Delays Caused When Government (Owner) Pushes Contractor’s Work Into Rainy / Adverse Weather Season
January 13, 2020 —
David Adelstein - Florida Construction Legal UpdatesThere are a number of horizontal construction projects where a contractor’s sequence of work and schedule is predicated on avoiding the rainy season (or certain force majeure events). The reason is that the rainy season will result in delays due to the inability to work (and work efficiently) during the adverse weather (including flooding caused by the weather). If the work is pushed into the rainy season, is such delay compensable if the government (or owner) delayed the project that pushed work out into the rainy season? It very well can be.
For example, in Meridian Engineering Co. v. U.S., 2019 WL 4594233 (Fed. Cl. 2019), a contractor was hired by the Army Corps of Engineers to construct a flood control project for a channel in Arizona. Due to delays, including those caused by the government, the project was pushed into the monsoon season, which caused additional delays largely due to flooding caused by the heavy rain. One issue was whether such delays were compensable to the contractor – the government raised the argument that the contractor assumed the risk of potential flooding from the rainy season. The Court found this argument unconvincing:
[The contractor’s] initial construction schedule planned for a completion of the channel invert work, a necessary step in protecting the site from flooding, to be completed by late June 2008…[M]any issues arose in the project’s early stages that led to cumulative substantial delay, including those caused by the government’s failure….The government cannot now claim that [the contractor] assumed the risk of flooding from monsoon season when the government was largely responsible for [the contractor’s] inability to complete the project prior to the beginning of the monsoon season. Simply put, the government cannot escape liability for flood damages when the government is responsible for causing the contractor to be working during the flood-prone season.
Meridian Engineering, 2019 WL at *7 (internal citations omitted)
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Not Pandemic-Proof: The Ongoing Impact of COVID-19 on the Commercial Construction Industry
December 06, 2021 —
George B. Green Jr. - Construction ExecutiveThe impact of COVID-19 has been felt in nearly every industry and arena across the country, with the exception of construction—or so that is the general perception. Perceptions are often wrong though, and this one is no different. The truth is that the construction industry has been hit just as hard, if not harder, than every other industry.
As the COVID-19 pandemic struck in the spring of 2020, construction projects plowed forward full steam ahead. Roadwork seemed to increase and developers continued to systematically acquire property and initiate large-scale projects. Perhaps it was these observations that led many to the conclusion that construction was pandemic-proof as the rest of society attempted to cobble together something that vaguely resembled a normal business year. But the construction industry has endured many challenges over the last 18 months, and unfortunately, the challenges do not appear to be evaporating anytime soon.
The industry has been primarily affected in the areas of scheduling, manpower and permitting, which has ultimately affected pricing. The entire way jobs are scheduled has been turned upside down. The supply chain issues that many have experienced for everyday household items have hit the construction industry as well.
Reprinted courtesy of
George B. Green Jr., Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the court decisionRead the full story...Reprinted courtesy of
Mr. Green may be contacted at
ggreen@wwhgd.com
Sometimes a Reminder is in Order. . .
June 21, 2021 —
Christopher G. Hill - Construction Law MusingsRecently, I was talking with my friend Matt Hundley about a recent case he had in the Charlottesville, VA Circuit Court. It was a relatively straightforward (or so he and I would have thought) breach of contract matter involving a fixed price contract between his (and an associate of his Laura Hooe) client James River Stucco and the Montecello Overlook Owners’ Association. I believe that you will see the reason for the title of the post once you hear the facts and read the opinion.
In James River Stucco, Inc. v. Monticello Overlook Owners’ Ass’n, the Court considered Janes River Stucco’s Motion for Summary Judgment countering two arguments made by the Association. The first Association argument was that the word “employ” in the contract meant that James River Stucco was required to use its own forces (as opposed to subcontractors) to perform the work. The second argument was that James River overcharged for the work. This second argument was made without any allegation of fraud or that the work was not 100% performed.
Read the court decisionRead the full story...Reprinted courtesy of
The Law Office of Christopher G. HillMr. Hill may be contacted at
chrisghill@constructionlawva.com
Not so Fast – Florida’s Legislature Overrules Gindel’s Pre-Suit Notice/Tolling Decision Related to the Construction Defect Statute of Repose
May 11, 2020 —
Rahul Gogineni - The Subrogation StrategistAs discussed in a prior blog post, in Gindel v. Centex Homes, 2018 Fla.App. LEXIS 13019, Florida’s Fourth District Court of Appeal held that when the plaintiffs provided a pre-suit notice in compliance with §558.004 of Florida’s construction defect Right-to-Cure statute, Fla. Stat. §§ 558.001 to 558.005, et. seq., they commenced a “civil action or proceeding,” i.e. an “action,” within the meaning of Florida’s construction defect Statute of Repose, Florida Statue § 95.11(3)(c). Thus, the court held that the plaintiffs commenced their action prior to the time Florida’s 10-year statute of repose period ended. In overturning the lower court’s dismissal of the action, the court found that because the Right-to-Cure statute, §558 of the Florida Statutes, sets out a series of mandatory steps that must be taken prior to bringing a judicial action, filing pre-suit notice of claim sufficiently constituted an “action” for purposes of Florida’s Statute of Repose.
For various reasons, the parties appealed the decision to the Supreme Court of Florida. In July of 2019, before the Florida Supreme Court could decide whether to hear the case, the Florida legislature passed legislation that effectively overruled the decision. To overrule the decision, the Florida Legislature modified § 558.004 of Florida’s Right-to-Cure statute to expressly state that a notice of claim served pursuant to the Right-to-Cure statute does not toll the 10-year statute of repose period for construction claims. See Fla. Stat.
§ 558.004(d).
Read the court decisionRead the full story...Reprinted courtesy of
Rahul Gogineni, White and Williams LLPMr. Gogineni may be contacted at
goginenir@whiteandwilliams.com
NY Estimating Consultant Settles $3.1M Government Project Fraud Case
November 23, 2020 —
Eva Fedderly - Engineering News-RecordVJ Associates, a Hicksville, N.Y., estimating consultant, has agreed to pay $3.13 million in civil and criminal penalties to settle charges that the firm overbilled and falsified hours on multiple federal and state government-funded transportation and other contracts in New York and Massachusetts, the U.S. Attorney's office in Boston announced on Oct. 29.
Reprinted courtesy of
Eva Fedderly, Engineering News-Record
ENR may be contacted at ENR.com@bnpmedia.com
Read the full story... Read the court decisionRead the full story...Reprinted courtesy of
HP Unveils Cheaper, 3-D Printing System to Spur Sales
November 05, 2014 —
Jack Clark - BloombergHewlett-Packard Co. (HPQ) unveiled a new 3-D-capable computer and speedier 3-D printer technology as it prepares to spin off its personal-computer and printer businesses into a stand-alone company.
The company today introduced Sprout, an $1,899 computer that lets people scan and manipulate 2-D and 3-D objects. It will be available early next month online and in some U.S. stores. Hewlett-Packard also said new 3-D printer technology will make the process cheaper and faster than competitors.
The Palo Alto, California-based company is betting that 3-D technology will help revitalize sales and spur growth in the printer industry. More than 2.3 million 3-D printers will ship in 2018, up from about 108000 this year, according to researcher Gartner Inc. Earlier this month, Hewlett-Packard said it would split into two companies by late 2015, with one focused on corporate hardware services and the other -- dubbed HP Inc. -- on PCs and printers.
Read the court decisionRead the full story...Reprinted courtesy of
Jack Clark, BloombergMr. Clark may be contacted at
jclark185@bloomberg.net
Top 10 Take-Aways from the 2024 Annual Forum Meeting in New Orleans
May 20, 2024 —
Marissa L. Downs & Brendan Witry - Laurie & Brennan, LLPOver 600 construction lawyers, experts, and consultants met in New Orleans last week for the Forum’s 2024 Annual Meeting where Program Coordinators Brenda Radmacher and Joseph Imperiale together with John Cook and Buck Beltzer put together an insightful program focused on all things construction litigation. Here are our 10 top take-aways from this unique program.
10. Don't underestimate the soft skills that are necessary to effectively represent your clients. There are different ways to measure success when it comes to construction litigation, according to Stephen Dale (WSP USA), Melissa Beutler Withy (Big-D), and Matthew Whipple (Wohlsen Construction). What these (and likely other inside counsel) will look for when retaining outside counsel is the ability to accurately forecast litigation expense and timely communicate case developments. Being able to master these "soft" skills is as important (if not more so) as an attorney's aptitude for trial advocacy. The in-house counsel who hire litigation counsel will be held accountable to deliver results on the investment they are making in legal fees. Outside counsel who cannot manage budgets or avoid surprises in the course of a case will not be successful as litigators.
Reprinted courtesy of
Marissa L. Downs, Laurie & Brennan, LLP and
Brendan Witry, Laurie & Brennan, LLP
Ms. Downs may be contacted at mdowns@lauriebrennan.com
Mr. Witry may be contacted at bwitry@lauriebrennan.com
Read the court decisionRead the full story...Reprinted courtesy of
Arizona Court Determines Statute of Limitations Applicable to a Claim for Reformation of a Deed of Trust (and a Related Claim for Declaratory Judgment)
October 16, 2018 —
Kevin J. Parker - Snell & Wilmer Real Estate Litigation BlogIn a recent Arizona Court of Appeals case, Deutsche Bank National Trust Co. v. Pheasant Grove LLC, 798 Ariz. Adv. Rep. 15 (August 23, 2018), the Court of Appeals addressed the question of what statute of limitations was applicable to a declaratory judgment claim. In that case, a bank’s deed of trust inadvertently omitted one of the lots that was supposed to secure that bank’s loan. The deed of trust should have covered lots 8 and 9, but by its terms covered only lot 8. A different bank subsequently recorded a deed of trust that encumbered lot 9. In connection with the second bank’s foreclosure of its deed of trust, the first bank sought reformation and a declaratory judgment with regard to its deed of trust, seeking to have that deed of trust cover both lots 8 and 9, as intended. The trial court determined that the first bank’s reformation claim was filed too late, and also determined that the declaratory judgment claim was filed too late, beyond the applicable statute of limitations.
Read the court decisionRead the full story...Reprinted courtesy of
Kevin J. Parker, Snell & WilmerMr. Parker may be contacted at
kparker@swlaw.com
