Seattle Washington Building Expert Directory

Force Majeure Under the Coronavirus (COVID-19) Pandemic

March 29, 2021 — Lindsay T. Watkins - Ahlers Cressman & Sleight PLLC
As COVID-19 disrupts work and life as we know it, the question many contractors have is what protections are available against the inevitable project impacts and delays? Generally, construction contracts require a contractor to timely perform work until project completion or potentially face damages (liquidated or actual) and possible termination. When events occur, however, that are beyond our control (such as a national pandemic), it is important to review and understand what contract provisions or avenues are available for potential relief.

Review Your Contract For A Force Majeure Provision.

Washington State Department of Transportation Clause (2018 Standard Specifications for Road, Bridge and Municipal Construction): The Contractor shall rebuild, repair, restore, and make good all damages to any portion of the permanent or temporary Work occurring before the Physical Completion Date and shall bear all the expense to do so, except damage to the permanent Work caused by: (a) acts of God, such as earthquake, floods, or other cataclysmic phenomenon of nature, or (b) acts of the public enemy or of governmental authorities; or (c) slides in cases where Section 2-03.3(11) is applicable; Provided, however, that these exceptions shall not apply should damages result from the Contractor’s failure to take reasonable precautions or to exercise sound engineering and construction practices in conducting the Work.

Read the court decision
Read the full story...
Reprinted courtesy of Lindsay T. Watkins, Ahlers Cressman & Sleight PLLC
Ms. Watkins may be contacted at Lindsay.Watkins@acslawyers.com

Nebraska Joins the Ranks—No CGL Coverage for Faulty Work

September 17, 2014 — Craig Martin – Construction Contractor Advisor
The Nebraska Court of Appeals has ruled that a home builder that fails to adequately compact the soil does not have insurance coverage to repair damages to the home caused by the settling soil. In “insurance speak”, there was no occurrence to trigger coverage. In this case, Cizek Homes, Inc. v Columbia National Insurance Company, a home builder contracted with a buyer to build a house. A lot was selected and the home was built. After the buyer moved in, the house started to settle, causing damage to the house. The buyer told the builder about these problems and the builder agreed to fix the problems. The builder also contacted its insurance company and requested coverage for the buyer’s claim. The insurer rejected the claim, determining that the buyer’s claim was not covered by the builder’s Commercial General Liability (CGL) insurance. The insurer then filed suit asking the court to interpret the insurance policy and to determine whether the CGL insurance covered the claim. The court looked to the buyer’s allegations that the builder failed to construct the home in accordance with accepted construction and industry standards and that the builder was negligent in designing and constructing the home. The builder admitted that it was obligated to pay for the costs of repairs, but denied that it was negligent in constructing the home. Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

Meet the Forum's In-House Counsel: KATE GOLDEN

February 19, 2024 — Jessica Knox - The Dispute Resolver
Company: Mortenson Email: kate.golden@mortenson.com Website: www.mortenson.com College: University of Iowa (Bachelor of Science in Engineering, 1991) Graduate School: University of Minnesota (Master of Science in Civil Engineering, 1994) Law School: William Mitchell College of Law (now Mitchell | Hamline School of Law) (JD 1999) States Where Company Operates/Does Business: Mortenson is a national builder and developer with 13 regional office locations. Q: Describe your background and the path you took to becoming in-house counsel. A: In high school, I loved math and science, so I attended the University of Iowa College of Engineering and studied civil engineering, with a focus on environmental engineering. To practice environmental engineering at that time, you generally needed a master’s degree, so I attended the University of Minnesota, where my thesis for my degree program was “Organochlorines in Lake Michigan.” I then worked as an environmental engineer for a consulting firm called Montgomery Watson (now MWH) assisting clients with various environmental issues from air permitting to watershed reports to risk assessments of contaminated sites. Read the court decision
Read the full story...
Reprinted courtesy of Jessica Knox, Stinson LLP
Ms. Knox may be contacted at jessica.knox@stinson.com

CA Supreme Court: Right to Repair Act (SB 800) is the Exclusive Remedy for Residential Construction Defect Claims – So Now What?

January 31, 2018 — Steven M. Cvitanovic & Omar Parra - Publications & Insights
A torrent of alerts have been flooding e-mail inboxes regarding the California Supreme Court’s decision in McMillin v. Superior Court, to reverse the Liberty Mutual Insurance Company v. Brookfield Crystal Cove LLC (2013) case, but with little discussion about the practical effects of the ruling. This alert will discuss how this ruling affects litigation of SB 800 Claims and Builders. Background on Liberty Mutual Case In 2002, the California Legislature enacted comprehensive construction defect litigation reform referred to as the Right to Repair Act (the “Act”). Among other things, the Act establishes standards for residential dwellings, and creates a prelitigation process that allows builders an opportunity to cure the construction defects before being sued. Since its enactment, however, the Act’s application has been up for debate. Most notably, in Liberty Mutual Insurance Company v. Brookfield Crystal Cove LLC (2013), the California Court of Appeal for the Fourth District held the Act was the exclusive remedy only in instances where the defects caused only economic loss, and that homeowners could pursue other remedies in situations where the defects caused actual property damage or personal injuries. Reprinted courtesy of Steve Cvitanovic, Haight Brown & Bonesteel LLP and Omar Parra, Haight Brown & Bonesteel LLP Mr. Cvitanovic may be contacted at scvitanovic@hbblaw.com Mr. Parra may be contacted at oparra@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

The Requirement to State a “Sum Certain” No Longer a Jurisdictional Bar to Government Contract Claims

November 13, 2023 — Marcos R. Gonzalez - ConsensusDocs
The Boards of Contract Appeals, Court of Federal Claims, and the Federal Circuit have long held that the elements of a claim under the Contract Disputes Act (“CDA”) to be jurisdictional. Those requirements are as follows: (a) Claims generally.– (1) Submission of contractor’s claims to contracting officer.–Each claim by a contractor against the Federal Government relating to a contract shall be submitted to the contracting officer for a decision. (2) Contractor’s claims in writing.—Each claim by a contractor against the Federal Government relating to a contract shall be in writing. (3) Contracting officer to decide Federal Government’s claims.–Each claim by the Federal Government against a contractor relating to a contract shall be the subject of a written decision by the contracting officer. Read the court decision
Read the full story...
Reprinted courtesy of Marcos R. Gonzalez, Peckar & Abramson, P.C.
Mr. Gonzalez may be contacted at mgonzalez@pecklaw.com

Wildfire Insurance Coverage Series, Part 2: Coverage for Smoke-Related Damages

July 03, 2022 — Scott P. DeVries & Yosef Itkin - Hunton Insurance Recovery Blog
For many policyholders, smoke emanating from wildfire causes as much if not more damage than the fire itself. In this post in the Blog’s Wildfire Insurance Coverage Series, we discuss damages caused by smoke emanating from wildfires. Some insurers argue that policies are limited to fire damage to the insured property and do not include smoke damage associated with nearby fires. A treatise frequently cited by insurers states otherwise: “The concept that fire insurance covers non-fire damage which is the proximate result of fire finds application also when the fire occurs on other property and causes harm to the insured property. In such case, the harm to the insured property, even though it is a non-fire harm, has long been recognized to be the result of fire, and, therefore, within the policy coverage.”[1] Reprinted courtesy of Scott P. DeVries, Hunton Andrews Kurth and Yosef Itkin, Hunton Andrews Kurth Mr. DeVries may be contacted at sdevries@HuntonAK.com Mr. Itkin may be contacted at yitkin@HuntonAK.com Read the court decision
Read the full story...
Reprinted courtesy of

Pre-Judgment Interest Not Awarded Under Flood Policy

January 17, 2023 — Tred R. Eyerly - Insurance Law Hawaii
The court granted the insurer's motion to dismiss state law and extracontractual claims, including pre-judgment interest. Hurley v. Wright Nat'l Flood Ins. Co., 2022 U.S. Distl. LEXIS 203803 (W.D. La. Nov. 8, 2022). The insured suffered damage from Hurricane Delta. He filed suit, alleging that Wright National Flood Insurance Company breached the Standard Flood Insurance Policy (SFIP). The insured sought damages for state law claims for bad faith, diminution in value, actual repair costs, attorney's fees , litigation costs, and interest. Wright moved to dismiss the extracontractual state law causes of action for bad faith and various claims for damages, other than the damages sought for the alleged breach of the SFIP. The court explained that the Write-Your-Own (WYO) Program carriers issuing flood insurance under the National Flood Insurance Program (NFIP) arranged for the adjustment, settlement, payment, and defense of all claims arising from the policy. Congress underwrote all operations of the NIFP, including claims adjustment, through United States Treasury funds. A judgment against a WYO Program carrier constituted a judgment against FEMA, and consequently, a direct charge on the United States Treasury. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Five Frequently Overlooked Points of Construction Contracts

October 18, 2021 — Craig H. O'Neill - White and Williams LLP
There is no shortage of articles addressing the key points of construction contracts. Just enter that phrase into any internet search engine and you will find plenty. It should go without saying that a construction contract should be in writing, it should clearly identify the scope of work to be performed and the sums to be paid for that work, and it should address the parties’ rights and responsibilities with regard to termination or suspension of the contract, correcting defective work, and handling claims and disputes—just to name a few. Of course, these items should receive their due consideration. Too often, however, other important aspects of the construction contract get shortchanged. This article aims the spotlight on five often overlooked aspects of construction contracts. Project Schedules Surprisingly, many construction contracts pay little attention to a central component of any construction project: the project schedule. Many contracts provide the dates of commencement and substantial completion but not much else. With the frequent use of project management techniques such as the Critical Path Method (CPM) and the associated software, it is easier than ever to identify which tasks should be prioritized and identify potential areas of delay. The owner’s contract with the general contractor should clearly define the scheduling methods used and provide measures to keep the parties informed of the progress of the work. By including basic scheduling requirements in the contract documents—such as the submission of “Baseline Project Schedules” (consistent with the contract time provisions), “Schedule Progress Updates” (comparing the progress of the work against the Baseline Project Schedule), and “Schedule Recovery Plans” (when Schedule Project Updates indicate projected delays)—the parties can avoid or reduce disputes over project delays that often lead to litigation. Read the court decision
Read the full story...
Reprinted courtesy of Craig H. O'Neill, White and Williams LLP
Mr. O'Neill may be contacted at oneillc@whiteandwilliams.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES