Kentucky Court of Appeals has ruled in Lake Cumberland Community Action Agency v. CMW, Inc. affirming the arbitration award. CMW, Inc. was responsible for the construction of a facility to be used for pre-school students and the housing of Alzheimer patients and senior citizens. An agreement was made that any disputes would be heard by an arbitrator selected by the construction industry.

The plaintiff alleged that there were design and construction defects in the building trusses, violation of the Kentucky Building Code, and problems with the HVAC system. The arbitrator awarded $106,000 to the plaintiff which then sought to vacate the award. The circuit court upheld the arbitrator’s decision.

The Court of Appeals found that there was no basis for rejecting the arbitrator’s decision, noting “there is nothing to show that there was any fraud or bias on the part of the arbitrator.” The appeals court, with all three judges concurring, upheld the arbitration award.

Read the court’s decision